<PAGE> 1
================================================================================
SECURITIES AND EXCHANGE COMMISSION
WASHINGTON, D.C. 20549
FORM 10-Q
(Mark One)
[X] QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
SECURITIES EXCHANGE ACT OF 1934
For the quarterly period ended March 31, 1999.
[ ] TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
SECURITIES EXCHANGE ACT OF 1934
COMMISSION FILE NUMBER: 00-23473
COMBICHEM, INC.
(Exact name of registrant as specified in its charter)
DELAWARE 33-0617379
(State or other jurisdiction of (I.R.S. Employer
incorporation or organization) Identification Number)
9050 Camino Santa Fe, San Diego, CA 92121
(Address of principal executive offices) (Zip Code)
REGISTRANT'S TELEPHONE NUMBER, INCLUDING AREA CODE IS (619) 530-0484
Indicate by check mark whether the registrant (1) has filed all reports
required to be filed by Section 13 or 15(d) of the Securities Exchange Act of
1934 during the preceding 12 months (or for such shorter period that the
registrant was required to file such reports), and (2) has been subject to such
filing requirements for the past 90 days.
(1) [X] Yes [ ] No; (2) [X] Yes [ ] No
As of May 12, 1999, there were 13,489,499 shares of $.001 par value common stock
outstanding.
================================================================================
<PAGE> 2
COMBICHEM, INC.
INDEX
<TABLE>
<CAPTION>
Page No.
--------
<S> <C>
PART I - FINANCIAL INFORMATION
Item 1. Financial Statements
Condensed Balance Sheets at March 31, 1999 (unaudited)
and December 31, 1998............................................. 1
Condensed Statements of Operations (unaudited) for the Three Months
Ended March 31, 1999 and 1998..................................... 2
Condensed Statements of Cash Flows (unaudited) for the
Three Months Ended March 31, 1999 and 1998........................ 3
Notes To Condensed Financial Statements.............................. 4
Item 2. Management's Discussion and Analysis of Financial Condition and Results
of Operations............................................................ 5
Item 3. Quantitative and Qualitative Disclosures About Market Risk............... 14
PART II - OTHER INFORMATION
Item 1. Legal Proceedings *...................................................... 15
Item 2. Change in Securities and Use of Proceeds................................. 15
Item 3. Defaults Upon Senior Securities *........................................ 15
Item 4. Submission of Matters to a Vote of Security Holders *.................... 15
Item 5. Other Information *...................................................... 15
Item 6. Exhibits and Reports on Form 8-K.......................................... 15
</TABLE>
* Not Applicable
<PAGE> 3
COMBICHEM, INC.
CONDENSED BALANCE SHEETS
(In Thousands)
<TABLE>
<CAPTION>
MARCH 31, DECEMBER 31,
1999 1998
--------- ------------
(UNAUDITED) (NOTE)
<S> <C> <C>
ASSETS
Current assets
Cash and cash equivalents $ 14,177 $ 20,334
Short-term investments 14,068 9,025
Accounts receivable 1,378 2,892
Prepaid expenses and other current assets 1,612 1,310
-------- --------
Total current assets 31,235 33,561
Property and equipment, net 7,829 7,902
Restricted cash 279 279
Deposits and other assets 602 238
Notes receivable from employees 75 --
-------- --------
Total assets $ 40,020 $ 41,980
======== ========
LIABILITIES AND STOCKHOLDERS' EQUITY
Current liabilities
Accounts payable and accrued expenses $ 1,766 $ 1,102
Accrued liabilities 813 1,295
Deferred revenue 3,900 3,193
Current portion of obligations under capital leases 2,281 1,825
-------- --------
Total current liabilities 8,760 7,415
Deferred rent 20 142
Obligations under capital leases, less current portion 3,838 4,246
Stockholders' equity (deficit):
Preferred stock, $.001 par value, 5,000,000 shares authorized; no shares
issued or outstanding at March 31, 1999 or December 31, 1998 -- --
Common stock, $.001 par value, 40,000,000 shares authorized; 13,450,145
and 13,399,201 shares issued and outstanding at March 31, 1999 and
December 31, 1998, respectively 13 13
Additional paid-in capital 52,100 51,862
Notes receivable from employees (411) (425)
Deferred compensation (1,030) (1,140)
Accumulated deficit (23,270) (20,133)
-------- --------
Total stockholders' equity 27,402 30,177
-------- --------
Total liabilities and stockholders' equity $ 40,020 $ 41,980
======== ========
</TABLE>
Note: The balance sheet at December 31, 1998 has been derived from the audited
financial statements at that date but does not include all of the
information and footnotes required by generally accepted accounting
principles for complete financial statements.
See accompanying notes
1
<PAGE> 4
COMBICHEM, INC.
CONDENSED STATEMENTS OF OPERATIONS
(In Thousands, Except Per Share Data)
<TABLE>
<CAPTION>
THREE MONTHS ENDED
MARCH 31,
------------------------
1999 1998
-------- --------
(unaudited)
<S> <C> <C>
Revenue:
Project initiation fees and
milestone payments $ 75 $ 750
Research and development
funding 2,243 1,872
ChiroChem service revenue 600 --
-------- --------
Total revenue 2,918 2,622
Expenses:
Research and development
Collaborative 2,509 1,923
Proprietary 1,539 1,315
-------- --------
4,048 3,238
General and administrative 1,202 892
ChiroChem service expense 600 --
-------- --------
Total operating expenses 5,850 4,130
-------- --------
Loss from operations (2,932) (1,508)
Interest income 360 236
Interest expense (140) (122)
Foreign tax expense -- (30)
Equity in net loss of 50%
owned joint venture (425) --
-------- --------
Net loss $ (3,137) $ (1,424)
======== ========
Net loss per share $ (0.24) $ (0.60)
======== ========
Shares used in calculating
net loss per share 12,979 2,368
======== ========
</TABLE>
See accompanying notes
2
<PAGE> 5
COMBICHEM, INC.
CONDENSED STATEMENTS OF CASH FLOWS
(IN THOUSANDS)
<TABLE>
<CAPTION>
THREE MONTHS ENDED MARCH 31
---------------------------
1999 1998
-------- --------
(unaudited)
<S> <C> <C>
CASH FLOWS FROM OPERATING ACTIVITIES:
Net loss $ (3,137) $ (1,424)
Adjustments to reconcile net loss to net cash
used in operating activities
Depreciation and amortization 525 331
Amortization of premium on short-term investments 23 41
Deferred rent (122) 13
Deferred revenue 707 1,191
Amortization of deferred compensation 110 110
Change in operating assets and liabilities:
Accounts receivable 1,514 (1,394)
Prepaid expenses and other current assets (270) (19)
Accounts payable and accrued liabilities 182 26
-------- --------
NET CASH USED IN OPERATING ACTIVITIES (468) (1,125)
CASH FLOWS FROM INVESTING ACTIVITIES:
Purchases of short-term investments (8,067) (2,561)
Maturities of short-term investments 3,000 3,000
Purchase of accrued interest on short-term investments (32) (108)
Purchases of property and equipment (451) (1,493)
Deposits and other assets (364) (150)
Notes receivable from employees (75) --
-------- --------
NET CASH USED IN INVESTING ACTIVITIES (5,989) (1,312)
CASH FLOWS FROM FINANCING ACTIVITIES:
Advances on capital lease obligations 635 871
Principal repayments on capital lease obligations (587) (387)
Issue of common stock, net of repurchased shares 239 --
Receipt of payment on note from stockholder 13 --
Restricted cash given as collateral for letter of credit -- --
-------- --------
NET CASH PROVIDED BY FINANCING ACTIVITIES 300 484
-------- --------
NET DECREASE IN CASH AND CASH EQUIVALENTS (6,157) (1,953)
CASH AND CASH EQUIVALENTS AT BEGINNING OF PERIOD 20,334 5,867
-------- --------
CASH AND CASH EQUIVALENTS AT END OF PERIOD $ 14,177 $ 3,914
======== ========
</TABLE>
See accompanying notes
3
<PAGE> 6
COMBICHEM, INC.
NOTES TO CONDENSED FINANCIAL STATEMENTS
(Unaudited)
1. Basis of Presentation
The unaudited financial statements have been prepared in accordance with
generally accepted accounting principles for interim financial
information. Accordingly, they do not include all of the information and
footnotes required by generally accepted accounting principles for
complete financial statements. In the opinion of management, all
adjustments (consisting of normal recurring accruals) considered
necessary for a fair presentation have been included. Interim results
are not necessarily indicative of the results that may be expected for
the year. For further information refer to the financial statements and
footnotes thereto for the year ended December 31, 1998 included in the
Company's annual report on Form 10-K.
2. Equity in Net Loss of 50% Owned Joint Venture
The Company owns a 50% interest in ChiroChem Discovery Services, LLC, a
limited liability corporation created to develop and market
computationally designed libraries of single-isomer, chiral compounds.
Pursuant to the terms of the agreement entered into with ChiroChem
Discovery Services, LLC, the Company will design and synthesize
information-rich chiral compound libraries. For the three months ended
March 31, 1999, the Company earned $0.6 million related to reimbursement
for expenses incurred on behalf of the joint venture and recognized a
$0.4 million loss for its equity in the loss of the joint venture.
3. Computation of Net Loss Per Share
Interpretations by the Securities and Exchange Commission have altered
the treatment of preferred stock previously included in computing
certain loss per share data. The Company previously considered
redeemable convertible preferred stock, which converted in conjunction
with the Company's initial public offering in May 1998, as outstanding
in pre-IPO periods from the date of original issuance ("as if converted
method"). To conform with the interpretations, the Company has revised
its calculation of loss per share for all pre-IPO periods to exclude the
impact of redeemable convertible preferred shares.
4
<PAGE> 7
ITEM 2. MANAGEMENT'S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS
OF OPERATIONS
This quarterly report may contain predictions, estimates and other
forward-looking statements that involve a number of risks and uncertainties,
including our dependence on the execution of new collaborative agreements and
other factors relating to our growth as well as those discussed below under
"Risks and Uncertainties." While this outlook represents our current judgment on
the future direction of our business, such risks and uncertainties could cause
actual results to differ materially from any future performance suggested below.
We undertake no obligation to release publicly the results of any revisions to
these forward-looking statements to reflect events or circumstances arising
after the date hereof.
OVERVIEW
CombiChem is a computational product discovery company that is applying
proprietary design technology and rapid synthesis capabilities to accelerate the
discovery process for new drugs and chemical products. We believe our approach
offers pharmaceutical and chemical companies the opportunity to conduct their
discovery efforts in a more productive and cost-effective manner. Using our
proprietary Discovery Engine(TM) process, we focus on the generation, evolution
and optimization of potential new lead candidates for our collaborative partners
who will then develop, manufacture, market and sell any resulting products. We
believe that our process is widely applicable to a variety of disease targets
and therapeutic indications as well as to other industries such as agrochemical,
industrial chemical and materials science. To date, we have established
collaborative agreements with Athena Neurosciences, Inc., a wholly owned
subsidiary of Elan Corporation, plc, ICOS Corporation, ImClone Systems
Incorporated, Novartis Crop Protection AG, Ono Pharmaceutical Co., Ltd., Roche
Bioscience, a division of Syntex (U.S.A.) Inc., Sumitomo Pharmaceuticals Co.,
Ltd. and Teijin Limited. In addition, we are using our approach on internal
programs to discover new lead candidates that will then be outlicensed to third
parties, while retaining a larger economic interest. In December 1998, we
further broadened the application of our technology by establishing a joint
venture with Chirotech Technology, Ltd., a member of the Chiroscience Group of
companies, to commercialize libraries of chiral compounds. The joint venture,
ChiroChem Discovery Services, LLC, was established to develop and sell
specifically designed chiral compound libraries.
Our revenue to date is primarily attributable to the receipt of project
initiation fees, milestone payments and research funding. Project initiation
fees are received from our collaborators upon, or shortly following, execution
of the collaborative agreement. Milestone payments are received from
collaborators upon achievement of certain pre-determined objectives. In
connection with the performance of research services, we receive research
funding under our collaborative agreements. Research funding typically is
received only during the life of the research program under the particular
collaboration. In addition, we may receive advance payments from our
collaborators or potential collaborators, which require us to complete certain
performance obligations. Such payments are recorded as deferred revenue when
received and are recognized as revenue when our performance obligations have
been met, as evidenced by our collaborator's written approval and acceptance.
The collaborative activities for which we receive revenue typically occur over a
one- to three-year period, if multiple projects are anticipated, or one to two
years for single project collaborations. The agreements provide for earlier
termination in certain circumstances. We expect that a significant portion of
our revenue for the foreseeable future will be comprised of such payments. The
receipt of project initiation fees is dependent on our ability to enter into
additional collaborative agreements that provide for such fees; the timing of
such payments will be difficult to predict. In addition, the timing of certain
revenue in the future will depend upon the completion of certain milestones as
provided for in our collaborative agreements, which are contingent and
uncertain. Milestone fees may be earned for different events or achievements in
different agreements. For certain collaborations, such fees may not be earned
until the collaborator has advanced products into human testing. In any one
fiscal quarter we may earn multiple or no payments from our collaborators.
Operating results may therefore vary substantially from period to period and
will not necessarily be indicative of results in subsequent periods. Completion
of the research phase of a single project collaboration or a single project
within a broad multiple project collaboration is not expected to have a material
adverse effect on our business. However, the termination or conclusion of any
collaborative agreement could have a material adverse effect on our business. In
addition, our failure to enter into additional collaborative agreements on
favorable terms would have a material adverse effect on our business.
We have not been profitable since inception and have incurred a cumulative
net loss of $23.3 million through March 31, 1999. Losses have resulted
principally from costs incurred in research and development
5
<PAGE> 8
activities related to efforts to develop our technologies and from the
associated administrative costs of supporting these efforts. Our ability to
achieve profitability is dependent on our ability to market our technology and
capabilities to pharmaceutical, biotechnology and agrochemical companies.
RESULTS OF OPERATIONS
THREE MONTHS ENDED MARCH 31, 1999 AND 1998
Revenue
Our revenue for the three months ended March 31, 1999 was $2.9 million, up
from $2.6 million for the same period in 1998. An increase in the number of
projects in the active collaboration phase accounted for $0.4 million of the
increase while $0.6 million is attributable to the reimbursement of costs
incurred on behalf of ChiroChem Discovery Services, LLC. These increases were
offset by a $0.7 million decrease in project initiation fees and milestone
payments.
Operating Expenses
Research and development expenses for the three months ended March 31, 1999
totaled $4.0 million compared to $3.2 million for the same period in 1998.
Research and development costs incurred on behalf of our collaborators increased
$0.6 million due to an increase in the number of projects in the active
collaboration phase. Research and development costs incurred to advance our
proprietary technologies increased $0.2 million as we further expanded the
application of our technologies. We expect research and development spending to
increase over the next several years due to increased activities related to
collaborators, internal programs and technology development.
General and administrative expenses for the three months ended March 31,
1999 totaled $1.2 million compared to $0.9 million for the same period in 1998.
The increase is primarily attributable to increased payroll and personnel
expenses incurred as we continue to expand both the size and activities of our
business development group in support of our continued expansion.
In conjunction with supporting the operations of our 50%-owned joint
venture, ChiroChem Discovery Services, other operating expenses increased $0.6
million for the period ended March 31, 1999. This increase was entirely
reimbursed by the joint venture.
Interest Income/Expense
Interest income totaled $0.4 million and $0.2 million in the three months
ended March 31, 1999 and 1998, respectively. The increase is a result of the
increase of the average balance of cash, cash equivalents and marketable
securities. Interest expense of $0.1 million for both periods relates to our
capital lease obligations.
Net Loss
For the three months ended March 31, 1999, our net loss increased to $3.1
million from $1.4 million for the same period in 1998. The increased loss for
the current period is attributable to increased operating expenses as discussed
above. In addition, we reported a $0.4 million loss for our 50% equity interest
in ChiroChem Discovery Services.
LIQUIDITY AND CAPITAL RESOURCES
From inception through March 31, 1999, we financed our operations through
proceeds from our initial public offering and private placements of equity
securities, payments from corporate collaborators and the utilization of capital
equipment lease financing. Net cash used in operating activities for the three
months ended March 31, 1999 was $0.5 million compared to $1.1 million for the
corresponding period in 1998. The decrease in net cash used in operating
activities was primarily attributable to the collection of advance payments from
collaborators.
6
<PAGE> 9
At March 31, 1999, we held cash and cash equivalents and short-term
investments with a value of $28.2 million. Working capital at March 31, 1999 was
$22.5 million. We have maintained capital lease arrangements since 1994. Under
these arrangements, we have funded certain capital expenditures with lease terms
ranging from 36 to 48 months in duration. As of March 31, 1999, we had utilized
$9.8 million of an available $11.4 million financing facility. We expect that
the net proceeds from our initial public offering completed in May 1998, and the
interest income generated from these proceeds, together with the existing cash
and cash equivalents, short-term investments, operating revenues and lease
financing arrangements, will be sufficient to finance our working capital and
capital requirements for the foreseeable future. Our capital requirements depend
on numerous factors. These factors include: (1) our ability to enter into
additional collaborative arrangements, (2) competing technological and market
developments, (3) changes in our existing collaborative relationships, (4) the
cost of filing, prosecuting, defending and enforcing patent claims and other
intellectual property rights, (5) the purchase of additional capital equipment,
(6) the progress of our drug discovery programs and (7) the progress of the
commercialization of milestone-and royalty-bearing compounds by our
collaborators. We may be required to raise additional capital over a period of
several years in order to continue to conduct our operations. Such capital may
be raised through additional public or private financing arrangements, as well
as collaborative arrangements, borrowings and other available sources. In
addition, we may from time to time earn milestone fees under our collaborations.
Milestone fees may be earned for different events or achievements in different
agreements. Furthermore, for certain collaborations, such fees may not be earned
until the collaborator has advanced products into later stage testing. Such
milestones may not be earned for several years, if at all. Our collaborative
arrangements may not produce revenue adequate to fund our operating expenses.
Additional funding, if necessary, may not be available on favorable terms, if at
all. If adequate funds are not available, we may be required to curtail
operations significantly or obtain funds through arrangements with collaborative
partners or others that may require us to relinquish rights to certain of our
technologies, product candidates, products or potential markets that we would
not otherwise relinquish. The failure to receive additional funding would have a
material adverse effect on our business and results of operations.
YEAR 2000 ISSUE
Description of the Issue. The Year 2000 issue refers to the inability of
certain date-sensitive computer chips, software, and systems to recognize a
two-digit date field as belonging to the 21st century. Mistaking "00" for 1900
or any other incorrect year could result in a system failure or miscalculations
causing disruptions to operations, including manufacturing, a temporary
inability to process transactions, or send invoices, or engage in other normal
business activities. This is a significant issue for most, if not all companies,
with far reaching implications, some of which cannot be anticipated or predicted
with any degree of certainty. The Y2K issue may create unforeseen risks from our
internal computer systems as well as from computer systems of third parties with
which we deal. Our failures and/or those of third parties' computer systems
could have a material adverse impact on our ability to conduct our business.
Year 2000 Readiness. We have formed a committee, including the Vice
President of Software R&D and the Information Technology Manager, to evaluate
Y2K risks and readiness. The committee has addressed both information technology
and non-information technology systems. Examples of information technology
systems include hardware and software purchased from external sources and
internally developed software. Examples of non-information technology systems
include laboratory equipment and those systems that operate the facilities
infrastructure. The committee has also considered the systems of those third
parties with which we maintain a material relationship.
We have substantially completed an assessment of our information technology
and non-information technology systems. The assessment phase is, however, an
on-going effort. As part of this effort, we are assessing the potential severity
of the impact of Y2K induced failures, conducting an inventory of information
systems for each business area, prioritizing systems or components to be
converted or replaced, and developing a contingency plan for mission critical
systems.
Renovation procedures have begun on those systems that we have identified
in our assessment as being non-Y2K compliant. This renovation entails
installation of commercially-available software and firmware updates and
performance of system tests. The renovation phase of our Year 2000 efforts is
approximately 90% complete.
7
<PAGE> 10
Although the assessment and renovation phases are not 100% complete, based
on the work performed to date, we do not foresee an inherently complex Y2K
problem. Accordingly, we will concurrently validate and implement converted or
replaced mission-critical systems. Validation will take place in an environment
that is representative of the true operating environment. Implementation will
address the integration of Y2K compliant systems into our true operating
environment and will take into consideration the interdependencies of the
systems involved. Finally, we will ensure that the Y2K contingency plan is
available for each business area. The validation phase is currently in process
and we expect this phase to be competed in the third quarter of 1999.
For material third parties, we are obtaining written assurances that their
systems and/or products are, or will be, Y2K compliant. However, we are not
independently verifying their representations. In addition, while we are not
dependent on any sole-source suppliers to conduct our laboratory operations,
efforts are ongoing to monitor the progress of the Y2K preparations of our
current major suppliers of laboratory materials.
Year 2000 Costs. The total cost of our Y2K activities is funded through
operating cash flows. We are expensing these costs as they are incurred. As of
March 31, 1999, we have not incurred any incremental costs to resolve our Y2K
issue and we expect that the total cost to become fully compliant will not
exceed $50,000.
Year 2000 Risks and Contingencies. In the event that systems of third-party
providers or vendors of laboratory supplies fail to resolve Y2K issues that
effect services or product deliveries to us, we may have to change providers or
vendors. Such changes are not anticipated to have a material adverse effect on
our business. As previously indicated, we are preparing a Y2K contingency plan
which addresses each of the mission-critical systems of our business areas. This
plan will also identify strategies and available resources necessary to restore
operations. We expect this plan to be completed by September 30, 1999.
RISKS AND UNCERTAINTIES
The following is a summary of some of the many risks we face in our
business. You should carefully review these risks in evaluating our business.
THE TECHNOLOGY WE USE IN OUR BUSINESS IS NEW AND HAS NOT BEEN SHOWN TO BE
SUCCESSFUL IN DISCOVERING NEW COMPOUNDS THAT ARE USEFUL.
Our discovery process is new. We have not yet shown that it can
successfully be used to discover candidates that ultimately become commercial
products. Furthermore, our discovery efforts are focused on some targets with
unknown functions. Development of new drugs and other useful products is highly
uncertain. Our discovery process may not result in candidates that will be safe
or effective or commercially successful as products. If our technology is not
validated through the successful discovery of candidates, our business will be
adversely affected.
Our strategy, which is unproven, is to use our proprietary technology to
rapidly identify, optimize and obtain rights to as many product candidates as
possible. Our near-term profitability depends entirely on whether we can enter
into additional collaborative agreements and maintain our current agreements.
The pricing and nature of our collaborative relationships, however, is such that
our potential customers may include only a limited number of drug,
biotechnology, agrochemical and materials science companies. Our strategy also
involves conducting our own discovery programs by choosing targets of current
scientific interest and working in collaboration with screening companies to
discover drug candidates. Accordingly, we cannot be certain that our strategy
will prove successful.
Our success also depends on whether potential customers view our process as
an effective discovery tool. Historically, drug, biotechnology, agrochemical and
materials science companies have identified and optimized new compounds in their
own research departments. They have done so primarily to protect the proprietary
nature of their activities. To achieve our business objectives, we must convince
these companies that our technology and capabilities justify the outsourcing of
their programs to us. We may not, however, be able to attract any future
customers on acceptable terms for our products and services or develop a
sustainable, profitable business. Any failure to do so would adversely affect
our business.
8
<PAGE> 11
We generally structure each of our collaborative agreements to provide us
with payments for:
- initiating the collaboration,
- providing research for a specified period (typically over one or two
years),
- attaining specifically negotiated milestones, and
- earning royalties from the commercial sale of any successfully
developed drug candidate.
To date, we have generated most of our revenues from providing research
services under our collaborative agreements. We receive these revenues, however,
only for a limited period and they are generally offset by corresponding
research costs. After we complete the research phase of each collaborative
agreement, we will receive additional revenues only if our collaborators achieve
the specified milestones or sell products on which we earn royalties from
commercial sales. Any failure to achieve the milestones or to earn royalties
could adversely affect our business.
WE MAY NEVER BE PROFITABLE.
Our near term profitability depends entirely on whether we can enter into
additional collaborative agreements and maintain our current agreements. As a
result, we are unable to predict when, or if, we will become profitable. We have
not yet received, and may never receive, any revenues from royalties for
commercial sales by a customer. In addition, our strategy includes potentially
developing and licensing drug candidates that we have identified through our
internal programs, at our own expense, to others for further development. To
date, we have not entered into any of these licenses. We may never enter into
any of these licenses on acceptable terms or at all.
THE SUCCESSFUL IMPLEMENTATION OF OUR STRATEGY IS DEPENDENT ON THE ACTIVITIES OF
OTHERS, OVER WHICH WE HAVE NO CONTROL.
Our strategy depends on our ability to enter into collaborative
arrangements with others on a regular basis. We may not be able to continue to
establish additional collaborative arrangements. If we are successful in
establishing additional arrangements, they may not be on favorable terms. The
collaborative arrangements also may not ultimately be successful. Any failure to
enter into additional collaborative arrangements on favorable terms would
adversely affect our business. The timing of when we receive revenues from
collaborative arrangements depends on both our efforts and our collaborators'
efforts.
We will depend on others' expertise and commitment to develop and
commercialize products based on candidates we discovered or optimized. The
amount and timing of resources that current and future collaborators devote to
our collaborations are not within our control, and we cannot be certain that
their efforts will be successful.
In addition, when we are eligible to earn milestone payments differs for
each agreement. For instance, for some collaborations, we may not earn milestone
fees until the collaborator has advanced drug products into human testing, which
may be well into the future. Furthermore, our collaborative partners are not
obligated to develop or commercialize product candidates we have discovered.
Rather, each collaborative partner may independently move forward with a
competing product candidate that the partner developed either internally or in
collaboration with others, including our competitors. The potential products a
collaborative partner develops also may be derivatives of the product candidates
we provided to the partner. While our existing collaborative agreements allow us
to retain milestone and royalty payment rights with respect to products
developed from certain derivatives, disputes may arise over how the payment
provisions in our agreements apply to those types of products.
Conflicts also may arise between collaborative partners about who has the
proprietary rights to particular compounds or product candidates. Additionally,
our collaborators generally may terminate their agreements with us upon short
notice and following an uncured material breach. Termination of our existing or
future collaborative agreements would result in a loss of anticipated revenue
and could adversely affect our business.
9
<PAGE> 12
Furthermore, even though we use independent teams for each collaborative
project, conflicts may arise among our collaborators about which collaborator
has rights to any overlapping compounds or product candidates developed with our
technologies. Any failure to manage our collaborative relationships
successfully, maintain confidentiality among our relationships or prevent these
types of conflicts could lead to costly and time-consuming disputes and a loss
of reputation, capital or current or future collaborators. Any of these events
could adversely affect our business.
SIGNIFICANT FLUCTUATIONS IN OUR QUARTERLY RESULTS COULD MATERIALLY IMPACT OUR
STOCK PRICE.
Our operating results may vary substantially from quarter to quarter and
will not necessarily be indicative of results in later periods. Any quarterly
fluctuations in revenue or financial results may materially impact our stock
price. To date, we have received revenues from project initiation fees, research
funding and milestone fees paid under our collaborative agreements. We expect
that most of our revenues for the foreseeable future will continue to consist of
these payments. In any one quarter, we may receive multiple or no payments from
our collaborators.
OUR SUCCESS IS DEPENDENT ON OUR ABILITY TO BUILD AND MAINTAIN A STRONG
INTELLECTUAL PROPERTY POSITION; FAILURE TO DO SO WOULD HAVE AN ADVERSE EFFECT ON
OUR BUSINESS.
Our success will depend on our ability and the ability of our licensors to
obtain and defend patents and other proprietary rights for our technologies and
the compounds and other products resulting from our technologies. In addition,
to be successful we must avoid infringing the proprietary rights of others. Our
patent position, like that of many companies, is uncertain and involves complex
legal and factual questions for which important legal principles are unresolved.
We may not develop or obtain rights to products or processes that are
patentable. Even if we do obtain patents, they may not adequately protect the
technology we own or have licensed. In addition, others may challenge, seek to
invalidate, infringe or circumvent any patents we own or license, and rights we
receive under those patents may not provide competitive advantages to us.
Further, our activities may infringe the patent rights of others.
We cannot be certain that any patents will issue as a result of any pending
applications. In addition, any issued patents still may not provide sufficient
protection against competitors with similar technologies. Although we believe
that our current activities do not infringe any patents of others, we
continually assess our position. We cannot be certain that we would be
successful in any litigation over patents or that our future technological
developments will be outside the scope of others' patent rights.
We may also need to initiate litigation, which could be time consuming and
expensive, to enforce our proprietary rights or to determine the scope and
validity of others' rights. If litigation results, a court may find our patents
or those of our licensors invalid or may find that we have infringed on a
competitor's rights. If any of our competitors have filed patent applications in
the United States which claim technology we also have invented, the Patent and
Trademark Office may require us to participate in expensive interference
proceedings to determine who has the right to a patent for the technology.
We currently license rights from other parties. In the future, we may
require additional licenses from other parties to refine our drug discovery
process further and to allow our collaborators to develop, manufacture and
market commercially viable products effectively. We cannot be certain that:
- we will be able to obtain any licenses on commercially reasonable
terms, or at all,
- any patents underlying such licenses will be valid and enforceable, or
- the proprietary nature of any patented technology underlying such
licenses will remain proprietary.
In addition, if we breach any of our licenses, we may lose important
rights.
We also rely on unpatented trade secrets and know-how to maintain our
competitive position, which we seek to protect, in part, by confidentiality
agreements with employees, consultants and others. These parties may
10
<PAGE> 13
breach or terminate these agreements, and we may not have adequate remedies for
any breach. In addition, our competitors may independently discover our trade
secrets. We also rely substantially on certain technologies that are not
patentable or proprietary and are therefore available to our competitors.
OUR INDUSTRY IS EXTREMELY COMPETITIVE AND WE MAY ULTIMATELY PROVE UNSUCCESSFUL.
Many organizations are actively attempting to identify, optimize and
generate compounds for potential drug, agrochemical and materials science
development. We compete with the research departments of drug companies,
biotechnology companies, agrochemical companies, combinatorial chemistry
companies and research and academic institutions as well as other product
discovery companies. Many of our competitors have greater financial and human
resources and more experience in research and development than us. We anticipate
that we will face increased competition in the future as new companies enter the
market and advanced technologies become available. Ultimately, our processes may
become obsolete or uneconomical as a result of new technologies or approaches
our competitors develop.
FAILURE TO EXPAND OUR OPERATIONS AND MANAGE OUR EXPANDED OPERATIONS WOULD HAVE
AN ADVERSE EFFECT ON OUR BUSINESS.
Our success will depend on whether we can expand our operations to service
additional collaborative arrangements and manage our expanded operations. To be
cost-effective, we must enhance our productivity by further automating our
processes and improving our technology generally. In addition, we must
successfully structure and manage additional collaborative relationships,
including maintaining the confidentiality of the research being provided to our
customers. We may not be able to add the technical personnel needed to meet the
staffing requirements of any additional collaborative relationships. In
addition, our efforts to automate our processes further or to improve our
technology may not be successful. Any failure to achieve these goals could
adversely affect our business.
THE LOSS OF ONE OR MORE OF THE KEY MEMBERS OF OUR SCIENTIFIC AND MANAGEMENT
STAFF COULD ADVERSELY AFFECT OUR BUSINESS
The loss of one or more of the key members of our scientific and management
staff could adversely affect our business. Our future success also depends on
the continued service of our key design, engineering, scientific, software and
management personnel and on our ability to identify, hire and retain any
additional personnel. There is intense competition for these qualified
personnel. We may not be able to continue to attract and retain the personnel
necessary to develop our business. Any failure to attract and retain key
personnel could adversely affect our business.
FAILURE TO COMPLY WITH REGULATORY REQUIREMENTS WOULD HAVE AN ADVERSE EFFECT ON
OUR BUSINESS.
Any failure to comply with regulatory requirements in the United States and
overseas can result in fines, warning letters, recall or seizure of products,
clinical study holds or delays, total or partial suspension of production,
refusal of the government to grant approvals, and civil and criminal penalties.
United States and foreign government regulation will be a significant factor in
the production and marketing of any products that we, our customers or our
collaborators develop. The scope of the regulation will vary depending on the
type of products involved. Virtually all products our customers develop will
require regulatory approval. For example, the FDA and foreign regulatory
authorities require vigorous early state and human testing and other procedures
for human drug products. Numerous regulations also govern the manufacturing,
safety, labeling, storage, record keeping, reporting and marketing of products
developed by our customers.
The process of obtaining and complying with regulatory approvals is time
consuming and expensive. The testing and approval processes require substantial
time and we cannot be certain if or when any approval will be granted for any
products resulting from our technologies.
Even if regulatory clearances are obtained, a marketed product may be
subject to continual review. Later discovery of previously unknown problems or
failure to comply with the applicable regulatory requirements may
11
<PAGE> 14
result in restrictions on a product's marketing or withdrawal of the product
from the market, as well as possible civil or criminal sanctions. In addition,
domestic manufacturing facilities are subject to inspections and must comply
with certain manufacturing practices regulations. To comply with these
regulations, a manufacturer must spend funds, time and effort on production and
quality control. For marketing outside the United States, we, our collaborators
or customers may be subject to foreign regulatory requirements.
OUR FUTURE CAPITAL NEEDS ARE UNCERTAIN AND MAY HAVE AN ADVERSE EFFECT ON OUR
BUSINESS.
Our capital requirements depend on many factors, including:
- our ability to enter into additional collaborative arrangements,
- competing technological and market developments,
- changes in our existing collaborative arrangements,
- the cost of filing, prosecuting, defending and enforcing patent claims
and other proprietary rights,
- the purchase of additional equipment,
- the progress in our discovery programs, and
- our collaborators' ability to commercialize milestone and
royalty-bearing compounds.
We may be required to raise additional capital over a period of several
years to continue our operations. Additional funding, if necessary, may not be
available on favorable terms. If adequate funds are not available, we may be
required to curtail operations significantly or obtain funds through
arrangements with collaborative partners or others that may require us to
relinquish rights to certain of our technologies, product candidates, products
or potential markets that we would not otherwise relinquish. Any failure to
receive additional funding would adversely affect our business.
THE EFFORTS OF THE GOVERNMENT AND OTHERS TO REDUCE THE COST OF HEALTH CARE MAY
HAVE AN ADVERSE EFFECT ON OUR COLLABORATORS AND OUR BUSINESS.
We expect that a substantial portion of our revenue in the foreseeable
future will be derived from products and services provided to the drug,
biotechnology, agrochemical and materials science industries. Accordingly, our
success in the foreseeable future depends on the success of the companies within
those industries and continued demand for our products and services.
The efforts of governments and third party payors to contain or reduce the
cost of health care will continue to affect the business and financial condition
of these companies. For example, in certain foreign markets, pricing or
profitability of prescription pharmaceuticals is subject to governmental
control. In the United States, a number of legislative and regulatory proposals
to change the health care system have been proposed in recent years. In
addition, an increasing emphasis on managed care in the United States has and
will continue to increase pressure on drug pricing. We cannot predict whether
legislative or regulatory proposals will be adopted. If proposals or reforms are
adopted and adversely affect the business of our collaborators or customers, our
business may also be adversely affected.
OUR USE OF HAZARDOUS MATERIALS MAY SUBJECT US TO SIGNIFICANT ENVIRONMENTAL
RISKS.
We use hazardous materials in our research and development activities. As a
result, we are subject to federal, state and local laws and regulations
governing the use, manufacture, storage, handling and disposal of hazardous
materials. The risk of accidental contamination or injury exists. If an accident
occurs, we could be responsible for any damages and the amount of the damages
could exceed our resources. In addition, we may incur
12
<PAGE> 15
significant costs to comply with environmental laws and regulations in the
future. Any of these events could adversely affect our business.
THE MARKET PRICE OF OUR COMMON STOCK IS VOLATILE AND YOU MAY NOT BE ABLE TO MAKE
A RETURN ON YOUR INVESTMENT.
The market price of our common stock is likely to be volatile and could
fluctuate widely in response to many factors, including:
- announcements of new technologies or products by us or our
competitors,
- developments concerning patents or other proprietary rights,
- publicity regarding the status of compounds we or our collaborators
are developing,
- regulatory developments, both in the United States and foreign
countries,
- public concern about the effectiveness of new technologies,
- changes in expectations of securities analysts concerning our company
or our industry in general;
- quarterly fluctuations in our revenues and financial results, and
- general market conditions.
As a result, our operating results may be below the expectations of market
analysts and investors, which could reduce the market price of our common stock.
The stock market has experienced extreme price and volume fluctuations that
have particularly affected the market prices of the securities of many companies
in our industry. Often, these fluctuations have been unrelated or
disproportionate to the operating performance of the companies. These market
fluctuations, as well as general economic, political and market conditions, may
reduce the market price of our common stock. In addition, in the past,
securities class action litigation has often been instituted following periods
of volatility in the market prices of securities. If we face such litigation in
the future, it would be costly and time consuming and could adversely affect our
business.
OUR CHARTER, DELAWARE LAW AND CONTRACT PROVISIONS MAY PREVENT OR DELAY A CHANGE
OF CONTROL WHICH MAY NOT BE IN THE BEST INTERESTS OF OUR STOCKHOLDERS.
Provisions of our charter and stock options, as well as provisions of
Delaware law, could delay or impede the removal of incumbent directors and could
make more difficult a merger, tender offer or proxy contest involving us, even
if the events could be beneficial to our stockholders. These provisions could
also limit the price that investors might be willing to pay for our common
stock. Our charter also authorizes our Board of Directors to issue shares of
undesignated preferred stock without stockholder approval on terms that the
Board may determine. The issuance of preferred stock could decrease the amount
of earnings and assets available for distribution to our other stockholders or
otherwise adversely affect the rights and powers, including voting rights, of
our other stockholders. Moreover, the issuance of preferred stock may make it
more difficult for another party to acquire, or may discourage another party
from acquiring, voting control of us.
WE MAY NOT BE SUCCESSFUL IN RESOLVING ALL OUR YEAR 2000 ISSUES THAT COULD HAVE
AN ADVERSE EFFECT ON OUR BUSINESS.
The year 2000 issue refers to the inability of certain date-sensitive
computer chips, software, and systems to recognize a two-digit date field as
belonging to the 21st century. This is a significant issue for most, if not all
companies, with far reaching implications, some of which cannot be anticipated
or predicted with any degree of certainty. The year 2000 issue may create
unforeseen risks to us from our internal computer systems as well as from
computer systems of others with whom we deal. Any failure of our and/or others'
computer systems could
13
<PAGE> 16
adversely affect our business. For a more complete description of the status of
our year 2000 readiness program and contingency plans we have instituted, please
see Part I, Item 2 - "Management's Discussion and Analysis of Financial
Condition and Results of Operations - Year 2000 Issue."
ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK
The information called for by this item has not changed materially since
December 31, 1998. Please see Part I, Item 7A of our annual report on Form 10-K
for the fiscal year ended December 31, 1998 for a discussion of our disclosures
about market risk.
14
<PAGE> 17
PART II - OTHER INFORMATION
ITEM 1. LEGAL PROCEEDINGS
None
ITEM 2. CHANGE IN SECURITIES AND USE OF PROCEEDS
(a) None
(b) None
(c) In February 1999, we issued a common stock purchase warrant
exercisable into 180,000 shares of common stock at an exercise price
of $8.00 per share. The warrant was issued to our new landlord in
connection with the execution of a lease agreement. The warrant first
becomes exercisable on the commencement date of the lease agreement
and expires on February 22, 2006. The above securities were offered
and sold by us in reliance upon exemptions from registration pursuant
to Section 4(2) of the Securities Act of 1933 as transactions not
involving any public offering. No underwriters were involved in
connection with the sales of securities referred to in this Item 2.
(d) A Registration Statement on Form S-1 (File No. 333-37981) registering
2,587,500 shares of common stock filed in connection with our initial
public offering for an aggregate offering of $20.7 million was
declared effective by the SEC on May 7, 1998. As of March 31, 1999,
none of the net offering proceeds has been used.
ITEM 3. DEFAULTS UPON SENIOR SECURITIES
None
ITEM 4. SUBMISSION OF MATTERS TO A VOTE OF SECURITY HOLDERS
None
ITEM 5. OTHER INFORMATION
None
ITEM 6. EXHIBITS AND REPORTS ON FORM 8-K.
a. Exhibits
3.1+ Amended and Restated Certificate of Incorporation
of the Company, previously filed as Exhibit 3.2 on
Form S-1, File No. 333-37981, and incorporated
herein by reference.
3.2+ Restated Bylaws of the Company, previously filed as
Exhibit 3.4 on Form S-1, File No. 333-37981, and
incorporated herein by reference.
10.68 Lease agreement between LMC-Shoreham Investment
Company, LLC, Convoy Court Investment Company, LLC,
and CombiChem, Inc., dated February 23, 1999.
10.69 Common Stock Purchase Warrant between the Company
and Lee M. Chestnut, dated February 23, 1999.
27.1 Financial Data Schedules.
b. None.
+ Incorporated by reference to the same-numbered exhibit (except as otherwise
indicated) to the Company's Registration Statement on Form S-1 (No.
333-37981), as amended.
15
<PAGE> 18
COMBICHEM, INC.
SIGNATURES
Pursuant to the requirements of the Securities Exchange Act of 1934, the
registrant has duly caused this report to be signed on its behalf by the
undersigned thereunto duly authorized.
CombiChem, Inc.
Date: May 14, 1999 By: /s/ VICENTE ANIDO, JR.
------------- ------------------------------------
Vicente Anido, Jr., Ph.D.
President, Chief Executive Officer
and Acting Chief Financial Officer
(Principal Financial and
Accounting Officer)
16
<PAGE> 1
EXHIBIT 10.68
================================================================================
LEASE
4570 EXECUTIVE DRIVE
================================================================================
Between
COMBICHEM, INC.
(Tenant)
and
LMC-SHOREHAM INVESTMENT COMPANY, LLC
and
CONVOY COURT INVESTMENT COMPANY, LLC
as Tenants in Common
(Landlord)
<PAGE> 2
LEASE TABLE OF CONTENTS
<TABLE>
<CAPTION>
PAGE
----
<S> <C> <C>
1. LEASE AGREEMENT..................................................................... 4
2. RENT................................................................................ 4
A. Types of Rent................................................................ 4
1. Base Rent............................................................. 4
2. Operating Cost Share Rent............................................. 4
3. Tax Share Rent........................................................ 4
4. Additional Rent....................................................... 4
5. Rent.................................................................. 5
B. Payment of Operating Cost Share Rent and Tax Share Rent...................... 5
1. Payment of Estimated Operating Cost Share Rent and Tax Share Rent..... 5
2. Correction of Operating Cost Share Rent............................... 5
3. Current Tax Share Rent................................................ 5
C. Definitions.................................................................. 5
1. Included Operating Costs.............................................. 5
2. Excluded Operating Costs.............................................. 6
3. Taxes................................................................. 8
4. Lease Year............................................................ 9
5. Fiscal Year........................................................... 9
D. Computation of Base Rent and Rent Adjustments................................ 9
1. Prorations............................................................ 9
2. Default Interest......................................................10
3. Rent Adjustments......................................................10
4. Books and Records.....................................................10
5. Miscellaneous.........................................................10
3. PREPARATION AND CONDITION OF PREMISES; POSSESSION AND SURRENDER OF PREMISES.........10
A. Condition of Premises........................................................10
B. Measurement of Premises......................................................11
C. Tenant's Possession..........................................................11
D. Surrender....................................................................12
4. PROJECT SERVICES....................................................................12
A. Heating and Air Conditioning.................................................12
B. Elevators....................................................................12
C. Electricity..................................................................12
D. Water........................................................................12
E. Exercise Room and Shower.....................................................12
F. Interruption of Services.....................................................12
G. Parking......................................................................13
</TABLE>
<PAGE> 3
<TABLE>
<S> <C> <C>
5. ALTERATIONS, MAINTENANCE AND REPAIRS................................................13
A. Landlord's Consent and Conditions............................................13
B. Maintenance and Repairs......................................................14
C. No Liens.....................................................................15
D. Ownership of Improvements....................................................16
E. Removal at Termination.......................................................16
F. Landlord's Work..............................................................17
6. USE OF PREMISES.....................................................................17
7. GOVERNMENTAL REQUIREMENTS AND PROJECT RULES.........................................18
8. WAIVER OF CLAIMS; INDEMNIFICATION; INSURANCE........................................18
A. Waiver of Claims.............................................................18
B. Indemnification..............................................................18
C. Tenant's Insurance...........................................................18
D. Insurance Certificates.......................................................20
E. Landlord's Insurance.........................................................20
9. FIRE AND OTHER CASUALTY.............................................................21
A. Termination..................................................................21
B. Restoration..................................................................21
10. EMINENT DOMAIN......................................................................21
11. RIGHTS RESERVED TO LANDLORD.........................................................22
A. Name.........................................................................22
B. Signs........................................................................22
C. Window Treatments............................................................22
D. Keys.........................................................................22
E. Access.......................................................................22
F. Preparation for Reoccupancy..................................................22
G. Heavy Articles...............................................................23
H. Show Premises................................................................23
I. Use of Lockbox...............................................................23
J. Repairs and Alterations......................................................23
K. Landlord's Agents............................................................23
L. Building Services............................................................23
M. Other Actions................................................................23
N. Driveway Easement............................................................23
12. TENANT'S OR LANDLORD'S DEFAULT......................................................23
A. Rent Default.................................................................24
B. Performance Default..........................................................24
C. Credit Default...............................................................24
D. Abandonment Default..........................................................24
E. Landlord Default.............................................................24
</TABLE>
<PAGE> 4
<TABLE>
<S> <C> <C>
13. LANDLORD REMEDIES...................................................................24
A. Termination of Lease or Possession...........................................24
B. Lease Termination Damages....................................................25
C. Continuation of Lease........................................................25
D. Possession Termination Damages...............................................25
E. Landlord's Remedies Cumulative...............................................26
F. WAIVER OF TRIAL BY JURY......................................................26
G. Litigation Costs.............................................................26
14. SURRENDER...........................................................................26
15. HOLDOVER............................................................................26
16. SUBORDINATION TO GROUND LEASES AND MORTGAGES........................................27
A. Subordination................................................................27
B. Termination of Ground Lease or Foreclosure of Mortgage.......................27
C. Security Deposit.............................................................28
D. Notice and Right to Cure.....................................................28
E. Definitions..................................................................28
17. ASSIGNMENT AND SUBLEASE.............................................................28
A. In General...................................................................28
B. Landlord's Consent...........................................................29
C. Procedure....................................................................29
D. Permitted Transfers..........................................................29
E. Excess Payments..............................................................30
F. Landlord's Assignment........................................................30
18. CONVEYANCE BY LANDLORD..............................................................30
19. ESTOPPEL CERTIFICATE................................................................30
20. SECURITY DEPOSIT....................................................................31
21. FORCE MAJEURE.......................................................................31
22. NOTICES.............................................................................31
A. Landlord.....................................................................32
B. Tenant.......................................................................32
23. QUIET POSSESSION....................................................................32
24. REAL ESTATE BROKER..................................................................32
25. MISCELLANEOUS.......................................................................32
A. Successors and Assigns.......................................................32
B. Date Payments Are Due........................................................33
C. Meaning of "Landlord," "Re-Entry," "Including" and "Affiliate"...............33
</TABLE>
<PAGE> 5
<TABLE>
<S> <C> <C>
D. Time of the Essence..........................................................33
E. No Option....................................................................33
F. Severability.................................................................33
G. Governing Law................................................................33
H. Lease Modification...........................................................33
I. No Oral Modification.........................................................33
J. Landlord's Right to Cure.....................................................33
K. Captions.....................................................................33
L. Authority....................................................................33
M. Landlord's Enforcement of Remedies...........................................33
N. Entire Agreement.............................................................34
O. Singular and Plural..........................................................34
P. Memorandum of Lease..........................................................34
Q. Exclusivity..................................................................34
R. No Construction Against Drafting Party.......................................34
S. Survival.....................................................................34
T. Rent Not Based on Income.....................................................34
U. Building Manager and Service Providers.......................................34
V. Late Charge and Interest on Late Payments....................................34
W. Lease Termination Agreement and Agreement for Purchase and Sale..............34
26. UNRELATED BUSINESS INCOME...........................................................35
27. HAZARDOUS SUBSTANCES................................................................35
28. EXCULPATION.........................................................................36
29. ARBITRATION OF DISPUTES.............................................................36
A. Disputes Subject to Arbitration..............................................36
B. Enforcement..................................................................38
30. RIGHT OF FIRST NEGOTIATION..........................................................38
31. CONDITION PRECEDENT: LANDLORD'S ACQUISITION OF THE PROPERTY.........................39
32. CONDITION PRECEDENT: LANDLORD'S LENDER APPROVAL.....................................39
33. LANDLORD'S INDEMNITY AND LIQUIDATED DAMAGES.........................................39
34. OPTION TO RENEW.....................................................................40
</TABLE>
<PAGE> 6
EXHIBITS
EXHIBIT A - PLAN OF THE PREMISES
EXHIBIT B - RULES AND REGULATIONS
EXHIBIT C - TENANT IMPROVEMENT AGREEMENT
EXHIBIT D - MORTGAGES CURRENTLY AFFECTING THE PROJECT
EXHIBIT E - COMMENCEMENT DATE CONFIRMATION
EXHIBIT F - SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT
EXHIBIT G - MEMORANDUM OF LEASE
EXHIBIT H - LANDLORD'S CONSENT TO ENCUMBRANCE BY TENANT OF LEASEHOLD ESTATE
EXHIBIT I - ENVIRONMENTAL ASSESSMENT CRITERIA
<PAGE> 7
LEASE
THIS LEASE (the "Lease") is made as of February 23, 1999 between
LMC-SHOREHAM INVESTMENT COMPANY, LLC, a California limited liability company,
and CONVOY COURT INVESTMENT COMPANY, LLC, a California limited liability
company, as tenants in common (the "Landlord"), and the Tenant named in the
Schedule below.
The following schedule (the "Schedule") is an integral part of this
Lease. Terms defined in this Schedule shall have the same meaning throughout the
Lease.
SCHEDULE
1. TENANT: CombiChem, Inc., a Delaware corporation.
2. PROJECT: Lots 1, 2 and 3 of Nexus Technology Centre Unit No. 1,
in the City of San Diego, County of San Diego, State of
California, according to Map thereof No. 11876, filed in the
Office of the County Recorder of San Diego County, August 7,
1987.
3. BUILDING: The building to be constructed known as 4570 Executive
Drive, San Diego, California.
4. PROPERTY: Lot 2 of the Project.
5. PREMISES: A portion of the Building as shown on Exhibit A
attached hereto. If, prior to the commencement of construction of
the Tenant Improvements, Tenant desires to modify the lay-out of
the Premises, Landlord shall in good faith accommodate Tenant's
reasonable request therefor. In addition, Landlord shall, at
Tenant's request made prior to Landlord's approval of the Plans
for the Tenant Improvements, provide sufficient space on the
first floor of the Building for Tenant's staging, shipping and/or
receiving activities. In the event that Tenant does request such
space for staging, shipping and/or receiving, such space shall be
part of the Premises and be included in the calculation of
Rentable Area. If the parties agree upon a revised lay-out for
the Premises, then the parties shall promptly amend Exhibit A of
this Lease to include a floor plan of each floor of the Building
with those portions of the Building which comprise the Premises
marked accordingly.
6. RENTABLE AREA: Approximately 75,000 rentable square feet
("Rentable Area") subject to adjustment pursuant to Section 3B.
Landlord shall use its best efforts, however, from the date
hereof through the Commencement Date to reduce the Rentable Area
of the Premises by 5,000 rentable square feet by leasing such
space to a third party. If Landlord succeeds in reducing the
Rentable Area of the Premises by this amount (which shall be
proven by the measurement required under Section 3B of this
Lease) on or before the Commencement Date, Base Rent and all
other items that are based upon the Rentable Area of the Premises
shall be adjusted accordingly. If Landlord fails to reduce the
Rentable Area by such
1
<PAGE> 8
amount on or before the Commencement Date, Landlord shall not
increase the Base Rent for the Premises for the second year of
the Term, as more fully described in item 12 of the Schedule.
Thus, the Base Rent shall remain $191,250 (subject to adjustment
pursuant to Section 3B of the Lease) until the commencement of
the third year of the Term when the annual adjustments described
in item 12 of the Schedule shall commence; provided, however, the
maximum increase to the Base Rent for the third Lease Year shall
not exceed ten percent (10%) of the Base Rent for the first Lease
Year.
7. TENANT'S PROPORTIONATE SHARE: Approximately 62.5% with respect to
the Building. Tenant's Proportionate Share shall be calculated by
dividing the rentable square footage of the Premises by the total
rentable square footage of the Building.
8. SECURITY DEPOSIT: $191,250.
9. TENANT IMPROVEMENTS: See the Tenant Improvement Agreement
attached hereto as Exhibit C.
10. COMMENCEMENT DATE: Ten (10) days following the Substantial
Completion (as defined in Exhibit C) of the Tenant Improvements.
Within five (5) business days following the Commencement Date,
Landlord and Tenant shall execute a Commencement Date
Confirmation substantially in the form of Exhibit E attached
hereto. Within five days following Landlord's acquisition of fee
title to the Property, Landlord and Tenant shall execute and
cause to be recorded a Memorandum of Lease substantially in the
form of Exhibit H attached hereto.
11. TERMINATION DATE/TERM: The Lease term shall end fifteen (15)
years after the Commencement Date, or if the Commencement Date is
not the first day of a month, then the Lease term shall end
fifteen (15) years after the first day of the calendar month
following the Commencement Date.
12. BASE RENT: $191,250 per month ($2.55 per rentable square foot).
Base Rent shall be adjusted each year as follows:
Except as set forth in item 6 of this Schedule, at the
commencement of the second Lease Year and at the commencement of
each Lease Year thereafter, the Base Rent (as the same may have
been previously increased pursuant to this section) will be
increased by multiplying the Base Rent for the first Lease Year
(i.e., $191,250/month, subject to possible adjustment based upon
a determination of change in the Rentable Area of the Premises as
provided in Section 3B below) will be multiplied by a fraction,
the numerator of which is the Index (defined below) for the last
period for which the Index is published and ends before the
commencement of the Lease Year for which the calculation is being
made and the denominator of which is the Index for the same
calendar period immediately preceding the Commencement Date. As
used herein, the term "Index" is that which is published by the
United States Department of Labor, Bureau of Labor
2
<PAGE> 9
Statistics in the Consumer Price Index for all Urban Consumers
(CPI-U): San Diego, 1982-84 Base. The Base Rent as so increased
will be paid in accordance with the provisions of Section 2A1 of
this Lease. By way of illustration only, if (1) the Commencement
Date were November 1, 1999, (2) the first Lease Year ended on
October 31, 2000 and (3) the Index were published monthly, then
the Base Rent for the Lease Year beginning on November 1, 2000,
would be determined by multiplying the Base Rent for the first
Lease Year (i.e., assume $191,250/month) by a fraction, the
numerator of which is the Index for October, 2000 (assume such
Index equals 171.6) and the denominator of which is the Index for
October, 1999 (assume such Index equals 165.0) and, under those
assumed facts, the Base Rent for the Lease Year commencing
November 1, 2000, would be $198,900. Notwithstanding the
foregoing, the maximum increase of Base Rent for any Lease Year
shall not exceed five percent (5%) of the Base Rent for the
preceding Lease Year. If the Bureau of Labor Statistics
discontinues the publication of the Index or publishes the Index
less frequently or alters the Index in some manner, then Landlord
will adopt a substitute index or substitute procedure which
reasonably reflects and monitors changes in consumer prices
subject to Tenant's reasonable approval. In no event will Base
Rent be decreased. Landlord's failure by reason of oversight,
mistake or otherwise promptly to make the calculation or advise
Tenant of the amount of increased Base Rent or to collect any
increased Base Rent determined as set forth above, will not
release Tenant of Tenant's obligation to pay Landlord, forthwith
upon discovery of such oversight or mistake, an amount equal to
the difference between Base Rent actually paid and the increased
Base Rent that should have been paid.
13. PERMITTED USES: Provided that such uses comply with all
Governmental Requirements (as hereinafter defined) and the
provisions of the Rules and Regulations attached as Exhibit B
hereto, the Premises may be used for (1) General office purposes
(including, but not limited to, sales and marketing); (2)
research and development (including, but not limited to, light
manufacturing of Tenant's products within the laboratory spaces
of the Building as necessary to produce Tenant's chemical
libraries for its partners, collaborators and customers and
otherwise without substantial changes to the Initial
Improvements); (3) warehouse, shipping and receiving; and (4)
other light manufacturing in accordance with Governmental
Requirements.
14. TENANT'S PARKING RIGHTS: Tenant shall be entitled to Tenant's
Proportionate Share of the four hundred twenty-one (421)
available parking spaces. Ten (10) such parking spaces shall be
exclusive which such exclusive parking spaces shall be the ten
(10) parking spaces closest to the Building's passenger
elevators, as determined by Tenant.
15. REA: That certain Reciprocal Easement Agreement dated as of
December 21, 1993 by and between Gensia, Inc., a Delaware
corporation, and Gena Property Company, a California general
partnership, and recorded in the Official Records of the San
Diego County Recorder's Office on December 22, 1993 as Document
Number 1993-0865825. Tenant has received and reviewed a copy of
the REA.
3
<PAGE> 10
16. EXHIBITS: Exhibits A - I attached hereto as incorporated herein
by this reference.
17. ZONING: Landlord represents and warrants that Tenant's intended
use of the Premises complies with the zoning applicable to the
Property as of the date of this Lease.
18. TARGET COMMENCEMENT DATE: November 1, 1999.
1. LEASE AGREEMENT. On the terms stated in this Lease, Landlord leases
the Premises to Tenant, and Tenant leases the Premises from Landlord, for the
Term beginning on the Commencement Date and ending on the Termination Date
unless extended or sooner terminated pursuant to this Lease.
2. RENT.
A. Types of Rent. Tenant shall pay the following Rent, in the form of a
check payable to LMC-Shoreham Investment Company, LLC to Landlord at the
following address:
LMC-Shoreham Investment Company, LLC
c/o Lee Chesnut
9627 Grossmont Summit Drive
La Mesa, CA 91941
or, at Landlord's option, by wire transfer to such account(s) as Landlord shall
notify Tenant, or in such other reasonable manner as Landlord may notify Tenant:
1. Base Rent in monthly installments, without deduction or
offset, in advance on or before the first day of each month of the Term
in the amount set forth on the Schedule. Base Rent for the first full
calendar month of the first Lease Year shall be paid upon execution of
this Lease.
2. Operating Cost Share Rent in an amount equal to the Tenant's
Proportionate Share of the Operating Costs for the applicable fiscal
year of the Lease, paid monthly in advance in an estimated amount.
Definitions of Operating Costs and Tenant's Proportionate Share, and the
method for billing and payment of Operating Cost Share Rent are set
forth in Sections 2B, 2C and 2D.
3. Tax Share Rent in an amount equal to the Tenant's
Proportionate Share of the Taxes for the applicable fiscal year of this
Lease, paid to Landlord on or before the later of thirty (30) days prior
to delinquency or ten (10) days after Tenant's receipt from Landlord of
a copy of the applicable tax bill. A definition of Taxes and the method
for billing and payment of Tax Share Rent are set forth in Sections 2B,
2C and 2D.
4. Additional Rent in the amount of all costs, expenses,
liabilities, and amounts which Tenant is required to pay under this
Lease, excluding Base Rent, Operating Cost Share Rent and Tax Share
Rent, but including any interest for late payment of any item of Rent.
4
<PAGE> 11
5. Rent as used in this Lease means Base Rent, Operating Cost
Share Rent, Tax Share Rent and Additional Rent. Tenant's agreement to
pay Rent is an independent covenant, with no right of setoff, deduction
or counterclaim of any kind.
B. Payment of Operating Cost Share Rent and Tax Share Rent.
1. Payment of Estimated Operating Cost Share Rent and Tax Share
Rent. Landlord shall estimate the Operating Costs and Taxes of the
Property by April 1 of each fiscal year, or as soon as reasonably
possible thereafter. Landlord may revise these estimates whenever it
obtains more accurate information, such as the final real estate tax
assessment or tax rate for the Property.
Within ten (10) days after receiving the original or revised estimate
from Landlord, Tenant shall pay Landlord one-twelfth (1/12th) of
Tenant's Proportionate Share of this estimate (excluding Tenant's
Proportionate Share of the Taxes which shall be paid pursuant to Section
2B3 below), multiplied by the number of months that have elapsed in the
applicable fiscal year to the date of such payment including the current
month, minus payments previously made by Tenant for the months elapsed.
On the first day of each month thereafter, Tenant shall pay Landlord
one-twelfth (1/12th) of Tenant's Proportionate Share of this estimate
(excluding Tenant's Proportionate Share of the Taxes which shall be paid
pursuant to Section 2B3 below), until a new estimate becomes applicable.
2. Correction of Operating Cost Share Rent. Landlord shall
deliver to Tenant a report for the previous fiscal year (the "Operating
Cost Report") by May 15 of each year, or as soon as reasonably possible
thereafter, setting forth (a) the actual Operating Costs incurred, (b)
the amount of Operating Cost Share Rent due from Tenant, and (c) the
amount of Operating Cost Share Rent paid by Tenant. Within twenty (20)
days after such delivery, Tenant shall pay to Landlord the amount due
minus the amount paid. If the amount paid exceeds the amount due,
Landlord shall apply the excess to Tenant's payments of Operating Cost
Share Rent next coming due.
3. Current Tax Share Rent. Landlord shall deliver to Tenant an
invoice for the upcoming fiscal year (the "Tax Report") by November 1 of
each year, or as soon as reasonably possible thereafter, setting forth
(a) the actual Taxes, (b) the amount of Tax Share Rent due from Tenant,
and (c) the amount of Tax Share Rent to be paid by Tenant. Tenant shall
pay to Landlord the amount due from Tenant for such Taxes on or before
the later of thirty (30) days prior to delinquency or ten (10) days
after Tenant's receipt from Landlord of a copy of the applicable tax
bill.
C. Definitions.
1. Included Operating Costs. "Project Common Areas" means the
common areas designated in the REA. "Common Areas" means (a) all areas
and facilities outside the Premises and within the exterior boundary
line of the Property that are provided and designated by Landlord from
time to time for the general non-exclusive use of Landlord, Tenant and
other tenants of the Property and their respective employees, suppliers,
5
<PAGE> 12
shippers, customers and invitees, including, without limitation,
exercise room, shower and changing rooms, parking areas, loading and
unloading areas, trash areas, roadways, sidewalks, walkways, parkways,
ramps, driveways, landscaped areas and decorative walls, and (b) Project
Common Areas. "Operating Costs" means any expenses, costs and
disbursements of any kind other than Taxes and capital expenses (except
to the extent expressly permitted herein), paid or incurred by Landlord
in connection with the management, maintenance, operation, insurance,
repair and other related activities in connection with any part of the
Building, Property, Project or Common Areas, as applicable, and of the
personal property, fixtures, machinery, equipment, systems and apparatus
used in connection therewith, including the cost of providing those
services required to be furnished by Landlord under this Lease.
Operating Costs shall also include (x) amounts billed to Landlord under
the REA, (y) the costs of any Included Capital Items (defined below);
provided, that if the cost of any single Included Capital Item shall
exceed $35,000 then such cost shall be amortized by Landlord, together
with an amount equal to interest at ten percent (10%) per annum, over
the estimated useful life of such item and such amortized costs are only
included in Operating Costs for that portion of the useful life of the
Included Capital Item which falls within the Term, and (z) a management
fee equal to one-and-one-half percent (1 1/2%) of Base Rent. Operating
Costs shall also include the reasonable wages and overhead costs of a
building engineer hired by Landlord with respect to the Property;
provided, however, that such engineer helps to repair and maintain the
Building and Property and does not primarily supervise Landlord's repair
and maintenance obligations under this Lease. Landlord shall make such
engineer available to Tenant, at no additional cost to Tenant, to
perform minor repair and maintenance functions to the Premises.
As used herein, the term "Included Capital Items" shall mean
collectively (1) Replacement Capital Items and (2) Permitted Capital
Additions. As used herein, the term "Replacement Capital Items" shall
mean repair and replacement of the improvements in the Property (and all
components thereof) which (a) Landlord has the obligation to maintain
(other than the foundation and structural components of (i) the exterior
walls of the Building, (ii) the roof of the Building and (iii) interior
bearing walls and columns of the Building) and (b) were installed in the
Property at the Commencement Date; without limiting the generality of
the foregoing, Replacement Capital Items shall include (1) the repair of
parking areas (including resurfacing and restriping as needed), (ii)
replacement of roof covering and (iii) repair and replacement of
components of HVAC, electrical, mechanical and plumbing systems. As used
herein, the term "Permitted Capital Additions" shall mean capital
improvements which are intended to (a) reduce Operating Costs or improve
safety or (b) keep the Building, Property, Project or Common Areas, as
applicable, in compliance with Governmental Requirements.
2. Excluded Operating Costs. Operating Costs shall not
include:
(a) costs of improvements or alterations of tenant premises;
(b) costs of capital improvements other than Included Capital
Items;
6
<PAGE> 13
(c) interest and principal payments on mortgages or any other
debt costs, or rental payments on any ground lease of the
Property or Project;
(d) real estate brokers' leasing commissions;
(e) legal fees, space planner fees and advertising expenses
incurred with regard to leasing the Property or portions
thereof;
(f) any cost or expenditure for which Landlord is reimbursed,
by insurance proceeds or otherwise, except by Operating
Cost Share Rent;
(g) the cost of any service furnished to any other tenant of
the Property which Landlord does not make available to
Tenant;
(h) depreciation (except on any Included Capital Items);
(i) franchise or income taxes imposed upon Landlord;
(j) costs of correcting defects in construction of the
Building or Property (as opposed to the cost of normal
repair, maintenance and replacement expected with the
construction materials and equipment installed in the
Building or Property in light of their specifications);
(k) legal and auditing fees which are for the benefit of
Landlord such as collecting delinquent rents, preparing
tax returns and other financial statements, and audits
other than those incurred in connection with the
preparation of reports required pursuant to Section 2B
above;
(l) the wages of any employee for services not related
directly to the management, maintenance, operation and
repair of the Property and wages and expenses or for
management in excess of the management fee provided in
2.C.1;
(m) fines, penalties and interest;
(n) attorney's fees and other costs and expenses incurred in
connection with negotiations or disputes with prospective
tenants, tenants or other occupants of the Property;
(o) damage and repairs necessitated by the negligence or
willful misconduct of Landlord or Landlord's employees,
contractors or agents;
(p) personal property taxes payable by any other occupant of
the Property;
(q) costs incurred due to a violation by Landlord or any
tenant of the terms and conditions of any lease of space
in the Building or Property;
7
<PAGE> 14
(r) rentals and other related expenses (other than taxes and
insurance) incurred in leasing equipment ordinarily
considered to be of a capital nature, except equipment
that is presently leased for use in, or providing services
to the Property, or that is used in providing security,
operational, and maintenance services, and equipment, the
cost of which would be included as an Included Capital
Item;
(s) costs arising from Landlord's charitable or political
contributions or from costs or fees associated with
Landlord's membership in a trade association;
(t) maintenance, improvement, replacement or repair of the (a)
exterior or interior load-bearing walls (except for the
surfaces thereof), (b) foundations, and (c) roof structure
of any building of the Property;
(u) wages, fees and administrative costs for the management of
the Property in excess of one-and-one-half percent (1
1/2%) of Base Rent; and
(v) the costs of electricity used by Tenant in the Premises
which is separately metered to, and paid by, Tenant.
Landlord agrees that (i) Landlord shall make no profit from Landlord's
collection of Operating Cost; and (ii) Landlord shall reduce the amount of
Operating Costs by any refund Landlord receives in connection with any costs or
expenditures previously included in Operating Costs, less any cost incurred by
Landlord by obtaining any such refund.
3. Taxes. "Taxes" means any and all taxes, assessments and
charges of any kind, general or special, ordinary or extraordinary,
levied against the Property which Landlord shall pay or become obligated
to pay in connection with the ownership, leasing, renting, management,
use, occupancy, control or operation of the Property or of the personal
property, fixtures, machinery, equipment, systems and apparatus used in
connection therewith and for the benefit of the tenants thereof. Taxes
shall include real estate taxes, personal property taxes, sewer rents,
water rents, special or general assessments, transit taxes, ad valorem
taxes, and any tax levied on the rents hereunder or the interest of
Landlord under this Lease (the "Rent Tax"). Taxes shall also include all
fees and other costs and expenses paid by Landlord in reviewing any tax
and in seeking a refund or reduction of any Taxes to the extent that, if
successful, Tenant would be benefited thereby, whether or not the
Landlord is ultimately successful.
If, by applicable law, any taxes or assessments may be paid in
installments at the option of the taxpayer, then whether or not Landlord
elects to pay taxes and assessments in such installments, Tenant's
liability for such taxes and assessments shall be computed as if such
election had been made, and only the installments thereof which would
have become due during the Term shall be included in Tenant's tax
obligations. Any refund or other adjustment to any Taxes by the taxing
authority, shall apply during the year in which the adjustment is made.
If a reduction in Taxes is obtained for any year of the Lease Term
during which Tenant paid Taxes, then Operating Costs for such year shall
be
8
<PAGE> 15
retroactively adjusted and Landlord shall provide Tenant with a credit
against Tenant's next due obligations for Base Rent and Operating Costs
or, if none, refund such amount to Tenant within thirty (30) days based
on such adjustment. Landlord agrees to contest increases in the tax rate
and assessed valuation of the Building or Property, which affect the
general real estate tax component of Taxes or any other increase in
Taxes customarily protested by prudent owners of commercial office
buildings in the City of San Diego in a manner appropriate for such an
owner.
Taxes shall not include any net income (except Rent Tax), capital,
stock, succession, transfer, franchise, gift, estate or inheritance tax,
except to the extent that such tax shall be imposed in lieu of any
portion of Taxes. In addition to the foregoing exclusions, Taxes shall
not include: (i) any item to the extent otherwise included in Operating
Costs; (ii) any environmental assessments, charges or liens arising in
connection with the remediation of Hazardous Materials from the
Property, the causation of which arose prior to the Commencement Date of
this Lease, or to the extent caused by Landlord, its agents, employees
or contractors or any tenant of the Property (other than Tenant or its
sublessees or assignees); (iii) costs or fees payable to public
authorities in connection with any future construction, renovation
and/or improvements to the Property other than the Work or Improvements
to the Premises made by or for Tenant, including fees for transit,
housing, schools, open space, child care, arts programs, traffic
mitigation measures, environmental impact reports, traffic studies, and
transportation system management plans; (iv) reserves for future Taxes;
or (v) any personal property taxes attributable to sculptures, paintings
or other objects of art (except for objects of art installed in the
Common Areas pursuant to requirements of public authority).
4. Lease Year. "Lease Year" means each consecutive twelve-month
period beginning with the Commencement Date, except that if the
Commencement Date is not the first day of a calendar month, then the
first Lease Year shall be the period from the Commencement Date through
the final day of the twelve months after the first day of the following
month, and each subsequent Lease Year shall be the twelve months
following the prior Lease Year.
5. Fiscal Year. "Fiscal Year" means the calendar year, except
that the first fiscal year and the last fiscal year of the Term may be a
partial calendar year.
D. Computation of Base Rent and Rent Adjustments.
1. Prorations. If this Lease begins on a day other than the first
day of a month, the Base Rent, Operating Cost Share Rent and Tax Share
Rent shall be prorated for such partial month based on the actual number
of days in such month. If this Lease begins on a day other than the
first day, or ends on a day other than the last day, of the fiscal year,
Operating Cost Share Rent and Tax Share Rent shall be prorated for the
applicable fiscal year. If any Operating Cost paid in one fiscal year
relates to more than one fiscal year, Landlord may proportionately
allocate such Operating Cost among the related fiscal years.
9
<PAGE> 16
2. Default Interest. Any sum due from Tenant to Landlord not paid
when due shall bear interest from the date due until paid at the lesser
of ten percent (10%) per annum or the maximum rate permitted by law.
3. Rent Adjustments. If the City of San Diego grants any tax
break or conveys some other benefit due to Tenant's occupancy of the
Premises (collectively, a "Benefit") and such Benefit accrues all or in
part to Landlord, Landlord shall credit such amount to Tenant against
Tenant's Rent obligation under this Lease at the time or times Landlord
receives such Benefit.
4. Books and Records. Landlord shall maintain books and records
reflecting the Operating Costs and Taxes in accordance with generally
accepted accounting practices and sound management practices. Tenant and
its certified public accountant shall have the right to inspect
Landlord's records at Landlord's office upon at least seventy-two (72)
hours' prior notice during normal business hours during the ninety (90)
days following the respective delivery of the Operating Cost Report or
the Tax Report. The results of any such inspection shall be kept
strictly confidential by Tenant and its agents, and Tenant and its
certified public accountant must agree, in their contract for such
services, to such confidentiality restrictions and shall specifically
agree that the results shall not be made available to any other tenant
of the Building. Unless Tenant sends to Landlord any written exception
to either such report within ninety (90) days' following the date Tenant
completes its review of Landlord's records, such report shall be deemed
final and accepted by Tenant. Tenant shall pay the amount shown on both
reports in the manner prescribed in this Lease, whether or not Tenant
takes any such written exception, without any prejudice to such
exception. If Tenant makes a timely exception, Landlord shall cause its
independent certified public accountant to issue a final and conclusive
resolution of Tenant's exception. If Tenant's and Landlord's accountants
cannot agree upon a mutually-agreeable resolution to Tenant's exception,
then such accountant shall jointly determine a mutually-acceptable
accountant to resolve such disputed exception. Tenant shall pay the cost
of such certification unless Landlord's original determination of annual
Operating Costs or Taxes overstated the amounts thereof by more than
three percent (3%), in which case Landlord shall pay the cost of such
inspection and certification.
5. Miscellaneous. So long as Tenant is in default of any
obligation under this Lease, Tenant shall not be entitled to any refund
of any amount from Landlord. If this Lease is terminated for any reason
prior to the annual determination of Operating Cost Share Rent or Tax
Share Rent, either party shall pay the full amount due to the other
within fifteen (15) days after Landlord's notice to Tenant of the amount
when it is determined. Landlord may commingle any payments made with
respect to Operating Cost Share Rent or Tax Share Rent, without payment
of interest.
3. PREPARATION AND CONDITION OF PREMISES; POSSESSION AND SURRENDER OF
PREMISES.
A. Condition of Premises. Except to the extent of the Tenant
Improvements item on the Schedule, Landlord is leasing the Premises to Tenant
absolutely "as is" (subject to
10
<PAGE> 17
Landlord's warranty obligations set forth below), without any obligation to
alter, remodel, improve, repair or decorate any part of the Premises. Landlord
shall cause the Premises to be completed in accordance with the Tenant
Improvement Agreement attached as Exhibit C. Landlord shall deliver the Premises
to Tenant on the Commencement Date clean and free of debris with the
installation of the Tenant Improvements completed in accordance with the terms
of the Tenant Improvement Agreement attached as Exhibit C. Landlord warrants to
tenant that the roof, plumbing, fire sprinkler system, lighting, heating,
ventilation and air conditioning systems and electrical systems in the Premises,
shall be in good operating condition on the Commencement Date and during the
initial twelve (12) months of the Term. In the event of a non-compliance with
such warranty, Landlord shall, except as otherwise provided in this Lease,
promptly after receipt of written notice from Tenant setting forth the nature
and extent of such non-compliance, rectify same at Landlord's cost and expense.
Further, in connection with the construction of the Building structure and the
Tenant Improvements pursuant to the Tenant Improvement Agreement, Landlord shall
obtain customary warranties and guaranties from the contractor(s) performing
such work and/or the manufacturers of equipment installed therein, but shall be
under no obligation to incur additional expense in order to obtain or extend
such warranties. If Tenant is required to make repairs to any component of the
Premises or any of its systems not covered by the Landlord's warranty contained
in this Section 3A but for which Landlord has obtained a contractor's or
manufacturer's warranty, then Landlord shall, upon request by Tenant, use its
good faith efforts to pursue its rights under any such warranties for the
benefit of Tenant. Tenant's acceptance of the Premises shall be subject to the
foregoing and to the provisions of this Lease regarding delivery of possession
and completion by Landlord of all punch-list items. Tenant may obtain, at
Tenant's sole cost and expense, extended warranties on any Building systems;
Landlord shall (i) notify Tenant prior to its purchase of any Building system
for which Tenant may obtain an extended warranty in order to give Tenant ample
opportunity to obtain such a warranty and (ii) cooperate with and assist Tenant
to obtain any such warranties.
B. Measurement of Premises. Tenant understands that the Premises is to
contain approximately seventy-five thousand (75,000) rentable square feet (as
set forth in Item 6 of the Schedule). Upon completion of the Tenant
Improvements, Landlord shall measure the Premises using the Standard Method for
Measuring Floor Area in Office Buildings (BOMA), except that the "Construction
Area" (as defined by BOMA) shall be included as gross rentable area (the
"Standard Measure"), and if such measurement indicates that either the rentable
square footage of the Premises and/or the Building differs from that set forth
in this Lease, then Landlord shall so notify Tenant and the and Basic Rent (as
shown in Items 8 and 15 of the Schedule) and all other items which are based
upon the square footage of the Premises and/or the Building shall be promptly
adjusted in proportion to the change in square footage. Tenant reserves the
right to have its space planner or architect measure the Premises upon
completion to confirm that the measurement provided by Landlord is accurate and
conforms to the Standard Measure. Any discrepancy shall be promptly resolved by
the parties through good faith negotiations or, if such negotiations fail to
resolve the issue, arbitration pursuant to Section 29 hereof. Within five (5)
business days following the Commencement Date, the parties shall memorialize the
adjustments by executing the Commencement Date Confirmation substantially in the
form of Exhibit E.
C. Tenant's Possession. Except as set forth in Section 3A above,
Tenant's taking possession of any portion of the Premises shall be conclusive
evidence that the Premises were in
11
<PAGE> 18
good order, repair and condition, with the exception of any latent defects in
the Building, which shall be Landlord's responsibility. If Landlord authorizes
Tenant to take possession of any part of the Premises prior to the Commencement
Date for purposes of doing business, all terms of this Lease shall apply to such
pre-Term possession, including Base Rent at the rate set forth for the First
Lease Year in the Schedule prorated for any partial month.
D. Surrender. At the termination of this Lease, or Tenant's right to
possession, Tenant shall return the Premises to Landlord in broom-clean, safe,
neat and sanitary condition. To the extent Tenant fails to perform either
obligation, Landlord may, but need not, restore the Premises to such condition
and Tenant shall pay the cost thereof.
4. PROJECT SERVICES. Landlord shall furnish services as follows (the
cost of each of which shall be included in Operating Costs except to the extent
that such service is separately metered to, and paid by, Tenant):
A. Heating and Air Conditioning. Landlord shall furnish heating and air
conditioning to provide a comfortable temperature, in Landlord's reasonable
judgment, for normal business operations. Tenant shall have the ability to
control after hours heating, and air conditioning of the Premises; provided,
however, Tenant shall pay the actual cost of such after-hours heating and air
conditioning.
B. Elevators. Landlord shall provide the services of one (1)
nonexclusive freight elevator and two (2) nonexclusive passenger elevators in
the Building at all times during the Term.
C. Electricity. Landlord shall provide sufficient electricity for
Tenant's intended use of the Premises. Tenant's electricity usage (except for
electricity used for heating and air conditioning other than heating and air
conditioning unit(s) installed by Tenant which serve only the Premises) shall be
separately metered.
D. Water. Landlord shall furnish hot and cold tap water for use in
Tenant's business operations, drinking and toilet purposes.
E. Exercise Room and Shower. Landlord shall furnish and maintain (a) an
exercise room not more than 1200 square feet in area, as reasonably agreed upon
by Landlord and Tenant, on the first floor of the Building and the equipment
therein and (b) two (2) men's and two (2) women's showers and changing rooms on
the first floor of the Building.
F. Interruption of Services. If any of the Building or Property
equipment or machinery ceases to function properly for any cause Landlord shall
use reasonable diligence to repair the same promptly. Landlord's inability to
furnish, to any extent, the Property services set forth in this Section 4, or
any cessation thereof resulting from any causes, other than Landlord's gross
negligence or willful failure to provide such services, including any entry for
repairs pursuant to this Lease, shall not render Landlord liable for damages to
either person or property or for interruption or loss to Tenant's business, nor
be construed as an eviction of Tenant, nor work an abatement of any portion of
Rent, nor relieve Tenant from fulfillment of any covenant or agreement hereof.
However, in the event that an interruption of the Property services set forth in
this Section 4 causes the Premises to be untenantable for a period of at least
five (5)
12
<PAGE> 19
consecutive business days, monthly Rent shall be abated proportionately and
retroactively, and it shall be Landlord's responsibility to carry any insurance
it requires to cover any such Rent abatement.
G. Parking. During the Term, Tenant and its employees shall be entitled
to use within the Project's parking areas at no additional expense to Tenant, it
being hereby agreed that Tenant's payment of Base Rent, Operating Cost Share
Rent and Tax Share Rent shall satisfy all parking rent obligations. Tenant shall
comply with the parking requirements of the REA in its use of the Project's
parking areas.
5. ALTERATIONS, MAINTENANCE AND REPAIRS.
A. Landlord's Consent and Conditions. After the Commencement Date,
Tenant shall not make any improvements or alterations to the Premises (the
"Work") without in each instance submitting plans and specifications for the
Work to Landlord. For any alterations or improvements (or series of related
alterations or improvements) costing more than $50,000 in any instance, Tenant
shall also obtain Landlord's prior written consent, which consent shall not be
unreasonably withheld, conditioned or delayed. Landlord will be deemed to be
acting reasonably in withholding its consent for any Work which (a) materially
increases the cost of maintaining or reduces the value or utility of the base
structural components or systems of the Building, (b) impairs the use or
occupancy of any other tenant's premises, (c) is visible from outside the
Project (other than Tenant's signage), or (d) reduces the value or utility of
the Premises all as determined by Landlord in its reasonable and good faith
discretion. Tenant shall reimburse Landlord for actual and reasonable costs
incurred for review of the plans and all other items submitted by Tenant. Tenant
shall pay for the cost of all Work.
The following requirements shall apply to all Work:
1. Prior to commencement, Tenant shall furnish to Landlord
building permits, certificates of insurance satisfactory to Landlord
(including, without limitation, certificates evidencing the insurance
Tenant, its contractors and subcontractors are required to maintain
under Section 8C), and, at Landlord's request, security for payment of
all costs.
2. Tenant shall perform all Work so as to maintain peace and
harmony among other contractors serving the Project and shall avoid
interference with other work to be performed or services to be rendered
in the Project. Tenant shall use contractors reasonably acceptable to
Landlord to perform the Work.
3. The Work shall be performed in a good and workmanlike manner,
meeting the standard for construction and quality of materials in the
Building, and shall comply with all insurance requirements and all
applicable governmental laws, ordinances and regulations ("Governmental
Requirements").
4. Tenant shall perform all Work so as to minimize or prevent
disruption to other tenants, and Tenant shall comply with all reasonable
requests of Landlord in response to complaints from other tenants.
13
<PAGE> 20
5. Tenant shall perform all Work in compliance with Landlord's
"Policies, Rules and Procedures for Construction Projects" in effect at
the time the Work is performed; provided that such policies, rules and
procedures shall not unreasonably increase the cost of the work.
6. Landlord may, in its sole discretion, supervise all Work;
however, Tenant shall not pay Landlord any fee for such supervision.
7. Upon completion, Tenant shall furnish Landlord with
contractor's affidavits and full and final statutory waivers of liens,
as-built plans and specifications, and receipted bills covering all
labor and materials, and all other close-out documentation reasonably
required in Landlord's "Policies, Rules and Procedures for Construction
Projects".
B. Maintenance and Repairs. Tenant shall, at its sole expense, keep the
Premises and every part thereof in good order, condition and repair (loss or
damage caused by the elements, ordinary wear and tear, and fire and other
casualty excepted) including, without limiting the generality of the foregoing,
all equipment or facilities specifically serving the Premises, such as plumbing,
heating, air conditioning, ventilating, electrical, lighting facilities, fire
hose connections if within the Premises, fixtures, interior walls, interior
surfaces of exterior walls, ceilings, floors, windows, doors, plate glass, all
Tenant Improvements installed pursuant to the Tenant Improvement Agreement and
all improvements installed by Tenant in the Premises after the Commencement
Date. Landlord shall maintain, at Landlord's sole cost which shall not be
included in Operating Costs, the foundation and structural components of the
Building including (1) the roof of the Building, (2) exterior walls of the
Building and (3) interior bearing walls and columns of the Building. Landlord
shall also maintain, and the cost thereof shall be an element of Operating
Costs, (1) the Project Common Areas to the extent required under the REA, (2)
the Common Areas located within the Property, including exercise room, showers
and changing rooms, sidewalks, walkways, driveways, parking areas, landscaped
areas, irrigation facilities, loading docks and interior and exterior lighting
fixtures, (3) roof covering of the Building and (4) systems installed in the
Building which service both the Premises and other portions of the Building
including, without limitation, electrical, mechanical, plumbing, heating,
ventilating, air conditioning, elevator, fire/life safety systems. Tenant shall,
at Tenant's sole cost, be responsible for interior janitorial service of the
Premises. Landlord shall maintain a common use trash disposal area within the
Property and the cost of providing trash removal shall be an element of
Operating Costs. Tenant shall, at Tenant's cost, be responsible for trash and/or
waste removal which requires special handling such as hazardous and/or
infectious waste. If Tenant fails to perform Tenant's obligations under this
paragraph, Landlord shall have the right, but not the obligation, to perform
such obligations and the reasonable costs incurred by Landlord in connection
therewith shall be Additional Rent payable by Tenant upon receipt of written
demand by Landlord.
If any of the items for which Landlord has maintenance and repair
responsibility break, fail or are damaged, Tenant shall promptly notify
Landlord, and Landlord shall repair such item(s). Landlord may also at any
reasonable time make any repairs or alterations which Landlord reasonably deems
necessary for the safety or protection of the Property, or which Landlord is
required to make by any court or pursuant to any Governmental Requirement. The
14
<PAGE> 21
cost of any repairs made by Landlord on account of Tenant's default, or on
account of the misuse or neglect by Tenant or its invitees, contractors or
agents anywhere in the Project, shall become Additional Rent payable by Tenant
on demand. If Landlord fails to perform any of its repair and maintenance
obligations under this Section 5B or otherwise as required in this Lease, and
such failure materially affects Tenant's ability to use or occupy the Premises
for the purposes permitted herein, Tenant shall have the right, but not the
obligation, to perform such repairs and/or maintenance if such failure continues
for more than fifteen (15) days after written notice from Tenant; provided,
however, that if the nature of the repairs and/or maintenance to be completed by
Landlord is such that more than fifteen (15) days are required to complete such
repairs and/or maintenance, Landlord shall have such additional time as is
reasonably necessary to complete such repairs and/or maintenance so long as
Landlord takes appropriate action to commence such repairs and/or maintenance
within such fifteen (15) day period and thereafter diligently pursues such
repairs and/or maintenance to completion. In such event, Landlord shall
reimburse Tenant for the reasonable costs incurred by Tenant to complete such
repairs and/or maintenance within thirty (30) days after receipt of Tenant's
written demand therefor, together with copies of the paid invoices evidencing
the costs incurred by Tenant. Any repairs and/or maintenance permitted herein
shall be performed in a good workmanlike manner by licensed contractors. If
Landlord objects to the repairs and/or maintenance performed or the expenses
incurred by Tenant in performing such work, Landlord shall deliver a written
notice of Landlord's objection to Tenant within thirty (30) days after
Landlord's receipt of Tenant's invoice evidencing the expenses incurred by
Tenant. Landlord's notice shall set forth in reasonable detail Landlord's
reasons for its claim that such repairs and/or maintenance were not required or
were not Landlord's obligation in the terms of this lease and/or the reasons for
Landlord's dispute of the expenses incurred by Tenant in performing such work.
If Landlord and Tenant fail to resolve any such dispute within said thirty (30)
day period, after Landlord has notified Tenant of Landlord's objections, the
matter shall be resolved by binding arbitration in accordance with the
provisions of Section 29 of this Lease.
C. No Liens. Tenant has no authority to cause or permit any lien or
encumbrance of any kind to affect Landlord's (or Landlord's Lender's) interest
in the Property; any such lien or encumbrance shall attach to Tenant's interest
only. If any mechanic's lien shall be filed or claim of lien made for work or
materials furnished to Tenant, then Tenant shall at its expense within ten (10)
business days thereafter either discharge or contest the lien or claim. If
Tenant contests the lien or claim, then Tenant shall (i) within such ten (10)
business day period, provide Landlord adequate security for the lien or claim,
(ii) contest the lien or claim in good faith by appropriate proceedings that
operate to stay its enforcement, and (iii) pay promptly any final adverse
judgment entered in any such proceeding. If Tenant does not comply with these
requirements, Landlord may discharge the lien or claim, and the amount paid, as
well as attorney's fees and other expenses incurred by Landlord, shall become
Additional Rent payable by Tenant on demand. Nothing contained in this Lease
shall constitute any consent by Landlord to subject Landlord's estate to
liability under any mechanics' or other lien law. Tenant shall give Landlord
adequate opportunity, and Landlord shall have the right at all times, to post
such notices of nonresponsibility as may be allowed under California law.
Landlord acknowledges Tenant's right to finance and to secure under the
Uniform Commercial Code, inventory, furnishings, furniture, equipment,
machinery, leasehold improvements and other personal property located in or at
the Premises, and Landlord agrees to
15
<PAGE> 22
execute waiver forms releasing liens in favor of any purchase money seller,
lessor or lender who has financed or may finance in the future such items;
provided, however, Tenant shall have no right to impose a lien upon (and
Landlord shall have no obligation to provide any waiver with respect to) the
Initial Improvements (defined below). Without limiting the effectiveness of the
foregoing, provided that no default shall have occurred and be continuing,
Landlord shall, upon the request of Tenant, and at the Tenant's sole cost and
expense, execute and deliver any instruments reasonably necessary or appropriate
to confirm any such grant, release, dedication, transfer, annexation or
amendment to any person or entity permitted under this paragraph including
landlord waivers substantially in the form of Exhibit H attached hereto with
respect to any of the foregoing.
D. Ownership of Improvements. All Tenant Improvements, as defined in
Exhibit C, financed by Landlord's Contribution plus the Tenant Improvements
financed and/or paid for by Tenant up to a maximum of $1,500,000 (together, the
"Initial Improvements") (i) shall become Landlord's property upon installation
without compensation to Tenant, unless Landlord consents otherwise in writing,
and (ii) shall be surrendered to Landlord with the Premises at the termination
of the Lease or Tenant's right to possession. To the extent that the total cost
of the Initial Improvements exceeds the amount of Landlord's Contribution plus
the $1,500,000 to be paid by Tenant, then, within 45 days following the
Commencement Date, Tenant shall submit to Landlord a list of leasehold
improvements as well as equipment and machinery, to the extent relevant, which
(1) have an installation cost equal to or less than the amount of the excess
cost for the Tenant Improvements over Landlord's Contribution and Tenant's
$1,500,000 payment, (2) could be removed from the Premises upon termination or
expiration of the Lease without material damage to the Building or the Premises
or otherwise materially affect the operation of systems installed in the
Building or Premises and (3) Tenant desires to retain ownership of and have the
right to remove upon termination or expiration of the Lease. Within 30 days
following Landlord's receipt of Tenant's list, Landlord shall approve the list
unless Landlord has a reasonable and material objection thereto. If Landlord and
Tenant are unable to resolve Landlord's objection(s), the matter shall be
resolved pursuant to arbitration as provided under Section 29 of this Lease.
All improvements to the Premises made by or on behalf of Tenant at
Tenant's sole cost and expense (except for the Initial Improvements) whether
pursuant to the Tenant Improvements Agreement attached hereto as Exhibit C or
Section 5A hereto (the "Subsequent Improvements") shall be and remain Tenant's
property. Tenant shall have the right to remove the Subsequent Improvements in
accordance with Section 5E below in which case Tenant shall restore the Premises
to the condition required for surrender under Section 3D hereto upon the
expiration or earlier termination of the Term.
E. Removal at Termination. Upon the termination of this Lease or
Tenant's right of possession, Tenant shall have the right to remove from the
Property the Subsequent Improvements and other personal property of Tenant. If
Tenant does not timely remove such property, then Tenant shall be conclusively
presumed to have, at Landlord's election and to the extent applicable (i)
conveyed such property to Landlord without compensation or (ii) abandoned such
property, and Landlord may dispose of or store any part thereof in any manner at
Tenant's sole cost, without waiving Landlord's right to claim from Tenant all
expenses arising out of Tenant's failure to remove the property, and without
liability to Tenant or any other person.
16
<PAGE> 23
Landlord shall have no duty to be a bailee of any such personal property. If
Landlord elects abandonment, Tenant shall pay to Landlord, upon demand, any
expenses incurred for disposition. Tenant expressly releases Landlord of and
from any and all claims and liability for damage to or destruction or loss of
property left by Tenant upon the Premises at the expiration or other termination
of this Lease and, to the extent permitted by then applicable law, Tenant shall
protect, indemnify, defend and hold Landlord harmless from and against any and
all claims and liability with respect thereto.
F. Landlord's Work. Landlord shall have the right at any time to change
the arrangement and location of all entrances, sidewalks, driveways, parking
areas, and other public parts of the Project, provided that such changes do not
materially impair Tenant's access to or use or occupancy of the Building, and,
upon giving Tenant reasonable notice thereof, to change any name, number or
designation by which the Premises, the Building or the Property is commonly
known, provided that Landlord shall reimburse Tenant's reasonable out-of-pocket
costs associated with such change including printing and administrative costs.
6. USE OF PREMISES. Tenant shall use the Premises only for the permitted
use identified in this Lease. Tenant shall not allow any change in use of the
Premises which will have a material adverse effect on the cost or coverage of
Landlord's insurance on the Property. Tenant shall not allow any inflammable or
explosive liquids or materials to be kept on the Premises except for those
liquids and materials used in the normal course of Tenant's business, which
shall be stored and used in accordance with applicable laws and insurance
requirements. Tenant shall not allow any change in use of the Premises which
would cause the value or utility of any part of the Premises to diminish or
would interfere with any other Tenant or with the operation of the Property by
Landlord. Tenant shall not cause or permit any nuisance or waste upon the
Premises, or allow any offensive noise or odor to emanate from the Premises or
in any way obstruct or interfere with the rights of other tenants or occupants
of the Project.
Tenant acknowledges that the Americans With Disabilities Act of 1990 (as
amended and as supplemented by further laws from time to time, the "ADA")
imposes certain requirements upon the owners, lessees and operators of
commercial facilities and places of public accommodation, including, without
limitation, prohibitions on discrimination against any individual on the basis
of disability. Notwithstanding any other provision of this Lease, Landlord
agrees at Landlord's expense, to take all proper action to cause the Building
structure and the Common Areas to comply with the ADA requirements and Tenant
agrees, at Tenant's expense, to take all proper and necessary action to cause
the Premises, any repairs, replacements, alterations and improvements thereto to
be maintained, used and occupied in compliance with the ADA requirements, to the
extent that those requirements are based upon the Tenant's occupancy,
alteration, improvement, use of the Premises and, further, to otherwise assume
all responsibility to ensure the Premises' continued compliance with all
provisions of the ADA throughout the Term. Tenant shall, at its expense, make
any alterations or modifications to its improvements to the Building, in order
to bring Tenant's use and occupancy of the Premises into compliance with the
ADA. Tenant shall pay, as Additional Rent, Tenant's Proportionate Share of
expenses incurred by Landlord in bringing the Common Areas of the Project into
compliance with provisions of the ADA to the extent any such compliance is
required by changes in the ADA after the Commencement Date. The Premises shall
not be used as a "place of public accommodation" under the ADA or similar laws,
regulations, statutes and/or ordinances;
17
<PAGE> 24
provided, that if any governmental authority shall deem the Premises to be a
"place of public accommodation" as a result of Tenant's use, Tenant shall either
modify its use to cause such authority to rescind its designation or be
responsible for any alterations, structural or otherwise, required to be made to
the Property or the Premises under such laws.
7. GOVERNMENTAL REQUIREMENTS AND PROJECT RULES. Tenant shall comply with
all Governmental Requirements applying to its use of the Premises. Tenant shall
also comply with all reasonable and non-discriminatory rules established for the
Project, including, without limitation, the parking area, from time to time
either by Landlord or pursuant to the REA, of which Tenant receives notice from
Landlord. The present rules and regulations are contained in Exhibit B. Failure
by another tenant to comply with the rules or failure by Landlord to enforce
them shall not relieve Tenant of its obligation to comply with the rules or make
Landlord responsible to Tenant in any way, provided that Landlord agrees to use
commercially reasonable efforts to enforce such rules to the extent that
Tenant's use or occupancy of the Premises is affected by such failure. Landlord
shall use reasonable efforts to apply the rules and regulations uniformly with
respect to Tenant and tenants in the Building under leases containing rules and
regulations similar to this Lease.
8. WAIVER OF CLAIMS; INDEMNIFICATION; INSURANCE.
A. Waiver of Claims. To the extent permitted by law, Tenant waives any
claims it may have against Landlord or its officers, directors, employees or
agents for business interruption or damage to property sustained by Tenant as
the result of any act or omission of Landlord, other than Landlord's gross
negligence or willful misconduct.
To the extent permitted by law, Landlord waives any claims it may have
against Tenant or its officers, directors, employees or agents for loss of rents
or damage to property sustained by Landlord as the result of any act or omission
of Tenant, other than Tenant's gross negligence or willful misconduct.
B. Indemnification. Tenant shall indemnify, defend and hold harmless
Landlord and its officers, directors, employees and agents against any claim by
any third party for injury to any person or damage to or loss of any property
occurring in the Property and arising from any act or omission or negligence of
Tenant or any of Tenant's employees or agents. Tenant's obligations under this
section shall survive the termination of this Lease.
Landlord shall indemnify, defend and hold harmless Tenant and its
officers, directors, employees and agents against any claim by any third party
for injury to any person or damage to or loss of any property occurring in the
Property and arising from any act or omission or negligence of Landlord or any
of Landlord's employees or agents. Landlord's obligations under this section
shall survive the termination of this Lease.
C. Tenant's Insurance. Tenant shall maintain insurance as follows, with
such other terms, coverages and insurers, as Landlord shall reasonably require
from time to time:
1. Commercial General Liability Insurance, with (a) Contractual
Liability including the indemnification provisions contained in this
Lease, (b) a severability of interest endorsement, (c) limits of not
less than One Million Dollars ($1,000,000)
18
<PAGE> 25
combined single limit per occurrence and not less than Two Million
Dollars ($2,000,000) in the aggregate for bodily injury, sickness or
death, and property damage, and umbrella coverage of not less than Five
Million Dollars ($5,000,000). Not more frequently than once every six
years during the term of this Lease, the limits of liability of the
policy of commercial general liability insurance shall be increased to
such amounts as Landlord's insurer or lender may reasonably require,
consistent with customary limits then being required of comparable
tenants in San Diego County.
2. Property Insurance against "All Risks" of physical loss
covering the replacement cost of all of the Tenant Improvements and all
of Tenant's improvements, fixtures and personal property in the
Premises;
3. Workers' compensation or similar insurance in form and amounts
required by law, and Employer's Liability with not less than the
following limits:
<TABLE>
<S> <C>
Each Accident $500,000
Disease--Policy Limit $500,000
Disease--Each Employee $500,000
</TABLE>
Tenant's insurance shall be primary and not contributory to that carried
by Landlord, its agents, or mortgagee. Landlord, and if any, Landlord's building
manager or agent and ground lessor shall be named as additional insureds as
respects to insurance required of the Tenant in Section 8C(1). The company or
companies writing any insurance which Tenant is required to maintain under this
Lease, as well as the form of such insurance, shall at all times be subject to
Landlord's reasonable approval, and any such company shall be authorized to do
business in the state in which the Project is located. Such insurance companies
shall have a A.M. Best rating of A- VI or better. Tenant's insurance policy
under paragraph 8C(1) may be covered by a "blanket policy" of insurance.
Tenant shall cause any contractor of Tenant performing work on the
Premises to maintain insurance as follows, with such other terms, coverages and
insurers, as Landlord shall reasonably require from time to time:
(1) Commercial General Liability Insurance, including
contractor's liability coverage, contractual liability coverage,
completed operations coverage, broad form property damage endorsement,
and contractor's protective liability coverage, to afford protection
with limits, for each occurrence, of not less than One Million Dollars
($1,000,000) with respect to personal injury, death or property damage.
(2) Workers' compensation or similar insurance in form and
amounts required by law, and Employer's Liability with not less than the
following limits:
<TABLE>
<S> <C>
Each Accident $500,000
Disease--Policy Limit $500,000
Disease--Each Employee $500,000
</TABLE>
Tenant's contractor's insurance shall be primary and not contributory to
that carried by Tenant, Landlord, their agents or mortgagees. Tenant and
Landlord, and if any, Landlord's
19
<PAGE> 26
building manager or agent, mortgagee or ground lessor shall be named as
additional insured on Tenant's contractor's insurance policies.
D. Insurance Certificates. Tenant shall deliver to Landlord certificates
evidencing all required insurance no later than five (5) days prior to the
Commencement Date and each renewal date. Each certificate will provide for
thirty (30) days prior written notice of cancellation to Landlord and Tenant.
E. Landlord's Insurance. Landlord shall, as an item of Operating Cost,
maintain "All-Risk" property insurance at replacement cost, including loss of
rents, on the Building, and Commercial General Liability insurance policies
covering the Common Area of the Property, each with such terms, coverages and
conditions as are normally carried by reasonably prudent owners of properties
similar to the Property, including, without limitation, reasonable deductibles
as are maintained by such owners (which, except with respect to earthquake
coverage shall not exceed 10% of the replacement value of the Building).
Landlord may, at Landlord's option or if required by Landlord's lender, as an
item of Operating Cost maintain earthquake insurance. The premiums for such
earthquake insurance shall not exceed the premium rate, as adjusted from time to
time, of the California Earthquake Authority as applicable to the Project, and
the deductible amount of such insurance shall be equal to the amount typically
held by the owners of similar commercial space in the University Towne Centre
area. In the event any earthquake damage occurs resulting in Tenant liability
for the deductible in excess of $10,000, Tenant's payment of such deductible
shall be amortized over the useful life of the repair or replacement and shall
be payable in monthly installments for the portion of the useful life which
falls within the Lease Term. Notwithstanding the foregoing, Tenant shall not be
liable for any earthquake insurance deductible in excess of $150,000. As an item
of Operating Costs, Landlord shall also maintain (or cause to be maintained) the
insurance required under the REA.
Without affecting any other rights or remedies, Landlord and Tenant
("Waiving Party") each hereby release and relieve the other, and waive their
entire right to recover damages (whether in contract or in tort) against the
other, for loss of or damage to the Waiving Party's property arising out of or
incident the perils required to be insured against under this Section 8. The
effect of such releases and waivers of the right to recover damages shall be
limited by the amount of insurance carried or required, or by any deductibles
applicable thereto. Landlord and Tenant agree to have their respective insurance
companies issuing insurance pursuant to this Lease, waive any right to
subrogation that such companies may have against Landlord or Tenant, as the case
may be, so long as the insurance is not invalidated thereby.
Landlord shall cause any contractor of Landlord performing work on the
Premises to maintain insurance as follows, with such other terms, coverages and
insurers, as Landlord shall reasonably require from time to time:
(1) Commercial General Liability Insurance, including
contractor's liability coverage, contractual liability coverage,
completed operations coverage, broad form property damage endorsement,
and contractor's protective liability coverage, to afford protection
with limits, for each occurrence, of not less than One Million Dollars
($1,000,000) with respect to personal injury, death or property damage.
20
<PAGE> 27
(2) Workers' compensation or similar insurance in form and
amounts required by law, and Employer's Liability with not less than the
following limits:
<TABLE>
<S> <C>
Each Accident $500,000
Disease--Policy Limit $500,000
Disease--Each Employee $500,000
</TABLE>
9. FIRE AND OTHER CASUALTY.
A. Termination. If a fire or other casualty causes substantial damage to
the Building or the Premises, Landlord shall engage a registered architect to
certify within one (1) month of the casualty to both Landlord and Tenant the
amount of time needed to restore the Building and the Premises to tenantability,
using standard working methods. If the time needed exceeds 180 days from the
beginning of the restoration, or two (2) months therefrom if the restoration
would begin during the last twelve (12) months of the Lease, then in the case of
the Premises, either Landlord or Tenant may terminate this lease, and in the
case of the Building, Landlord may terminate this Lease, by notice to the other
party within ten (10) days after the notifying party's receipt of the
architect's certificate. The termination shall be effective thirty (30) days
from the date of the notice and Rent shall be paid by Tenant to that date, with
an abatement for any portion of the space which has been untenantable after the
casualty. Notwithstanding the foregoing, Landlord shall not be permitted to
terminate the Lease if (1) Tenant provides Landlord written notice within five
(5) business days of Tenant's receipt of Landlord's termination notice that it
desires that the Lease not terminate and Tenant is willing to complete the
repairs and restorations and be responsible for any costs to be incurred in
connection therewith in excess of available insurance proceeds and (2) Tenant
shall pay to Landlord Rent due under this Lease as and when due without
abatement less the amount actually received by Landlord from rental loss
insurance.
B. Restoration. If a casualty causes damage to the Building or the
Premises but this Lease is not terminated for any reason, then subject to the
rights of any mortgagees or ground lessors, Landlord shall obtain the applicable
insurance proceeds and diligently restore the Building and the Premises subject
to current Governmental Requirements. Tenant shall replace its damaged
improvements and fixtures which are deemed Landlord's property under Section 5D
hereof. Rent shall be abated on a per diem basis from the date of the casualty
until the completion of the restoration for any portion of the Premises which is
untenantable, except to the extent that Tenant's negligence caused the casualty
and such rental abatement is not covered by Landlord's loss of rent insurance.
10. EMINENT DOMAIN. If a part of the Property is taken by eminent domain
or deed in lieu thereof which is so substantial that the Premises cannot
reasonably be used by Tenant for the operation of its business, then either
party may terminate this Lease effective as of the date of the taking. If all or
any portion of the parking areas of the Project is taken which affects Tenant's
parking rights under this Lease, Landlord shall use good faith, commercially
reasonable efforts to locate reasonable replacement parking for Tenant at no
additional cost to Tenant. Tenant shall have the right to terminate this Lease
by giving written notice to Landlord within six (6) months after the taking of
all or any portion of the parking areas of the Project if, (1) as a result of
such taking, Tenant's use of the Premises is materially and adversely affected,
21
<PAGE> 28
and (2) Landlord is unable or unwilling to provide Tenant with reasonably
comparable replacement parking for such lost parking. Notice of Tenant's
exercise of the right to terminate this Lease as provided in the preceding
sentence shall be delivered to Landlord in writing and shall specify the
effective date of termination which shall be not earlier than 90 days following
the date of such notice nor later than 180 days following the date of such
notice.
Rent shall abate from the date of the taking in proportion to any part
of the Premises taken. Tenant shall be entitled to any award which is
specifically awarded as compensation for the taking of Tenant's personal
property which was installed at Tenant's expense, for the value of Tenant's
goodwill, for any damage to Tenant's business and for costs of Tenant's
relocation to new premises. Except as set forth herein, the entire award for a
taking of any kind shall be paid to Landlord, and Tenant shall have no right to
share in the award. All obligations accrued to the date of the taking shall be
performed by each party.
11. RIGHTS RESERVED TO LANDLORD.
Landlord may exercise at any time any of the following rights respecting
the operation of the Project without liability to the Tenant of any kind:
A. Name. To change the name or street address of the Building or the
suite number(s) of the Premises (subject to the limitations of 5F).
B. Signs. To install, remove and maintain any signs on the exterior and
in the interior of the Building, and to approve, prior to installation, any of
Tenant's signs in the Premises visible from the common areas or the exterior of
the Building; provided, however, Tenant, at Tenant's sole cost, shall be
entitled to place signage on the building at a place selected by Tenant, subject
to the approval of any governmental authority with jurisdiction over the
project. Landlord shall have the right to reasonably approve the sign placement,
color and design; provided that such sign shall be visible from Eastgate Mall
and Executive Drive at Tenant's election.
C. Window Treatments. To approve, at its discretion, prior to
installation, any shades, blinds, ventilators or window treatments of any kind,
as well as any lighting within the Premises that may be visible from the
exterior of the Building or any interior common area.
D. Keys. To retain and use in the event of an emergency only (with
immediate telephonic notice to Tenant), one set of passkeys to enter the
Premises but no keys shall be required to be given to Landlord to provide access
to any laboratory areas or other areas reasonably reserved by Tenant from
Landlord access based upon the proprietary nature of any work being performed
therein.
E. Access. To have access to inspect the Premises upon 24 hours advance
notice to Tenant, and to perform its obligations, or make repairs, alterations,
additions or improvements, as permitted by this Lease.
F. Preparation for Reoccupancy. To decorate, remodel, repair, alter or
otherwise prepare the Premises for reoccupancy at any time after Tenant abandons
the Premises, without relieving Tenant of any obligation to pay Rent.
22
<PAGE> 29
G. Heavy Articles. To approve the weight, size, placement and time and
manner of movement within the Building of any safe, central filing system or
other heavy article of Tenant's property; provided that such approval shall not
be unreasonably withheld for any such article reasonably required for the
operation of Tenant's business in the Premises. Tenant shall move its property
entirely at its own risk.
H. Show Premises. To show the Premises to prospective purchasers,
tenants, brokers, lenders, investors, rating agencies or others at any
reasonable time, provided that Landlord gives at least 24 hours prior notice to
Tenant, agrees to be escorted by an employee of Tenant and does not materially
interfere with Tenant's use of the Premises.
I. Use of Lockbox. To designate a lockbox collection agent for
collections of amounts due Landlord. In that case, the date of payment of Rent
or other sums shall be the date of the agent's receipt of such payment or the
date of actual collection if payment is made in the form of a negotiable
instrument thereafter dishonored upon presentment. However, Landlord may reject
any payment for all purposes as of the date of receipt or actual collection by
mailing to Tenant within 21 days after such receipt or collection a check equal
to the amount sent by Tenant.
J. Repairs and Alterations. To make repairs or alterations to the
Property and in doing so transport any required material through the Premises,
to close entrances, doors, corridors, elevators and other facilities in the
Property and, to the extent required by such repairs or alterations, to open any
ceiling in the Premises or temporarily suspend services or use of the Common
Areas in the Property. Landlord may perform any such repairs or alterations
during ordinary business hours, except that Tenant may require any Work in the
Premises to be done after business hours if Tenant pays Landlord for overtime
and any other expenses incurred. Landlord may do or permit any work on any
nearby building, land, street, alley or way.
K. Landlord's Agents. If Tenant is in default under this Lease,
possession of Tenant's funds or negotiation of Tenant's negotiable instrument by
any of Landlord's agents shall not waive any breach by Tenant or any remedies of
Landlord under this Lease.
L. Building Services. To install, use and maintain through the Premises,
pipes, conduits, wires and ducts serving the Building, provided that such
installation, use and maintenance does not unreasonably interfere with Tenant's
use of the Premises.
M. Other Actions. To take any other action which Landlord deems
reasonable in connection with the operation, maintenance or preservation of the
Project.
N. Driveway Easement. To grant to Frazee East Property Partners, L.P.
(or its successor) a driveway easement for access to the property adjacent to
the Property known as Lots 1, 2, 3 and 4 of Chancellor Park Unit No. 2.
12. TENANT'S OR LANDLORD'S DEFAULT.
Any of the following shall constitute a default by Tenant:
23
<PAGE> 30
A. Rent Default. Tenant fails to pay any Rent within ten (10) days after
receipt of notice that such amount was not received when due (provided, however,
that any such notice shall be in lieu of, and not in addition to, any notice
required under Section 1161 et seq. of the California Code of Civil Procedure.)
B. Performance Default. Tenant fails to perform any other obligation to
Landlord under this Lease, and this failure continues for ten (10) days after
written notice from Landlord (provided, however, that any such notice shall be
in lieu of, and not in addition to, any notice required under Section 1161 et
seq. of the California Code of Civil Procedure), except that if Tenant begins to
cure its failure within the ten (10) day period but cannot reasonably complete
its cure within such period, then, so long as Tenant continues to diligently
attempt to cure its failure, the ten (10) day period shall be extended to sixty
(60) days, or such lesser period as is reasonably necessary to complete the
cure;
C. Credit Default. One of the following credit defaults occurs:
1. Tenant commences any proceeding under any law relating to
bankruptcy, insolvency, reorganization or relief of debts, or seeks
appointment of a receiver, trustee, custodian or other similar official
for the Tenant or for any substantial part of its property, or any such
proceeding is commenced against Tenant and either remains undismissed
for a period of sixty (60) days or results in the entry of an order for
relief against Tenant which is not fully stayed within seven days after
entry;
2. Tenant becomes insolvent or bankrupt, does not generally pay
its debts as they become due, or admits in writing its inability to pay
its debts, or makes a general assignment for the benefit of creditors;
3. Any third party obtains a levy or attachment under process of
law against Tenant's leasehold interest.
D. Abandonment Default. Tenant abandons the Premises.
E. Landlord Default. Landlord shall not be deemed in default under this
Lease unless Landlord fails to perform an obligation to be performed by Landlord
within thirty (30) days of the date such performance is due; provided, however,
that if the nature of Landlord's obligation is such that more than thirty (30)
days is reasonably required for its performance, then Landlord shall not be
deemed in default under this Lease if Landlord commences performance within such
thirty (30) day period and thereafter diligently pursues such performance to
completion.
13. LANDLORD REMEDIES.
A. Termination of Lease or Possession. If Tenant defaults, Landlord may
elect by notice to Tenant either to terminate this Lease or to terminate
Tenant's possession of the Premises without terminating this Lease. In either
case, Tenant shall immediately vacate the Premises and deliver possession to
Landlord, and Landlord may repossess the Premises and may, at Tenant's sole
cost, remove any of Tenant's signs and any of its other property, without
relinquishing its right to receive Rent or any other right against Tenant.
Without limiting the
24
<PAGE> 31
generality of the foregoing, upon the termination of this Lease or the
termination of Tenant's right of possession, it shall be lawful for the
Landlord, without formal demand or notice of any kind, to re-enter the Premises
by summary dispossession proceedings or any other action or proceeding
authorized by law and to remove Tenant and all persons and property therefrom.
B. Lease Termination Damages. Except as otherwise provided in Section
13C, if Tenant abandons the Premises prior to the end of the term hereof, or if
Tenant's right to possession is terminated by Landlord because of a default by
Tenant under this Lease, this Lease shall terminate. Upon such termination,
Landlord may recover from Tenant the following, as provided in Section 1951.2 of
the California Civil Code: (i) the worth at the time of award of the unpaid Rent
and other charges under this Lease that had been earned at the time of
termination; (ii) the worth at the time of award of the amount by which the
unpaid Rent and other charges under this Lease which would have been earned
after termination until the time of award exceeds the amount of such rental loss
that Tenant proves could have been reasonably avoided; (iii) the worth at the
time of award of the amount by which the unpaid Rent and other charges under
this Lease for the balance of the term of this Lease after the time of award
exceeds the amount of such rental loss that Tenant proves could have been
reasonably avoided; and (iv) any other amount necessary to compensate Landlord
for all the detriment proximately caused by Tenant's failure to perform its
obligations under this Lease or that in the ordinary course of things would be
likely to result therefrom. As used herein, the following terms are defined: (a)
The "worth at the time of award" of the amounts referred to in Sections (i) and
(ii) is computed by allowing interest at the lesser of eight percent (8%) per
annum or the maximum lawful rate. The "worth at the time of award" of the amount
referred to in Section (iii) is computed by discounting such amount at the
discount rate of the Federal Reserve Bank of San Francisco at the time of award
plus 1%.
C. Continuation of Lease. Even if Tenant has abandoned the Premises,
this Lease shall continue in effect for so long as Landlord does not terminate
Tenant's right to possession, and Landlord may enforce all its rights and
remedies under this Lease, including the right to recover rent as it becomes
due. This remedy is intended to be the remedy described in California Civil Code
Section 1951.4, and the following provision from such Civil Code Section is
hereby repeated: "The Lessor has the remedy described in California Civil Code
Section 1951.4 (lessor may continue lease in effect after lessee's breach and
abandonment and recover rent as it becomes due, if lessee has right to sublet or
assign, subject only to reasonable limitations)." Any such payments due Landlord
shall be made upon demand therefor from time to time and Tenant agrees that
Landlord may file suit to recover any sums falling due from time to time.
Notwithstanding any such reletting without termination, Landlord may at any time
thereafter elect in writing to terminate this Lease for such previous breach.
D. Possession Termination Damages. If Landlord terminates Tenant's right
to possession without terminating the Lease and Landlord takes possession of the
Premises itself, Landlord may relet any part of the Premises for such Rent, for
such time, and upon such terms as Landlord in its sole discretion shall
determine, without any obligation to do so prior to renting other vacant areas
in the Building. Any proceeds from reletting the Premises shall first be applied
to the expenses of reletting, including restoration, repair, alteration,
advertising, brokerage, legal, and other reasonably necessary expenses. If the
reletting proceeds after payment of expenses are insufficient to pay the full
amount of Rent under this Lease, Tenant
25
<PAGE> 32
shall pay such deficiency to Landlord monthly upon demand as it becomes due. Any
excess proceeds shall be retained by Landlord.
E. Landlord's Remedies Cumulative. All of Landlord's remedies under this
Lease shall be in addition to all other remedies Landlord may have at law or in
equity. Waiver by Landlord of any breach of any obligation by Tenant shall be
effective only if it is in writing, and shall not be deemed a waiver of any
other breach, or any subsequent breach of the same obligation. Landlord's
acceptance of payment by Tenant shall not constitute a waiver of any breach by
Tenant, and if the acceptance occurs after Landlord's notice to Tenant, or
termination of the Lease or of Tenant's right to possession, the acceptance
shall not affect such notice or termination. Acceptance of payment by Landlord
after commencement of a legal proceeding or final judgment shall not affect such
proceeding or judgment. Landlord may advance such monies and take such other
actions for Tenant's account as reasonably may be required to cure or mitigate
any default by Tenant. Tenant shall immediately reimburse Landlord for any such
advance, and such sums shall bear interest at the default interest rate until
paid.
F. WAIVER OF TRIAL BY JURY. EACH PARTY WAIVES TRIAL BY JURY IN THE EVENT
OF ANY LEGAL PROCEEDING BROUGHT BY THE OTHER IN CONNECTION WITH THIS LEASE. EACH
PARTY SHALL BRING ANY ACTION AGAINST THE OTHER IN CONNECTION WITH THIS LEASE IN
A FEDERAL OR STATE COURT LOCATED IN SAN DIEGO, CALIFORNIA, CONSENTS TO THE
JURISDICTION OF SUCH COURTS, AND WAIVES ANY RIGHT TO HAVE ANY PROCEEDING
TRANSFERRED FROM SUCH COURTS ON THE GROUND OF IMPROPER VENUE OR INCONVENIENT
FORUM.
G. Litigation Costs. Tenant shall pay Landlord's reasonable attorneys'
fees and other costs in enforcing this Lease, whether or not suit is filed.
14. SURRENDER. Upon termination of this Lease or Tenant's right to
possession, Tenant shall return the Premises to Landlord in good order and
condition, ordinary wear and casualty damage excepted. If Landlord requires
Tenant to remove any alterations, then Tenant shall remove the alterations in a
good and workmanlike manner and restore the Premises to its condition prior to
their installation.
15. HOLDOVER. If Tenant retains possession of any part of the Premises
after the Term, Tenant shall become a month-to-month tenant for the entire
Premises upon all of the terms of this Lease as might be applicable to such
month-to-month tenancy, except that Tenant shall pay all of Base Rent, Operating
Cost Share Rent and Tax Share Rent at double the rate in effect immediately
prior to such holdover, computed on a monthly basis for each full or partial
month Tenant remains in possession. Tenant shall also pay Landlord all of
Landlord's direct and consequential damages. No acceptance of Rent or other
payments by Landlord under these holdover provisions shall operate as a waiver
of Landlord's right to regain possession or any other of Landlord's remedies.
Notwithstanding the foregoing, any period of time required by Tenant for removal
of its alterations shall not be considered a holdover occupancy for purposes of
this Section 15 unless Landlord provides Tenant with at least 90 days advance
written notice of such obligations.
26
<PAGE> 33
16. SUBORDINATION TO GROUND LEASES AND MORTGAGES.
A. Subordination. This Lease shall be subordinate to any present or
future ground lease or mortgage respecting the Property, and any amendments to
such ground lease or mortgage, at the election of the ground lessor or mortgagee
as the case may be, effected by notice to Tenant in the manner provided in this
Lease; provided, however, that notwithstanding such subordination, so long as
Tenant is not in default under any of the terms, covenants and conditions of
this Lease, neither this Lease nor any of the rights of Tenant hereunder upon
Tenant's covenanting that Tenant is not in default hereunder, shall be
terminated or subject to termination by any trustee's sale, any action to
enforce the security, or by any proceeding or action in foreclosure. The
subordination shall be effective upon such notice, but at the request of
Landlord or ground lessor or mortgagee, Tenant shall within ten (10) business
days of the request, execute and deliver to the requesting party any reasonable
documents provided to evidence the provisions of this paragraph. Tenant
acknowledges that the subordination and non-disturbance agreement attached
hereto as Exhibit F is reasonable in form and content.
Landlord shall use reasonable efforts to obtain from all beneficiaries
under all deeds of trust and all mortgagees under all mortgages encumbering the
Property which were recorded prior to the recording of the Memorandum of Lease a
notarized subordination and non-disturbance agreement in a form reasonably
acceptable to Tenant (Tenant acknowledges that the subordination and
non-disturbance agreement attached hereto as Exhibit F is reasonably acceptable
to Tenant). If, notwithstanding Landlord's reasonable efforts, Landlord has been
unable to obtain a signed and notarized subordination and non-disturbance
agreement from all such beneficiaries and mortgagees within 60 days following
the date of this Lease, Tenant shall have the right to terminate this Lease
provided that (1) Tenant's exercise of the right to terminate must occur within
20 days following delivery by Landlord to Tenant of written notice that Landlord
has been unable to obtain all such subordination and non-disturbance agreements
(Tenant's failure timely to exercise the right to terminate shall result in a
waiver of the right to terminate) and (2) if Landlord has not yet notified
Tenant of Landlord's inability to obtain all such subordination and
non-disturbance agreements, Tenant's notice of termination shall not be
effective if, within 20 days after delivery of such notice by Tenant to
Landlord, Landlord delivers to Tenant all such subordination and non-disturbance
agreements bearing the notarized signatures of such beneficiaries and mortgagees
and (3) if this Lease is terminated, neither party shall have any further
liability to the other arising out of or relating to this Lease.
B. Termination of Ground Lease or Foreclosure of Mortgage. If any ground
lease is terminated or mortgage foreclosed or deed in lieu of foreclosure given
and the ground lessor, mortgagee, or purchaser at a foreclosure sale shall
thereby become the owner of the Property, Tenant shall attorn to such ground
lessor or mortgagee or purchaser without any deduction or setoff by Tenant, and
this Lease shall continue in effect as a direct lease between Tenant and such
ground lessor, mortgagee or purchaser, so long as, with respect to a new
purchaser, such new purchaser assumes all of the Landlord's obligations arising
under this Lease from and after the date of such transfer (except that
Landlord's obligation to fund the Landlord's Contribution under the Tenant
Improvement Agreement shall be binding upon any transferee). The ground lessor
or mortgagee or purchaser shall be liable as Landlord only during the time such
ground lessor or mortgagee or purchaser is the owner of the Property. At the
request of Landlord,
27
<PAGE> 34
ground lessor or mortgagee, Tenant shall execute and deliver within ten (10)
days of the request any document furnished by the requesting party to evidence
Tenant's agreement to attorn.
C. Security Deposit. Any ground lessor or mortgagee shall be responsible
for the return of any security deposit by Tenant only to the extent the security
deposit is received by such ground lessor or mortgagee. As a condition to
Tenant's attornment hereunder, the mortgagee or ground lessor shall be assigned
Landlord's interest in the Security Deposit and any Rent prepaid in excess of
one month.
D. Notice and Right to Cure. If the Property is subject to any ground
lease or mortgage identified with name and address of ground lessor or mortgagee
in Exhibit F to this Lease (as the same may be amended from time to time by
written notice to Tenant) then Tenant agrees to send by registered or certified
mail to any ground lessor or mortgagee identified either in such Exhibit or in
any later notice from Landlord to Tenant a copy of any notice of default sent by
Tenant to Landlord. If Landlord fails to cure such default within the required
time period under this Lease, but ground lessor or mortgagee begins to cure
within ten (10) days after such period and proceeds diligently to complete such
cure, then ground lessor or mortgagee shall have such additional time as is
necessary to complete such cure, including any time necessary to obtain
possession if possession is necessary to cure, and Tenant shall not begin to
enforce its remedies so long as the cure is being diligently pursued. Should
Landlord be deemed to be in material default of this Lease, then Landlord shall
be liable to Tenant for all damages sustained by Tenant as a direct result of
Landlord's breach. If any such default materially interferes with Tenant's
business operation in the Premises, Tenant may give Landlord and the holder of
any first mortgage or deed of trust covering the Premises a second written
notice specifying exactly the nature of the Landlord's failure and its impact on
Tenant's business operation in the Premises and the further remedial action
deemed necessary by Tenant. If such remedial action is not undertaken within ten
(10) days of such second written notice, Tenant shall be entitled to terminate
this Lease, but in no event earlier than ten (10) days after the second notice
to Landlord and the holder of any first mortgage or deed of trust covering the
Premises. Notwithstanding the foregoing, Tenant shall not be entitled to
terminate this Lease as a result of Landlord's default if Landlord or the ground
lessor or mortgagee is making diligent efforts to perform the obligations
required of Landlord under this Lease. Nothing herein contained shall be
interpreted to mean that Tenant is excused from paying any rent due hereunder as
a result of any default by Landlord.
E. Definitions. As used in this Section 16, "mortgage" shall include
"trust deed" and "mortgagee" shall include "trustee", "mortgagee" shall include
the mortgagee of any ground lessee, and "ground lessor", "mortgagee", and
"purchaser at a foreclosure sale" shall include, in each case, all of its
successors and assigns, however remote.
17. ASSIGNMENT AND SUBLEASE.
A. In General. Tenant shall not, without the prior consent of Landlord
in each case, (i) make or allow any assignment or transfer, by operation of law
or otherwise, of any part of Tenant's interest in this Lease, (ii) grant or
allow any lien or encumbrance, by operation of law or otherwise, upon any part
of Tenant's interest in this Lease, (iii) sublet any part of the Premises, or
(iv) permit anyone other than Tenant and its employees to occupy any part of the
Premises. Tenant shall remain primarily liable for all of its obligations under
this Lease,
28
<PAGE> 35
notwithstanding any assignment or transfer. No consent granted by Landlord shall
be deemed to be a consent to any subsequent assignment or transfer, lien or
encumbrance, sublease or occupancy. Any assignment or transfer, grant of lien or
encumbrance, or sublease or occupancy without Landlord's prior written consent
shall be void. If Tenant shall assign this Lease or sublet the Premises in its
entirety any rights of Tenant to renew this Lease, extend the Term or to lease
additional space in the Property shall be extinguished thereby and will not be
transferred to the assignee or subtenant, all such rights being personal to the
Tenant named herein.
B. Landlord's Consent. Landlord will not unreasonably withhold,
condition or delay its consent to any proposed assignment or subletting. It
shall be reasonable for Landlord to withhold its consent to any assignment or
sublease if (i) Tenant is in default under this Lease under any material
obligation beyond any applicable cure period, (ii) the proposed assignee or
sublessee is a tenant in the Property or an affiliate of such a tenant or a
party that Landlord has identified as a prospective tenant in the Property and
with whom Landlord is actively negotiating, (iii) the financial responsibility,
nature of business, and character of the proposed assignee or subtenant are not
all reasonably satisfactory to Landlord, (iv) in the reasonable judgment of
Landlord the purpose for which the assignee intends to use the Premises (or a
portion thereof) is not in keeping with Landlord's standards for the Building or
are in violation of the terms of this Lease or the REA, (v) the proposed
assignee or subtenant is a government entity, or (vi) in the case of an
assignment only, the proposed assignment is for less than the entire Premises or
for less than the remaining Term of the Lease or the REA. The foregoing shall
not exclude any other reasonable basis for Landlord to withhold its consent.
C. Procedure. Tenant shall notify Landlord of any proposed assignment or
sublease at least fifteen (15) days prior to its proposed effective date. The
notice shall include the name and address of the proposed assignee or subtenant,
its corporate affiliates in the case of a corporation and its partners in a case
of a partnership, an execution copy of the proposed assignment or sublease, and
sufficient information to permit Landlord to determine the financial
responsibility and character of the proposed assignee or subtenant. As a
condition to any effective assignment of this Lease, the assignee shall execute
and deliver in form satisfactory to Landlord at least fifteen (15) days prior to
the effective date of the assignment, an assumption of all of the obligations of
Tenant under this Lease. As a condition to any effective sublease, subtenant
shall execute and deliver in form satisfactory to Landlord at least fifteen (15)
days prior to the effective date of the sublease, an agreement to comply with
all of Tenant's obligations under this Lease, and at Landlord's option, an
agreement (except for the economic obligations which subtenant will undertake
directly to Tenant) to attorn to Landlord under the terms of the sublease in the
event this Lease terminates before the sublease expires.
D. Permitted Transfers. Any provision in this Lease to the contrary
notwithstanding, Landlord's consent shall not be required for any of the
following transfers (each of which shall be a "Permitted Transfer"): (a) to any
person(s) or entity who controls, is controlled by or is under common control
with Tenant; (b) to any entity resulting from the merger, consolidation or other
reorganization with Tenant, whether or not Tenant is the surviving entity, but
provided that, upon completion of such merger, consolidation or reorganization,
the net worth of the surviving entity is equal to or greater than Tenant's net
worth immediately prior to such merger, consolidation or reorganization; (c) to
any person or legal entity which acquires all or substantially all of the assets
or stock of Tenant (each of the foregoing is hereinafter referred to
29
<PAGE> 36
as a "Tenant Affiliate"); or (d) a sublease to any entity who operates a
business in the Premises solely for the purpose of supporting Tenant's business
operations; provided that such use is a Permitted Use under item 12 of the
Schedule. Before an assignment to a Tenant Affiliate shall be effective, (x)
said Tenant Affiliate shall assume, in full, the obligations of Tenant under
this Lease, (y) Landlord shall be given written notice of such assignment and
assumption and (z) the use of the Premises by the Tenant Affiliate shall be as
set forth in item 13 of the Schedule. For purposes of this paragraph, a public
or private offering of Tenant stock is a Permitted Transfer, and the term
"control" means possession, directly or indirectly, of the power to direct or
cause the direction of the management, affairs and policies of anyone, whether
through the ownership of voting securities, by contract or otherwise. The
provisions of Section 17E of this Lease shall not apply to an assignment or
sublease by Tenant as permitted by this Section 17D.
E. Excess Payments. If Tenant shall assign this Lease or sublet any part
of the Premises for consideration in excess of:
1. the pro rata portion of Rent applicable to the space subject
to the assignment or sublet and
2. Tenant's actual out-of-pocket costs of any such assignment or
subletting and any unamortized costs of tenant improvements benefiting
such transferee and paid for by Tenant directly (assuming all such
amounts are amortized in equal monthly installments of principal and
interest over the then-remaining term of the sublease or, in the event
of an assignment, this Lease (but not including any extension or renewal
rights) at an interest rate of 10% per annum),
then Tenant shall pay to Landlord as Additional Rent 50% of any such excess
immediately upon receipt.
F. Landlord's Assignment. Prior to the Commencement Date, Landlord shall
not assign its interest in this Lease to any third party without Tenant's prior
written consent, which consent shall not be unreasonably withheld or delayed.
Tenant's consent shall not be required in the event Landlord transfers its
interest to an entity in which Lee Chesnut owns at least a 33% beneficial
interest.
18. CONVEYANCE BY LANDLORD. If Landlord shall at any time transfer its
interest in the Property or this Lease, Landlord shall be released of any
obligations occurring after such transfer, except the obligation to return to
Tenant any security deposit or prepaid Rent not delivered to its transferee, and
Tenant shall look solely to Landlord's successors for performance of such
obligations. Subject to the provisions of Section 16, this Lease shall not be
affected by any such transfer.
19. ESTOPPEL CERTIFICATE. Each party shall, within ten (10) business
days of receiving a request from the other party, execute, acknowledge in
recordable form, and deliver to the other party or its designee a certificate
stating, subject to a specific statement of any applicable exceptions, that the
Lease as amended to date is in full force and effect, that the Tenant is paying
Rent and other charges on a current basis, and that to the best of the knowledge
of the certifying party, the other party has committed no uncured defaults and
has no offsets or
30
<PAGE> 37
claims. The certifying party may also be required to state the date of
commencement of payment of Rent, the Commencement Date, the Termination Date,
the Base Rent, the current Operating Cost Share Rent and Tax Share Rent
estimates, to the best of the knowledge of the certifying party the status of
any improvements required to be completed by Landlord, the amount of any
security deposit, and such other factual matters as may be reasonably requested.
Failure to deliver such statement within the time required shall be conclusive
evidence against the non-certifying party that this Lease, with any amendments
identified by the requesting party, is in full force and effect, that there are
no uncured defaults by the requesting party, that not more than one month's Rent
has been paid in advance, that the non-certifying party has not paid any
security deposit, and that the non-certifying party has no claims or offsets
against the requesting party.
20. SECURITY DEPOSIT. Tenant shall deposit with Landlord on the date of
this Lease security (the "Security Deposit") for the performance of all of its
obligations in the amount set forth on the Schedule. The Security Deposit shall
accrue interest at the rate of five percent (5%) per annum, and all interest
accrued on the Security Deposit shall be paid over to Tenant by Landlord within
five (5) business days of the last day of each calendar year. If Tenant defaults
under this Lease, Landlord may use any part of the Security Deposit to pay or
perform any obligation of Tenant under this Lease, or to compensate Landlord for
any loss or damage resulting from any default. To the extent any portion of the
Security Deposit is so used, Tenant shall within five (5) days after demand from
Landlord reinstate the Security Deposit to its full amount. If Tenant shall
perform all of its obligations under this Lease and return the Premises to
Landlord at the end of the Term, Landlord shall return any remaining Security
Deposit to Tenant. The Security Deposit shall not serve as an advance payment of
Rent or a measure of Landlord's damages for any default under this Lease.
If Landlord transfers its interest in the Property or this Lease,
Landlord shall either (a) transfer any Security Deposit then held by Landlord to
its transferee or (b) return to Tenant any Security Deposit then held by
Landlord and remaining after the deductions permitted herein. Upon such transfer
to such transferee or the return of the Security Deposit to Tenant, Landlord
shall have no further obligation with respect to the Security Deposit, and
Tenant's right to the return of the Security Deposit shall apply solely against
Landlord's transferee.
21. FORCE MAJEURE. Except with regard to Tenant's obligation to pay
Rent, neither Landlord nor Tenant shall be in default under this Lease to the
extent either of them is unable to perform any of its obligations on account of
any strike or labor problem, energy shortage, governmental pre-emption or
prescription, flood, earthquake, national emergency, or any other cause of any
kind beyond such party's reasonable control ("Force Majeure").
22. NOTICES. All notices, consents, approvals and similar communications
to be given by one party to the other under this Lease (including, without
limitation, any notice required by law to be given by Landlord to Tenant as a
condition to the filing of an action alleging an unlawful detainer of the
Premises and any three (3) day notice under Section 1161(2) or (3) of the
California Code of Civil Procedure), shall be given in writing, mailed or
personally delivered as follows:
31
<PAGE> 38
A. Landlord. To Landlord as follows:
LMC-Shoreham Investment Company, LLC
c/o Lee Chesnut
9627 Grossmont Summit Drive
La Mesa, CA 91941
or to such other person at such other address as Landlord may designate by
notice to Tenant.
B. Tenant. To Tenant as follows:
<TABLE>
<S> <C> <C>
Before the Commencement Date: After the Commencement Date:
CombiChem, Inc. CombiChem, Inc.
9050 Camino Santa Fe 4570 Executive Drive, Suite ___
San Diego, CA 92121 San Diego, CA 92121
Attn: Chief Financial Officer Attn: Chief Financial Officer
</TABLE>
or to such other person at such other address as Tenant may designate by notice
to Landlord.
Mailed notices shall be sent by United States certified or registered
mail, or by a reputable national overnight courier service, postage prepaid.
Mailed notices shall be deemed to have been given on the earlier of actual
delivery or three (3) business days after posting in the United States mail in
the case of registered or certified mail, and one business day in the case of
overnight courier.
23. QUIET POSSESSION. Subject to the provisions of Section 16, so long
as Tenant shall not be in default of any of its obligations under this Lease
beyond the applicable cure period provided herein, Tenant shall enjoy peaceful
and quiet possession of the Premises against any party claiming through the
Landlord.
24. REAL ESTATE BROKER. Tenant represents to Landlord that Tenant has
not dealt with any real estate broker with respect to this Lease except for John
Burnham and Company ("Tenant's Broker"), and no other broker claiming through
Tenant is in any way entitled to any broker's fee or other payment in connection
with this Lease. Tenant shall indemnify and defend Landlord against any claims
by any other broker or third party claiming to represent Tenant for any payment
of any kind in connection with this Lease based upon such representation.
Landlord shall, at its sole cost and expense, pay all commissions due and owing
to Tenant's Broker (specifically, Landlord shall pay Tenant's Broker (i)
$125,000 on the later of the date on which Landlord acquires fee title to the
Property (as set forth in Section 31) or the date on which Landlord's lender
approves this Lease (as set forth in Section 32) and (ii) $125,000 on the
Commencement Date).
25. MISCELLANEOUS.
A. Successors and Assigns. Subject to the limits on Tenant's assignment
contained in Section 17, the provisions of this Lease shall be binding upon and
inure to the benefit of all successors and assigns of Landlord and Tenant.
32
<PAGE> 39
B. Date Payments Are Due. Except for payments to be made by Tenant under
this Lease which are expressly due upon demand or upon a date which is expressly
stated in this Lease (e.g., Base Rent), Tenant shall pay to Landlord any other
amounts due hereunder within thirty (30) days of Tenant's receipt of a
Landlord's statement.
C. Meaning of "Landlord," "Re-Entry," "Including" and "Affiliate". The
term "Landlord" means only the owner of the Property and the lessor's interest
in this Lease from time to time. The words "re-entry" and "re-enter" are not
restricted to their technical legal meaning. The words "including" and similar
words shall mean "without limitation." The word "affiliate" shall mean a person
or entity controlling, controlled by or under common control with the applicable
entity. "Control" shall mean the power directly or indirectly, by contract or
otherwise, to direct the management and policies of the applicable entity.
D. Time of the Essence. Time is of the essence of each provision of this
Lease.
E. No Option. This document shall not be effective for any purpose until
it has been executed and delivered by both parties; execution and delivery by
one party shall not create any option or other right in the other party.
F. Severability. The unenforceability of any provision of this Lease
shall not affect any other provision.
G. Governing Law. This Lease shall be governed in all respects by the
laws of the state of California, without regard to the principles of conflicts
of laws.
H. Lease Modification. Tenant agrees to modify this Lease in any way
requested by a mortgagee which does not cause increased expense to Tenant or
otherwise materially adversely affect Tenant's interests under this Lease or in
the Premises.
I. No Oral Modification. No modification of this Lease shall be
effective unless it is a written modification signed by both parties.
J. Landlord's Right to Cure. If Landlord breaches any of its obligations
under this Lease, Tenant shall notify Landlord in writing and shall take no
action respecting such breach so long as Landlord immediately begins to cure the
breach and diligently pursues such cure to its completion. Landlord may cure any
default by Tenant; any expenses reasonably incurred shall become Additional Rent
due from Tenant on demand by Landlord.
K. Captions. The captions used in this Lease shall have no effect on the
construction of this Lease.
L. Authority. Landlord and Tenant each represents to the other that it
has full power and authority to execute and perform this Lease.
M. Landlord's Enforcement of Remedies. Landlord may enforce any of its
remedies under this Lease either in its own name or through an agent.
33
<PAGE> 40
N. Entire Agreement. This Lease, together with all Appendices,
constitutes the entire agreement between the parties. No representations or
agreements of any kind have been made by either party which are not contained in
this Lease.
O. Singular and Plural. Wherever appropriate in this Lease, a singular
term shall be construed to mean the plural where necessary, and a plural term
the singular. For example, if at any time two parties shall constitute Landlord
or Tenant, then the relevant term shall refer to both parties together.
P. Memorandum of Lease. Landlord and Tenant shall execute and record a
Memorandum of lease substantially in the form of Exhibit G attached hereto
within five (5) business days following the date on which Landlord acquires fee
title to the Property.
Q. Exclusivity. Landlord does not grant to Tenant in this Lease any
exclusive right except the right to occupy its Premises.
R. No Construction Against Drafting Party. The rule of construction that
ambiguities are resolved against the drafting party shall not apply to this
Lease.
S. Survival. All obligations of Landlord and Tenant under this Lease
shall survive the termination of this Lease.
T. Rent Not Based on Income. No rent or other payment in respect of the
Premises shall be based in any way upon net income or profits from the Premises.
Tenant may not enter into or permit any sublease or license or other agreement
in connection with the Premises which provides for a rental or other payment
based on net income or profit.
U. Building Manager and Service Providers. Landlord may perform any of
its obligations under this Lease through its employees or third parties hired by
the Landlord, provided that the costs of services performed by Landlord's
employees shall not exceed the cost of such services, if they had been submitted
by Landlord for competitive bid by competent third parties performing such
services in the San Diego Metropolitan area.
V. Late Charge and Interest on Late Payments. Without limiting the
provisions of Section 12A, if Tenant fails to pay any installment of Rent or
other charge to be paid by Tenant pursuant to this Lease when due and payable,
Landlord shall notify Tenant in writing that the installment of Rent or other
charge to be paid by Tenant is delinquent. If Tenant fails to pay such amount
within five (5) business days of its receipt of Landlord's notice, then Tenant
shall pay a late charge equal to the greater of four percent (4%) of the amount
of such payment or $250. In addition, interest shall be paid by Tenant to
Landlord on any late payments of Rent from the date due until paid at the rate
provided in Section 2D(2). Such late charge and interest shall constitute
Additional Rent due and payable by Tenant to Landlord upon the date of payment
of the delinquent payment referenced above.
W. Lease Termination Agreement and Agreement for Purchase and Sale.
Landlord's and Tenant's obligations hereunder are expressly conditioned upon
Campson Corporation's and Tenant's duly authorized execution and delivery of
that certain Lease Termination and Release
34
<PAGE> 41
Agreement dated as of the date hereof as well as that certain Agreement for
Purchase and Sale of Leasehold Improvements dated as of the date hereof.
26. UNRELATED BUSINESS INCOME. If Landlord is advised by its counsel at
any time that any part of the payments by Tenant to Landlord under this Lease
may be characterized as unrelated business income under the United States
Internal Revenue Code and its regulations, then Tenant shall enter into any
amendment proposed by Landlord to avoid such income, so long as the amendment
does not require Tenant to pay more Rent or accept fewer services from Landlord,
than this Lease provides, and provided that Landlord reimburses Tenant's
reasonable legal fees and costs associated with such amendment.
27. HAZARDOUS SUBSTANCES.
A. Reportable Uses Require Consent. The term "Hazardous Substance" as
used in this Lease shall mean any product, substance, chemical, material or
waste the presence, nature, quantity and/or intensity of existence, use,
manufacture, disposal, transportation, spill, lease or effect of which, either
by itself or in combination with other materials expected to be on the Premises,
is either: (i) potentially injurious to the public health, safety or welfare,
the environment or the Premises, (ii) regulated or monitored by any governmental
authority, or (iii) a basis for liability of Landlord to any governmental agency
or third party under any Government Requirement. Hazardous Substance shall
include, but not be limited to, hydrocarbons, petroleum, gasoline, crude oil or
any products, by-products or fractions thereof. Tenant may, without Landlord's
prior consent, use Hazardous Substances in the Premises provided that Tenant's
use of such Hazardous Substances (i) is in the normal course and scope of
Tenant's business operations permitted in the Premises, (ii) is in compliance
with all Government Requirements, (iii) does not expose the Premises or
neighboring properties to any meaningful risk of contamination or damage and
(iv) expose Landlord to any liability therefor.
B. Landlord's Access to Records regarding Hazardous Substances. Landlord
shall have access to and the right to audit, upon twenty-four (24) hours prior
written notice (or with no notice in the event of an emergency), all of Tenant's
records regarding the Hazardous Substances located on the Premises. Such records
shall include, without limitation, any statements, reports, notices,
registrations, applications, permits, business plans, licenses, claims, actions
or proceedings given to, or received from, any governmental authority or private
party, or persons entering into or occupying the Premises, concerning the
presence, spill, release, discharge of, or exposure to, any Hazardous Substance
or contamination in, on, or about the Premises in violation of Governmental
Requirements. Notwithstanding the foregoing, Tenant shall immediately notify
Landlord following any material violation (as determined by Tenant in its
reasonable and good faith discretion) of its obligations under Section 27A above
C. Indemnification. Tenant shall indemnify, protect, defend and hold
Landlord, its agents, employees, lenders and ground lessor, if any, and the
Premises, harmless from and against any and all loss of rents and/or damages,
liabilities, judgments, costs, claims, liens, expenses, penalties, permits and
attorney's and consultant's fees arising out of or involving any Hazardous
Substance or storage tank brought onto the Premises by or for Tenant or under
Tenant's control. Tenant's obligations under this Section 27 shall include, but
not be limited to, the effects of any contamination or injury to person,
property or the environment created or
35
<PAGE> 42
suffered by Tenant, and the cost of investigation (including reasonable
consultant's and attorney's fees and testing), removal, remediation, restoration
and/or abatement thereof, or of any contamination therein involved, such that
the Premises shall be returned to the condition required by all applicable
Government Requirements, and shall survive the expiration or earlier termination
of this Lease. No termination, cancellation or release agreement entered into by
Landlord and Tenant shall release Tenant from its obligation under this Lease
with respect to Hazardous Substances or storage tanks, unless specifically so
agreed by Lessor in writing at the time of such agreement. Notwithstanding any
other provision of this Lease, Landlord represents to the best of Landlord's
actual knowledge that there are no Hazardous Substances, including but not
limited to any solvents, metals, petroleum, lead-based paint, PCBs, or asbestos
in, on, under or about the Premises. Notwithstanding this representation,
Landlord shall indemnify and hold Tenant harmless against and from all liability
and claims of any kind for loss or damage to Tenant, its employees or agents,
and for expenses and fees of Tenant (including but not limited to reasonable
costs, expenses and attorneys' fees), incurred, directly or indirectly, as a
result the existence of Hazardous Substances in, on, under or about the Premises
as of the Commencement Date.
D. Exit Assessment. Prior to Tenant's surrender of the Premises, Tenant
shall conduct an "Exit Assessment" consisting of a Phase I Environmental
Assessment and such other tests as are listed on the Assessment Criteria
attached hereto as Exhibit H by an environmental consultant reasonably
acceptable to Landlord. Landlord shall receive a copy of the report(s) of
Tenant's Exit Assessment and said report(s) shall be deemed the physical
condition of the Premises upon Tenant's surrender of Premises. The cost of
Tenant's Exit Assessment shall be paid by Tenant. In the event that the Exit
Assessment indicates contamination of the Premises resulting from Tenant's
occupancy and/or use of the Premises, Tenant shall take such action as may be
reasonable under the circumstances to restore the Premises to the condition
required by all applicable Government Requirements; provided, however, that such
condition does not materially impair the value of the Property or the ability of
the owner to obtain financing for the Property. In the event such condition does
materially impair the value of the Property or the ability of the owner to
obtain financing for the Property, Tenant shall take such action as may be
reasonable under the circumstances to ensure that the condition of the Premises
does not materially impair the value of the Property or the ability of the owner
to obtain financing on the Property.
28. EXCULPATION. Landlord shall have no personal liability under this
Lease beyond its obligation to complete the Building shell and fund the
Landlord's Contribution (as set forth in the Tenant Improvement Agreement), its
liability shall be limited to its interest in the Project, and shall not extend
to any other property or assets of the Landlord (except for the amount of any
unfunded Landlord's Contribution wrongfully withheld by Landlord). In no event
shall any officer, director, employee, agent, shareholder, partner, member or
beneficiary of Landlord be personally liable for any of Landlord's obligations
hereunder.
29. ARBITRATION OF DISPUTES.
A. Disputes Subject to Arbitration. Except for Landlord's right to bring
an action in unlawful detainer as a result of any monetary default, or a default
caused by Tenant's vacation or abandonment of the Premises, all disputes or
controversies with respect to this Lease and any
36
<PAGE> 43
amendments hereof shall be determined and settled by arbitration conducted in
accordance with the commercial rules of the American Arbitration Association.
The arbitration shall be conducted in San Diego, California, by a single
arbitrator selected in accordance with the commercial rules of the American
Arbitration Association. Notwithstanding the commercial rules of the American
Arbitration Association, the following shall apply:
37
<PAGE> 44
1. Not less than three weeks in advance of the date for the
commencement of the arbitration hearing, Landlord and
Tenant shall simultaneously exchange (1) the name, address
and qualifications of all experts intended to be called at
the time of the arbitration hearing and (2) any reports
and/or data relied upon by such experts in connection with
forming an opinion relevant to the dispute which is the
subject of the arbitration.
2. Not less than five days prior to the date set for the
commencement of the arbitration hearing, each party shall
(1) make available for an oral deposition any expert(s)
whose testimony is/are expected to be given at the time of
the arbitration hearing and (2) deliver to the other party
all exhibits which are intended to be entered into
evidence at the time of the arbitration hearing.
3. In addition to the discovery allowed in the preceding
paragraphs, the arbitrator may, in the arbitrator's
discretion, allow for additional document discovery as may
be reasonable under the circumstances giving rise to the
dispute which is the subject of the arbitration.
4. Each party shall advance one-half of the fees payable to
the American Arbitration Association and the arbitrator;
provided, however, following the arbitrator's decision,
the arbitration may, at its discretion, award to the
prevailing party such fees and costs advanced in addition
to any other relief included in the arbitrator's award.
B. Enforcement. The judgment or the award rendered in any arbitration
initiated and conducted in accordance with this Article 29 may be entered in any
court of competent jurisdiction and shall be final and binding upon the parties.
Notice: By initialing in the space below you are agreeing to have
any dispute arising out of the matters included in the "Arbitration of Disputes"
provision decided by neutral arbitration as provided by California Law and you
are giving up any rights you might possess to have the dispute litigated in a
court of jury trial. By initialing in the space below you are giving up your
judicial rights to discovery and appeal, unless such rights are specifically
included in this Article 29. Your agreement to the arbitration provision is
voluntary.
As indicated by our initials below, we have read and understand
the foregoing and agree to submit disputes arising out of the matters included
in the "Arbitration of Disputes" provision to neutral, binding arbitration:
Landlord: ____________ Tenant: _____________
30. RIGHT OF FIRST NEGOTIATION. In the event that a tenant of the
Building decides to vacate or vacates the Building, or any portion thereof,
which such tenant is leasing (the "Additional Space") rendering the Additional
Space available for lease, Landlord shall, before it starts to market the
Additional Space, notify Tenant in writing that Tenant may lease the
38
<PAGE> 45
Additional Space. Tenant shall notify Landlord that it would like to lease
within thirty (30) days of its receipt of such notice, and Landlord and Tenant
shall then prepare a letter of intent or similar preliminary agreement (oral or
written) (collectively, the "LOI") and negotiate the terms of a lease for the
Additional Space. If Tenant fails to notify Landlord of its desire to lease the
Additional Space within such thirty (30) day period, Tenant shall be deemed to
have waived its right to the Additional Space. If Landlord and Tenant fail to
reach an agreement on the terms of such LOI and/or lease, Landlord shall notify
Tenant in writing of this fact and may then seek a third party tenant for the
Additional Space. Tenant, however, shall retain a right of first refusal on the
Additional Space if the Additional Space is offered for lease to any party for
consideration that is less than ninety-five percent (95%) of the consideration
specified in the LOI.
31. CONDITION PRECEDENT: LANDLORD'S ACQUISITION OF THE PROPERTY.
Landlord's and Tenant's obligations under this Lease are subject to the
condition precedent that, on or before April 30, 1999, Landlord (or Landlord's
assignee) acquires fee title to the Property from Sunroad Corporate Centre One,
LLC. Landlord shall use reasonable efforts to acquire fee title to the Property
in accordance with that certain Purchase and Sale Agreement between Landlord and
Sunroad dated February 4, 1999. If, on or before April 30, 1999, Landlord has
not acquired fee title to the Property, then either Landlord or Tenant may, by
delivery of written notice to the other, terminate this Lease; provided,
however, Tenant's notice of termination shall not be effective if, within five
business days after delivery of such notice, Landlord acquires fee title to the
Property.
32. CONDITION PRECEDENT: LANDLORD'S LENDER APPROVAL. Landlord's
obligations under this Lease are subject to the condition precedent that, on or
before March 15, 1999, Landlord receives from Landlord's lender (Tokai Bank)
written notice of approval of the terms of this Lease. Landlord shall use
reasonable efforts to obtain approval of this Lease from Landlord's lender. If,
on or before March 15, 1999, Landlord has not received from Landlord's lender
approval of this Lease, then Landlord or Tenant may, by delivery of written
notice to the other, terminate this Lease; provided, however, Tenant's notice of
termination shall not be effective if, within five business days after delivery
of such notice, Landlord receives from Landlord's lender written notice of
approval of this Lease.
33. LANDLORD'S INDEMNITY AND LIQUIDATED DAMAGES.
In the event this Lease is terminated as a consequence of either of the
conditions precedent set forth in Sections 31 and 32 not being timely satisfied,
Landlord (or Landlord's assignee) agrees to indemnify, defend and hold harmless
Tenant, Tenant's agents and Tenant's affiliates from and against any and all
claims, liabilities, costs and expenses arising out of or related to this
failure including, without limitation (i) all costs incurred in connection with
the Tenant Improvements and the Tenant Improvement Agreement (e.g., design
professional and project management fees as well as reasonable attorney's fees
and costs) and (ii) any commission paid to Tenant's Broker. Landlord shall be
liable for Tenant's consequential damages; however, Landlord and Tenant agree
that it would be impractical and extremely difficult to estimate the
consequential damages which Tenant may suffer. Therefore, Landlord and Tenant
agree that $3,810.69 per day from the date of this Lease through the date that
Landlord notifies Tenant in writing that either of the conditions precedent set
forth in Sections 31 and 32 has not been met
39
<PAGE> 46
represents a fair and reasonable amount of Tenant's consequential damages.
Landlord shall pay such sum to Tenant promptly following the failure of either
of the conditions precedent set forth in Sections 31 and 32.
34. OPTION TO RENEW. Tenant shall have the right and option to renew
this Lease for a further term of five years commencing on the expiration date of
the 15th Lease Year. The option to extend the term of this Lease may be
exercised only by delivery to Landlord, prior to the expiration date of the 14th
Lease Year, of written notice of such exercise. Tenant's exercise of the option
shall be subject to the condition that Tenant not be in default in the
performance of Tenant's obligations under this Lease and shall be irrevocable.
Tenant's occupancy during the option period shall be subject to all terms and
conditions of this Lease provided, however, Base Rent shall be adjusted as
provided below. The Base Rent to be paid by Tenant to Landlord during the first
Lease Year of the option period (i.e. Lease Year 16) shall be the greater of (1)
the Base Rent payable during the 15th Lease Year or (2) the Market Rental Rate.
As used herein, the term "Market Rental Rate" shall mean that rate which is
prevailing as of the commencement of the first Lease Year of the option period
for comparable space in a comparable building in the University Town Center area
of San Diego County, California, taking into consideration the size and age of,
and improvements in, the Premises and other relevant factors, and which Market
Rental Rate shall be determined as follows:
A. By mutual agreement between Landlord and Tenant evidenced in a
writing signed by each and mutually delivered; or
B. If Landlord and Tenant have not agreed upon the Market Rental Rate
prior to the commencement of the first Lease Year of the option period, then
either Landlord or Tenant may submit the issue of Market Rental Rate to
determination by arbitration under the auspices of the American Arbitration
Association (or its successor) which shall be conducted pursuant to the
commercial rules except as otherwise provided in this Lease. The venue for the
arbitration shall be in the City of San Diego. With respect to the conduct of
the arbitration, the following shall apply:
(1) Not less than three weeks in advance of the date for the
commencement of the arbitration hearing, Landlord and Tenant shall each
exchange (1) the name, address and qualifications of any appraiser,
broker or other expert intended to be called at the time of the
arbitration (each, an "Expert"), (2) any reports and/or data relied upon
by the Expert in connection with forming an opinion as to Market Rental
Rate and (3) a statement as to each party's determination of the Market
Rental Rate ("MRR Statement") (i.e. Landlord shall give to Tenant
Landlord's determination of the Market Rental Rate and vice-versa).
(2) For a period of ten days following the exchange of the MRR
Statements, either party may accept the Market Rental Rate stated in the
other party's MRR Statement and, in such event, the accepted amount will
become the Base Rent for the first Lease Year of the option period
(e.g., if Landlord delivered to Tenant timely written notice of
acceptance of Tenant's determination of Market Rental Rate as provided
in Tenant's
40
<PAGE> 47
MRR Statement, then the amount shown on Tenant's MRR Statement would
become the Base Rent for the option period).
(3) If neither party accepts the other party's determination of
Market Rental Rate, then the arbitration shall be conducted before a
single arbitrator who shall be selected pursuant to the commercial
rules. Not less than five days prior to the date set for the hearing for
the arbitration, each party shall (1) make available for an oral
deposition any Expert whose testimony is expected to be given at the
time of the arbitration and (2) deliver to the other party all exhibits
which are intended to be entered into evidence at the time of the
arbitration.
(4) Except as provided below, each party shall bear their own
attorney's fees and Expert's fees. Except as provided below, each party
shall share equally any administrative fees owed to the American
Arbitration Association and the reasonable hourly fees owed to the
arbitrator. Notwithstanding the foregoing, if the amount of the Market
Rental Rate stated in Tenant's MRR Statement is less than 95 percent of
the Market Rental Rate determined by the arbitrator, then the arbitrator
may, in the arbitrator's discretion, assess against Tenant costs
incurred by Landlord in connection with the arbitration including,
without limitation, reasonable attorney's fees, Expert's fees,
arbitrator's fees and administration fees. If the amount of the Market
Rental Rate stated in Landlord's MRR Statement is greater than 105
percent of the Market Rental Rate determined by the arbitrator, then the
arbitrator may, in the arbitrator's discretion, assess against Landlord
costs incurred by Tenant in connection with the arbitration including,
without limitation, reasonable attorney's fees, Expert's fees,
arbitrator's fees and administration fees.
(5) Following rendition of the arbitrator's award, either party
may petition the Superior Court of the State of California for the
County of San Diego to have the award confirmed and entered as a
judgment. Pending determination of the Base Rent for the first Lease
Year of the option period, Tenant shall continue to pay to Landlord Base
Rent at the rate due under the Lease for the 15th Lease Year. If the
arbitrator determines that the Market Rental Rate is more than the Base
Rent due under the Lease for the 15th Lease Year, then, within 30 days
following the arbitrator's decision, Tenant shall pay to Landlord the
amount of the difference between the Base Rent actually paid by Tenant
from the commencement of the option period and the amount of the Base
Rent at the Market Rental Rate as determined by the arbitrator for the
same period plus interest at the rate of 10 percent per annum.
(6) Base Rent for Lease Year 17 though 20 shall be subject to
increase as provided in Paragraph 12 of the Schedule except that (1) the
Base Rent to be multiplied by the fraction shall be the Base Rent for
the first Lease Year of the option period (i.e., the 16th Lease Year),
(2) the numerator of the fraction shall be the Index for the last
published period prior to the commencement of the Lease Year for which
the calculation is being made and (3) the denominator of the fraction
shall be the Index for the last published period prior to the
commencement of the 16th Lease Year.
[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]
41
<PAGE> 48
IN WITNESS WHEREOF, the parties hereto have executed this Lease.
LANDLORD:
LMC-SHOREHAM INVESTMENT COMPANY, LLC, a
California limited liability company
By: /s/ illegible
-----------------------------------------
Print Name: illegible
------------------------------
Print Title: member/manager
------------------------------
CONVOY COURT INVESTMENT COMPANY, LLC, a
California limited liability company
By: /s/ illegible
-----------------------------------------
Print Name: illegible
------------------------------
Print Title: member/manager
------------------------------
TENANT:
COMBICHEM, INC.
a Delaware corporation
By: /s/ Karin Eastham
-----------------------------------------
Print Name: Karin Eastham
------------------------------
Print Title: VP, Finance & Admin
------------------------------
By:
-----------------------------------------
Print Name:
------------------------------
Print Title:
------------------------------
[SIGNATURE PAGE TO LEASE]
<PAGE> 49
EXHIBIT A
PLAN OF THE PREMISES
FLOOR PLAN
A-1
<PAGE> 50
EXHIBIT B
RULES AND REGULATIONS
1. Tenant shall not place anything, or allow anything to be placed near
the glass of any window, door, partition or wall which may, in Landlord's
judgment, appear unsightly from outside of the Property.
2. The Property directory shall be available to Tenant solely to display
names and their location in the Property, which display shall be as directed by
Landlord.
3. The sidewalks, exits and entrances, shall not be obstructed by Tenant
or used by Tenant for any purposes other than for ingress to and egress from the
Premises. Tenant shall lend its full cooperation to keep such areas free from
all obstruction and in a clean and sightly condition and shall move all
supplies, furniture and equipment as soon as received directly to the Premises
and move all such items and waste being taken from the Premises (other than
waste customarily removed by employees of the Building) directly to the shipping
platform at or about the time arranged for removal therefrom. The Common Areas
of the Property are not for the use of the general public and Landlord shall, in
all cases, retain the right to control and prevent access thereto by all persons
whose presence in the judgment of Landlord, reasonably exercised, shall be
prejudicial to the safety, character, reputation and interests of the Property.
Neither Tenant nor any employee or invitee of Tenant shall go upon the roof of
the Property.
4. The toilet rooms, urinals, wash bowls and other apparatuses shall not
be used for any purposes other than that for which they were constructed, and to
the extent caused by Tenant or its employees or invitees, the expense of any
breakage, stoppage or damage resulting from the violation of this rule shall be
borne by Tenant.
5. Tenant shall not cause any unnecessary janitorial labor or services
by reason of Tenant's carelessness or indifference in the preservation of good
order and cleanliness.
6. Tenant shall not use the Premises for housing, lodging or sleeping
purposes. Tenant shall not occupy or use the Premises or permit the Premises to
be occupied or used for any purpose, act or thing which is in violation of any
Governmental Requirement.
7. Upon termination of the lease, Tenant shall deliver to Landlord all
keys and passes for offices, rooms, parking lot and toilet rooms which shall
have been furnished Tenant.
8. Tenant shall not install linoleum, tile, carpet or other floor
covering so that the same shall be affixed to the floor of the Premises in any
manner except as approved by Landlord.
9. Tenant shall not take or permit to be taken in or out of other
entrances of the Building, or take or permit on other elevators, any item
normally taken in or out through the trucking concourse or service doors or in
or on freight elevators.
10. Tenant shall cause all exterior doors to the Premises to be closed
and securely locked.
B-1
<PAGE> 51
11. Peddlers, solicitors and beggars shall be reported to the office of
the Property or as Landlord otherwise requests.
12. Tenant shall not make or permit any noise, vibration or odor to
emanate from the Premises, or do anything therein tending to create, or
maintain, a nuisance, or do any act tending to injure the reputation of the
Building.
13. Tenant acknowledges that Building security problems may occur which
may require the employment of extreme security measures in the day-to-day
operation of the Property.
Accordingly:
(a) Landlord may, at any time, or from time to time, or for
regularly scheduled time periods, as deemed advisable by Landlord and/or its
agents, in their sole discretion, require that persons entering or leaving the
Property or the Property identify themselves to watchmen or other employees
designated by Landlord, by registration, identification or otherwise.
(b) Tenant agrees that it and its employees will cooperate fully
with Property employees in the implementation of any and all security
procedures.
(c) Such security measures shall be the sole responsibility of
Landlord, and Tenant shall have no liability for any action taken by Landlord in
connection therewith, it being understood that Landlord is not required to
provide any security procedures and shall have no liability for such security
procedures or the lack thereof.
14. Tenant shall not disturb the quiet enjoyment of any other tenant.
15. Tenant shall not provide any janitorial services or cleaning without
Landlord's written consent and then only subject to supervision of Landlord and
at Tenant's sole responsibility and by janitor or cleaning contractor or
employees at all times satisfactory to Landlord.
16. Landlord may place and keep on the windows and doors of the Premises
at any time signs advertising the Premises for Rent.
17. No equipment, mechanical ventilators, awnings, special shades or
other forms of window covering shall be permitted either inside or outside the
windows of the Premises without the prior written consent of Landlord, and then
only at the expense and risk of Tenant, and they shall be of such shape, color,
material, quality, design and make as may be approved by Landlord.
18. Tenant shall not during the term of this Lease canvas or solicit
other tenants of the Building for any purpose.
19. Except as provided elsewhere in this Lease, Tenant shall not install
or operate any antenna, aerial, wires or other equipment inside or outside the
Building, nor operate any
B-2
<PAGE> 52
electrical device from which may emanate electrical waves which may interfere
with or impair radio or television broadcasting or reception from or in the
Building or elsewhere, without in each instance the prior written approval of
Landlord. The use thereof, if permitted, shall be subject to control by Landlord
to the end that others shall not be disturbed.
20. Tenant shall not exhibit, sell or offer for sale, Rent or exchange
in the Premises or at the Property any article, thing or service, except those
ordinarily embraced within the use of the Premises specified in Section 6 of
this Lease, without the prior written consent of Landlord.
21. Tenant shall not overload any floors in the Premises or any public
corridors or elevators in the Building.
22. Whenever Landlord's consent, approval or satisfaction is required
under these Rules, then unless otherwise stated, any such consent, approval or
satisfaction must be obtained in advance, such consent or approval may be
granted or withheld in Landlord's reasonable discretion.
B-3
<PAGE> 53
EXHIBIT C
TENANT IMPROVEMENT AGREEMENT
1. TENANT IMPROVEMENTS. Landlord shall cause to be performed the
improvements (the "Tenant Improvements") in the Premises in accordance with
plans and specifications approved by Tenant and Landlord (the "Plans"), which
approvals shall not be unreasonably withheld or delayed. The Tenant Improvements
shall be performed at the Tenant's cost, subject to the Landlord's Contribution
(hereinafter defined). The Tenant Improvements shall not include the costs of
designing and constructing the Building's "shell" as defined in Schedule C-1
attached hereto (collectively, the "Building Shell").
Tenant shall promptly and diligently cause the Plans to be prepared by
Carrier Johnson such that the commencement of construction of the Tenant
Improvements may occur by April 15, 1999. The Premises shall include hazardous
materials control zones. The number of such control zones shall be commensurate
with that of Tenant's current facility at 9050 Camino Santa Fe, San Diego,
California and shall be sufficient to meet the needs of Tenant's intended use of
the Premises. Tenant shall furnish the initial draft of the Plans to Landlord
for Landlord's reasonable review and approval. Landlord shall within ten (10)
business days after receipt either provide comments to such Plans or approve the
same. Landlord shall be deemed to have approved such Plans if it does not timely
provide comments on such Plans. If Landlord provides Tenant with comments to the
initial draft of the Plans, Tenant shall provide revised Plans to Landlord
incorporating Landlord's comments within five (5) business days after its
receipt of Landlord's comments. Landlord shall within five (5) business days
after its receipt then either provide comments to such revised Plans or approve
such Plans. Landlord shall be deemed to have approved such revised Plans if
Landlord does not timely provide comments on such Plans. The process described
above shall be repeated, if necessary, until the Plans have been finally
approved by Landlord. Tenant hereby agrees that the Plans for the Tenant
Improvements shall comply with all applicable Governmental Requirements.
Landlord's approval of any of the Plans (or any modifications or changes
thereto) shall not impose upon Landlord or its agents or representatives any
obligation with respect to the design of the Tenant Improvements or the
compliance of such Tenant Improvements or the Plans with applicable Governmental
Requirements.
DPR (the "Contractor") shall construct the Tenant Improvements. Tenant
may replace the Contractor with another contractor which such contractor shall
be subject to Landlord's reasonable approval. Landlord shall use commercially
reasonable efforts to cause the Tenant Improvements to be Substantially
Completed (as defined in Section 5 hereof) on or before November 1, 1999,
subject to extension Tenant Delays (as defined in Section 4 hereof) and Force
Majeure (the "Target Commencement Date").
BioStruct shall provide project management services in connection with
the construction of the Tenant Improvements and the Change Orders (hereinafter
defined). Neither Landlord nor any of its agents or employees shall receive any
other fee described for profit, overhead or general condition in connection with
the construction of the Tenant Improvements or Change Orders.
C-1
<PAGE> 54
BioStruct shall have the right to (a) require the Contractor to obtain
three (3) subcontractor bids on any item of the construction project and (b)
review, comment upon and approve (which approval shall not be unreasonably
withheld or delayed), prior to its execution, Landlord's contract with the
Contractor.
2. CHANGE ORDERS. If, prior to the Commencement Date, Tenant shall
require improvements or changes (individually or collectively, "Change Orders")
to the Premises in addition to, revision of or substitution for the Tenant
Improvements, Tenant shall deliver to Landlord for its approval plans and
specifications for such Change Orders. If Landlord does not approve of the plans
for Change Orders, Landlord shall advise Tenant of the revisions required.
Tenant shall revise and redeliver the plans and specifications to Landlord
within five (5) business days of Landlord's advice or Tenant shall be deemed to
have abandoned its request for such Change Orders. Tenant shall pay for all
preparations and revisions of plans and specifications, and the construction of
all Change Orders, subject to Landlord's Contribution.
3. LANDLORD'S CONTRIBUTION. Landlord shall contribute an amount equal to
$90.00 per rentable square foot of the Premises ("Landlord's Contribution")
toward the costs incurred for the Tenant Improvements and Change Orders.
Landlord has no obligation to pay for costs of the Tenant Improvements or Change
Orders in excess of Landlord's Contribution. If the cost of the Tenant
Improvements and/or Change Orders exceeds the Landlord's Contribution, Tenant
shall pay such overage to Landlord once the Landlord's Contribution has been
exhausted. For the purposes of this Lease, the costs incurred for the Tenant
Improvements and Change Orders shall include, without limitation, the
preparation of the Plans, hard construction costs, architectural and engineering
fees, all fees incurred for project management up to a maximum of $75,000, all
governmental and other regulatory fees and costs associated with the Tenant
Improvements and Change Orders, costs of utility connection and permitting and
construction management fees. Promptly following the parties' execution of the
Lease, Landlord shall reimburse to Tenant all fees incurred by Carrier Johnson
and paid by Tenant. Landlord's Contribution shall not be used to design or
construct the Building Shell (as defined in Schedule C-1 attached hereto);
Landlord shall, at its sole cost and expense, design and build the Building
Shell.
4. SUBSTANTIAL COMPLETION AND COMMENCEMENT DATE. The Tenant Improvements
shall be deemed to be "Substantially Completed", and "Substantial Completion"
shall be deemed to occur when the Contractor certifies in writing to Landlord
and Tenant that (a) Tenant has reasonable access to the Premises; (b) Contractor
has substantially performed all of the Tenant Improvement work required to be
performed under this Plans, other than decoration and minor "punch list" items
and adjustments which do not materially interfere with Tenant's access to or use
of the Premises; and (c) Contractor or Landlord has obtained a temporary
certificate of occupancy or other required approval from the local governmental
authority permitting occupancy of the Premises. Within three (3) days after its
receipt of such certificate from Landlord, Tenant shall conduct a walk-through
inspection of the Premises with Landlord to inspect the Premises and the Tenant
Improvements. Within five (5) days following such inspection, Tenant shall
prepare and provide to Landlord a written "punch list" specifying those Tenant
Improvements which require completion and other reasonable corrective work,
which punch list items Landlord shall cause Contractor to complete within thirty
(30) days of Landlord's receipt of the same. The Contractor shall guaranty all
work and Tenant
C-2
<PAGE> 55
Improvements for one (1) year from the earlier of the Commencement Date or the
commencement of the warranty for those items covered by manufacturer's or
vendor's warranties and, to the extent possible, shall assign all warranties to
Tenant.
5. COMMENCEMENT DATE DELAY. If Landlord fails to Substantially Complete
the Tenant Improvements by the Outside Date (defined below), Landlord shall pay
Tenant as liquidated damages $3,810.69 per day (which such amount is equal to
the Base Rent for the approximately 40,756 rentable square feet the Premises
shall contain in excess of the rentable square feet in Tenant's current facility
at 9050 Camino Santa Fe, San Diego, California multiplied by 110%). As used
herein, the term "Outside Date" shall mean the date which is 60 days after the
Target Commencement Date. If Landlord fails to Substantially Complete the Tenant
Improvements by the date which is 60 days after the Outside Date, Tenant may
deliver to Landlord written notice of the Tenant's intention to terminate this
Lease and, if Landlord fails to Substantially Complete the Tenant Improvements
within 10 days following Landlord's receipt of such notice, this Lease shall
terminate and neither party shall have any further liability to the other
arising out of or relating to this Lease. Each day that Substantial Completion
of the Tenant Improvements is delayed due to Force Majeure or a Tenant Delay
shall extend the Target Commencement Date by one (1) day; provided; however, in
order to extend the Target Commencement Date, Landlord must have previously
delivered to Tenant written notice of the occurrence(s) giving rise to such
delay(s) within ten (10) days following the date on which Landlord becomes aware
that such occurrence(s) are causing delay in achieving Substantial Completion.
For purposes of this paragraph, Landlord shall cause Carrier Johnson to certify
the date on which the Tenant Improvements would have been completed but for such
Force Majeure or Tenant Delay or were in fact completed without any such Force
Majeure or Tenant Delay.
For the purposes of this Tenant Improvement Agreement, a "Tenant Delay"
is defined as a delay caused by any one or more of the following:
A. Tenant's request for Change Orders within the last thirty (30)
days of construction to the extent such Change Orders are actually performed and
to the extent such Changes Orders exceed the period of time allotted therefor in
the Construction Schedule;
B. Contractor's performance of any Change Orders within the last
thirty (30) days of construction; or
C. Tenant's request for decorative materials, finishes or
installations requiring unusually long lead times; or
D. Tenant's delay in reviewing, revising or approving plans and
specifications beyond the periods set forth herein unless caused by the errors
or omissions of Landlord or its agents, employees or contractors; or
E. Tenant's delay in providing information critical to the normal
progression of the project. Tenant shall provide such information as soon as
reasonably possible, but in no event longer than ten (10) days after receipt of
such request for information from the Landlord; or
C-3
<PAGE> 56
F. Tenant's delay in making payments to Landlord for costs of the
Tenant Improvements and/or Change Orders in excess of the Landlord's
Contribution.
Notwithstanding the foregoing, no delay shall constitute a Tenant Delay
until (i) Landlord has given Tenant written notice which states that a Tenant
Delay has occurred and explains the nature of such Tenant Delay and (ii) Tenant
fails to cure such delay within two (2) business days of its receipt of such
notice.
7. ACCESS BY TENANT PRIOR TO COMMENCEMENT DATE. Landlord shall permit
Tenant and its agents to enter the Premises prior to the Commencement Date to
prepare the Premises for Tenant's use and occupancy. Any such permission shall
constitute a license only and shall be conditioned upon Tenant's:
A. working in harmony with Landlord and Landlord's agents,
contractors, workmen, mechanics and suppliers and with other tenants and
occupants of the Building;
B. obtaining in advance Landlord's approval of the contractors
proposed to be used by Tenant and depositing with Landlord in advance of any
work (i) security satisfactory to Landlord for the completion thereof, and (ii)
the contractor's affidavit for the proposed work and the waivers of lien from
the contractor and all subcontractors and suppliers of material; and
C. furnishing Landlord with such insurance as Landlord may
require against liabilities which may arise out of such entry.
Landlord shall have the right to withdraw such license for Tenant's
failure to comply with the foregoing conditions upon twenty-four (24) hours'
advance written notice to Tenant. Landlord shall not be liable in any way for
any injury, loss or damage which may occur to any of Tenant's property or
installations in the Premises prior to the Commencement Date. Tenant shall
protect, defend, indemnify and save harmless Landlord from all liabilities,
costs, damages, fees and expenses to the extent caused by the activities of
Tenant or its agents, contractors, suppliers or workmen in the Premises or the
Building. Any entry and occupation permitted under this Section shall be
governed by Section 5 and all other terms of the Lease.
8. ARBITRATION.
A. Dispute Resolution. If any dispute arises in connection with
this Tenant Improvement Agreement, such dispute shall be resolved by arbitration
in accordance with Article 29 of the Lease.
9. MISCELLANEOUS. Terms used in this Exhibit C shall have the meanings
assigned to them in the Lease. The terms of this Exhibit C are subject to the
terms of the Lease.
C-4
<PAGE> 57
SCHEDULE C-1
DEFINITION OF BUILDING SHELL
Except as provided below, "Building Shell" shall mean the work
identified in the plans bearing the cover sheet of Brian Paul & Associates dated
January 6, 1999 (revision Delta 4) ("the Delta 4 Plans"). Notwithstanding the
foregoing, Tenant and Landlord agree:
1. Landlord and Tenant acknowledge and agree that the mechanical yard
and the equipment to be placed into the central plant which will be located in
the mechanical yard will need to be revised from the Delta 4 Plans in order to
accommodate CombiChem's intended use of the Building. Subject to Tenant's
compliance with Government Requirements, Landlord shall permit Tenant to store
Hazardous Substances in tanks or other appropriate containers in the mechanical
yard (or in any other exterior location near the Building as reasonably agreed
upon by Landlord and Tenant). Such storage facilities shall include, without
limitation, those identified on Schedule C-2 attached hereto and shall have a
capacity approximately double the capacity of the external storage facilities
located at Tenant's current facility at 9050 Camino Santa Fe, San Diego,
California. The present amount budgeted for the cost of the mechanical yard and
central plant as shown in the Delta 4 Plans is $410,000. To the extent that the
actual cost to redesign and construct the mechanical yard and central plant
exceeds $410,000, such excess cost shall be included in the cost of the Tenant
Improvements.
2. Landlord and Tenant acknowledge that the Delta 4 Plans do not
presently contain any specifications for the Common Area floor coverings, wall
coverings, lighting and other finishes (collectively "the Finishes"). The amount
budgeted for the Finishes is $250,000 and is included as part of Landlord's cost
for the Building Shell. Landlord shall determine and select the Finishes,
subject to Tenant's approval which shall not be unreasonably withheld or
delayed. In the event that the actual cost of installing the Finishes shall be
less than $250,000, then Tenant shall be entitled credit against Rent first due
under this Lease in the amount of such savings.
3. Landlord and Tenant acknowledge that the Delta 4 Plans show three
passenger elevators and one freight elevator. Landlord contemplates that
Landlord may eliminate one of the passenger elevators. To the extent Landlord
eliminates one of the passenger elevators, Tenant shall be entitled to credit
against Rent due under this Lease in an amount equal to Tenant's Proportionate
Share of the savings derived by Landlord by deleting such elevator.
4. Tenant and Landlord acknowledge that the Delta 4 Plans show a 4,000
amp electrical service for the Building. Landlord shall install an additional
4,000 amp service to the Building (i.e., total 8,000 amp service shall be
installed) and the cost of such additional 4,000 amp service shall be included
as part of the cost of the Tenant Improvements.
C-5
<PAGE> 58
SCHEDULE C-2
EXTERIOR STORAGE
- Hazardous Substances Storage Room
- Nitrogen Storage Tank (at least fifteen (15) feet tall)
C-6
<PAGE> 59
EXHIBIT D
MORTGAGES CURRENTLY AFFECTING THE PROPERTY
Landlord shall provide the name and address of Landlord's lender
promptly after Landlord's acquisition of fee title to the Property.
D-1
<PAGE> 60
EXHIBIT E
COMMENCEMENT DATE CONFIRMATION
Landlord: ___________________, a ________________
Tenant: CombiChem, Inc., a Delaware corporation
This Commencement Date Confirmation is made by Landlord and Tenant
pursuant to that certain Lease dated as of _________, 1999 (the "Lease") for the
________________ floors in the building commonly known as Building __ of the Sun
Road Corporate Center (the "Premises"). This Confirmation is made pursuant to
Items 4 and 9 of the Schedule to the Lease.
1. Lease Commencement Date, Termination Date. Landlord and Tenant hereby
agree that the Commencement Date of the Lease is _____________, 1999, and the
Termination Date of the Lease is _______________, _____.
2. Acceptance of Premises. Tenant has inspected the Premises and affirms
that the Premises is acceptable in all respects in its current "as is"
condition.
3. Rentable Area. The Rentable Area of the Premises is ______________.
4. Incorporation. This Confirmation is incorporated into the Lease, and
forms an integral part thereof. This Confirmation shall be construed and
interpreted in accordance with the terms of the Lease for all purposes.
TENANT:
CombiChem, Inc., a Delaware corporation
By:
-------------------------------------
Name:
-------------------------------------
Title:
-------------------------------------
By:
-------------------------------------
Name:
-------------------------------------
Title:
-------------------------------------
E-1
<PAGE> 61
LANDLORD:
LMC-SHOREHAM INVESTMENT COMPANY, LLC, a
California limited liability company
By:
-------------------------------------
Print Name:
-------------------------------
Print Title:
-------------------------------
CONVOY COURT INVESTMENT COMPANY, LLC, a
California limited liability company
By:
-------------------------------------
Print Name:
-------------------------------
Print Title:
-------------------------------
E-2
<PAGE> 62
EXHIBIT F
SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT
RECORDING REQUESTED BY, AND )
WHEN RECORDED, RETURN TO: )
)
Brobeck, Phleger & Harrison )
550 West "C" Street, Suite 1300 )
San Diego, California 92101 )
(619) 234-1966 )
Attn: W. Scott Biel, Esq. )
)
- --------------------------------------------------------------------------------
(Space Above for Recorder's Use)
SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT
THIS AGREEMENT (this "Agreement") is made and entered into this ____ day
of ___________, 1999, by and among (1) COMBICHEM, a Delaware corporation
("Tenant"), (2) ________________________ ("Lender") and (3) LMC-SHOREHAM
INVESTMENT COMPANY, LLC, a California limited liability company, and CONVOY
COURT INVESTMENT COMPANY, LLC, a California limited liability company, as
tenants in common ("Landlord").
R E C I T A L S:
WHEREAS, Landlord executed a Lease (the "Lease") dated as of February
__, 1999, in favor of Tenant, covering a certain demised premises therein
described which are (1) commonly known as __________________________________
California _______ ("the Demised Premises") and (2) a portion of certain real
property legally described as:
(said parcel of real estate being referred to herein as the "Property"); and
WHEREAS, Landlord has executed a Deed of Trust (the "Mortgage") dated
___________________, in the amount of $____________ and recorded on ____________
19___, as Document No. _________________ of the County Records of San Diego
County, State of California, in favor of Lender, payable upon the terms and
conditions described therein; and
F-1
<PAGE> 63
WHEREAS, it is a condition to said loan that said Mortgage shall
unconditionally be and remain at all times a lien or charge upon the Property,
prior and superior to the Lease and to the leasehold estate created thereby; and
WHEREAS, the parties hereto desire to assure Tenant's possession and
control of the Demised Premises under the Lease upon the terms and conditions
therein contained;
NOW, THEREFORE, for and in consideration of the mutual covenants and
premises herein and other good and valuable consideration, the receipt and
sufficiency of which is hereby acknowledged and confessed by the parties hereto,
the parties hereto do hereby agree as follows:
A G R E E M E N T:
1. Subject to the non-disturbance covenants set forth herein, the Lease
is and shall be subordinate to the Mortgage, and to all renewals, modifications,
consolidations, replacements and extensions thereof, and to all future advances
made thereunder.
2. Should Lender become the owner of the Property, or should the
Property be sold by reason of foreclosure, or other proceedings brought to
enforce the Mortgage which encumbers the Property, or should the Property be
transferred by deed in lieu of foreclosure, or should any portion of the
Property be sold under a trustee's sale, the Lease shall continue in full force
and effect as a direct lease between the then owner of the Property covered by
the Mortgage and Tenant, upon, and subject to, all of the terms, covenants and
conditions of the Lease for the balance of the term thereof remaining, including
any extensions therein provided. Tenant does hereby agree to attorn to Lender or
to any such owner as its landlord after Tenant's receipt of written notice from
Lender, and Lender hereby agrees that it will accept such attornment.
3. Notwithstanding any other provision of this Agreement, Lender shall
not be (a) liable for any default of any landlord under the Lease (including
Landlord), except that Lender agrees to cure any default of Landlord that is
continuing as of the date Lender forecloses the Property, which shall be the
earliest to occur of (1) delivery of a trustee's deed following a non-judicial
foreclosure, (2) delivery of a marshal's deed upon sale of the property
following entry of judgment in a judicial foreclosure and/or (3) delivery of a
deed in lieu of foreclosure, within thirty (30) days from the date Tenant
delivers written notice to Lender of such continuing default, unless such
default is of such a nature to reasonably require more than thirty (30) days to
cure and then Lender shall be permitted such additional time as is reasonably
necessary to effect such cure, provided Lender commences such cure within such
30 day period and, thereafter, diligently and continuously proceeds to cure such
default; (b) subject to any offsets or defenses which have accrued prior to the
date of foreclosure as defined above, unless Tenant shall have delivered to
Lender written notice of the default which gave rise to such offset or defense
and permitted Lender the same right to cure such default as permitted Landlord
under the Lease; (c) bound by any rent that Tenant may have paid under the Lease
more than one month in advance; (d) bound by any amendment or modification of
the Lease hereafter made without Lender's prior written consent which shall be
Landlord's obligation to request and obtain; or (e) responsible for the return
of any security deposit delivered to Landlord under the Lease and not
subsequently received by Lender.
F-2
<PAGE> 64
4. If Lender sends written notice to Tenant to direct its rent payments
under the Lease to Lender instead of Landlord, then Tenant agrees to follow the
instructions set forth in such written instructions and deliver rent payments to
Lender; however, Landlord and Lender agree that Tenant shall be credited under
the Lease for any rent payments sent to Lender pursuant to such written notice.
5. All notices which may or are required to be sent under this Agreement
shall be in writing and shall be sent by Federal Express (or similar overnight
delivery service) or first-class, certified U.S. mail, postage prepaid, return
receipt requested, and sent to the party at the address appearing below or such
other address as any party shall hereafter inform the other party by written
notice given as set forth below:
TENANT: LANDLORD:
- -------------------------------- ------------------------------------
- -------------------------------- ------------------------------------
- -------------------------------- ------------------------------------
Attn: Attn:
--------------------------- -------------------------------
LENDER:
- --------------------------------
- --------------------------------
- --------------------------------
Attn:
---------------------------
6. The Mortgage shall encumber the Initial Improvements (as defined in
the Lease) but shall not encumber the Subsequent Improvements (as defined in the
Lease) or any other of Tenant's improvements, trade fixtures, furniture,
equipment or other personal property which, under the terms of the Lease, Tenant
is entitled to remove upon expiration or termination of the Lease. In the event
the Property or any part thereof shall be taken for public purposes by
condemnation or transfer in lieu thereof or the same are damaged or destroyed,
the rights of the parties to any condemnation award or insurance proceeds shall
be determined and controlled by the applicable provisions of the Lease.
7. This Agreement shall inure to the benefit of and be binding upon the
parties hereto, their successors in interest, heirs and assigns and any
subsequent owner of the Property secured by the Mortgage.
F-3
<PAGE> 65
IN WITNESS WHEREOF, the parties hereto have caused this Non-Disturbance
Agreement to be executed as of the day and year first above written.
LANDLORD: TENANT:
- -------------------------------- ------------------------------------
By: By:
---------------------------- --------------------------------
Its: Its:
---------------------------- --------------------------------
LENDER:
- --------------------------------
By:
----------------------------
Its:
----------------------------
F-4
<PAGE> 66
STATE OF CALIFORNIA )
) ss
COUNTY OF SAN DIEGO )
On ________________________, before me, ___________________________,
Notary Public, personally appeared __________________________________________,
personally known to me (or proved to me on the basis of satisfactory evidence)
to be the person(s) whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of which the person(s)
acted, executed the instrument.
WITNESS my hand and official seal.
[SEAL]
-------------------------------------
STATE OF CALIFORNIA )
) ss
COUNTY OF SAN DIEGO )
On ________________________, before me, ___________________________,
Notary Public, personally appeared __________________________________________,
personally known to me (or proved to me on the basis of satisfactory evidence)
to be the person(s) whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of which the person(s)
acted, executed the instrument.
WITNESS my hand and official seal.
[SEAL]
-------------------------------------
F-5
<PAGE> 67
STATE OF CALIFORNIA )
) ss
COUNTY OF SAN DIEGO )
On ________________________, before me, ___________________________,
Notary Public, personally appeared __________________________________________,
personally known to me (or proved to me on the basis of satisfactory evidence)
to be the person(s) whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of which the person(s)
acted, executed the instrument.
WITNESS my hand and official seal.
[SEAL]
-------------------------------------
STATE OF CALIFORNIA )
) ss
COUNTY OF SAN DIEGO )
On ________________________, before me, ___________________________,
Notary Public, personally appeared __________________________________________,
personally known to me (or proved to me on the basis of satisfactory evidence)
to be the person(s) whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of which the person(s)
acted, executed the instrument.
WITNESS my hand and official seal.
[SEAL]
-------------------------------------
F-6
<PAGE> 68
EXHIBIT G
FORM OF MEMORANDUM OF LEASE
RECORDING REQUESTED BY, AND )
WHEN RECORDED, RETURN TO: )
)
Brobeck, Phleger & Harrison )
550 West "C" Street, Suite 1300 )
San Diego, California 92101 )
(619) 234-1966 )
Attn: W. Scott Biel, Esq. )
)
- --------------------------------------------------------------------------------
(Space Above for Recorder's Use)
MEMORANDUM OF LEASE
THIS MEMORANDUM OF LEASE (this "Memorandum") is entered into as of the
____ day of ___________, 1999, by and among COMBICHEM, a Delaware corporation
("Tenant"), and LMC-SHOREHAM INVESTMENT COMPANY, LLC, a California limited
liability company, and CONVOY COURT INVESTMENT COMPANY, LLC, a California
limited liability company, as tenants in common ("Landlord").
Constructive Notice. This Memorandum is executed for the purpose of
providing constructive notice of the leasehold interest of Tenant in that
certain real property legally described on Exhibit A attached hereto and
incorporated herein (the "Real Property") pursuant to the terms of that certain
Lease between Landlord and Tenant, dated February __, 1999 (the "Lease"). Upon
the expiration or earlier termination of the Lease, Tenant shall execute such
documents as are necessary to evidence the termination or expiration of the
Lease, which obligation shall survive the expiration or earlier termination of
the Agreement.
Lease Term. The term of the Lease ("Term") shall be fifteen (15) years
subject to earlier termination as provided in the Lease.
Interpretation. This Memorandum is not a complete summary of the Lease.
The provisions of this Memorandum shall not be used in interpreting any
provision of the Lease. In the event of any conflict between the terms of the
Agreement and this Memorandum, the terms of the Agreement shall control.
Counterparts. This Memorandum may be executed in any number of
counterparts, each of which shall be deemed to be an original and all of which
together shall comprise but a single instrument.
G-1
<PAGE> 69
IN WITNESS WHEREOF, the parties executed this Memorandum as of the date
first above written.
LANDLORD: TENANT:
LMC-SHOREHAM INVESTMENT COMPANY, COMBICHEM, INC.
a California limited liability a Delaware corporation
company
LANDLORD:
By: By:
--------------------------- -------------------------------
Name: Name:
--------------------------- -------------------------------
Its: Its:
--------------------------- -------------------------------
CONVOY COURT INVESTMENT COMPANY,
a California limited liability company
By: By:
--------------------------- -------------------------------
Name: Name:
--------------------------- -------------------------------
Its: Its:
--------------------------- -------------------------------
G-2
<PAGE> 70
STATE OF CALIFORNIA )
) ss
COUNTY OF SAN DIEGO )
On ________________________, before me, ___________________________,
Notary Public, personally appeared __________________________________________,
personally known to me (or proved to me on the basis of satisfactory evidence)
to be the person(s) whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of which the person(s)
acted, executed the instrument.
WITNESS my hand and official seal.
[SEAL]
-------------------------------------
STATE OF CALIFORNIA )
) ss
COUNTY OF SAN DIEGO )
On ________________________, before me, ___________________________,
Notary Public, personally appeared __________________________________________,
personally known to me (or proved to me on the basis of satisfactory evidence)
to be the person(s) whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in his/her/their
authorized capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of which the person(s)
acted, executed the instrument.
WITNESS my hand and official seal.
[SEAL]
-------------------------------------
G-3
<PAGE> 71
EXHIBIT A
LEGAL DESCRIPTION OF PROPERTY
G-4
<PAGE> 72
EXHIBIT H
LANDLORD'S CONSENT TO ENCUMBRANCE
BY TENANT OF LEASEHOLD ESTATE
Recording requested )
by and when recorded )
return to: )
)
Brobeck, Phleger & Harrison LLP )
550 West "C" St., Suite 1200 )
San Diego, CA 92101 )
Attn: W. Scott Biel, Esq. )
)
- --------------------------------------------------------------------------------
Space above for recorder's use
LANDLORD'S CONSENT TO
ENCUMBRANCE BY TENANT OF LEASEHOLD ESTATE
This Landlord's Consent to Encumbrance by Tenant of Leasehold Estate is
prepared for the purpose of providing recorded notice of that certain Lease
dated February __, 1999 ("Lease") among LMC-SHOREHAM INVESTMENT COMPANY, LLC, a
California limited liability company, and CONVOY COURT INVESTMENT COMPANY, LLC,
a California limited liability company, as tenants in common ("Landlord"), and
COMBICHEM, INC., a Delaware corporation ("Tenant"), and for the benefit of
__________________________ ("Lender"), and is made with reference to the
following recitals:
A. The Lease affects certain real property more particularly described
in Exhibit "A" attached hereto and incorporated herein by this
reference. The real property leased by Landlord to Tenant under the
Lease is referred to below as the "Premises"; and
B. Tenant intends to obtain credit from Lender, and, as a condition of
such credit, Tenant is required to encumber its right, title, and
interest under the Lease to Lender as collateral for its obligations to
Lender, as well as to grant to Lender a security interest in personal
property that may from time to time be located on the Premises.
NOW, THEREFORE, for valuable consideration, the receipt and adequacy of
which hereby is acknowledged, Landlord agrees for the benefit of Lender as
follows:
1. The Lease is in full force and effect between Landlord and Tenant,
neither Landlord nor, to Landlord's actual knowledge, Tenant is in
default under the terms and conditions of the Lease and the term of the
Lease expires on _______________.
2. Landlord agrees that Lender may be added to the "Loss Payable
Endorsement" of any and all insurance policies required to be carried by
Tenant under the Lease and that all
H-1
<PAGE> 73
insurance proceeds may be used to restore the Premises in accordance
with the terms of the Lease.
3. Except when Lender is in possession of the Premises with respect to any
Lease or is the Tenant hereunder, Lender shall not have any liability or
obligation with regard to any of the covenants, conditions or terms of
such Lease, except to the extent expressly provided herein.
4. Any goods of Tenant (the "Goods," excluding therefrom (1) items that are
a part of the Premises such as heating and air-conditioning appliances
and ducts, electrical wiring, pipes, conduits, window coverings, walls,
partitions, structural components, and the like, and (2) those items
which are owned by Landlord pursuant to the Lease, including the Initial
Improvements (as such term is defined in the Lease) but otherwise
including all "goods" as defined in the Uniform Commercial Code) shall
be and remain personal property notwithstanding the manner of their
annexation to the Premises, their adaptability to the uses and purposes
for which the Premises are used, or the intentions of the party making
the annexation.
5. Landlord hereby waives any rights which Landlord may claim to have in
and to the Goods, no matter how arising, including all rights of levy or
distraint for rent.
6. Landlord consents to the location or installation of the Goods on the
Premises, agrees that Lender may do to and with the Goods any or all of
the acts below enumerated, and grants Lender a right, as set forth
below, to enter into possession of the Premises to do any or all of the
following (the "Permitted Actions") with respect to the Goods: assemble,
have appraised, display, sever, remove, maintain, prepare for sale or
lease, advertise, inspect, repair, lease, transfer, and/or sell (at
public auction or private sale). With respect to any Lease, Lender shall
have the right and license to enter into and to occupy the Premises
affected by such Lease, for the purposes described above, for an actual
occupancy period of up to sixty (60) days (at Lender's discretion),
following abandonment or surrender of the Premises by Borrower, whether
voluntary or involuntary. Lender shall pay Landlord, periodically in
advance, a per diem occupancy fee equivalent to the monthly rental
provided for in such Lease divided by thirty (30) for actual days of
occupancy by Lender. Any extensions of the foregoing period shall be
with the written consent of Landlord and at the same rate. All physical
damage to the Premises caused by the removal of the Goods shall be
reimbursed or repaired by Lender at its expense.
7. Landlord acknowledges that at any time prior to abandonment or surrender
of the Premises by Borrower, Lender may take any or all of the Permitted
Actions subject to Lender's agreements with Borrower.
8. Any notice required herein to be given to Lender shall be deemed to be
given three days after deposit in the United States mail, postage
prepaid to:
[INSERT ADDRESS OF LENDER]
H-2
<PAGE> 74
With a copy to:
[INSERT APPROPRIATE ADDRESS]
or to such other address as may be designated by Lender or its successors or
assigns in the manner herein provided for giving notice.
Dated as of ________________________.
LANDLORD: TENANT:
LMC-SHOREHAM INVESTMENT COMPANY, COMBICHEM, INC.
a California limited liability a Delaware corporation
company
By: By:
-------------------------- ------------------------------
Name: Name:
-------------------------- ------------------------------
Title: Title:
-------------------------- ------------------------------
CONVOY COURT INVESTMENT COMPANY,
a California limited liability company
By:
--------------------------
Name:
--------------------------
Title:
--------------------------
H-3
<PAGE> 75
EXHIBIT "A"
LEGAL DESCRIPTION OF THE LAND
AFFECTED BY THE LEASE
Lot 2 of Nexus Technology Centre Unit No. 1, in the City of San Diego, County of
San Diego, State of California, according to Map thereof No. 11876, filed in the
Office of the County Recorder of San Diego County, August 7, 1987.
H-4
<PAGE> 76
EXHIBIT I
ENVIRONMENTAL ASSESSMENT CRITERIA
For purposes of compliance with the requirements of Section 27D of the
Lease, the term "Assessment Criteria" with respect to the Premises shall refer
to, and include, the following studies and assessments:
1. Phase I Assessment consistent with the American Society for
Testing Materials (ASTM) Standard E-1527 which shall, by its
terms, allow Landlord and Tenant to rely upon its conclusions.
2. Interior Site Assessment consisting of a visual inspection of all
surfaces (floors, walls, ceiling tiles, benches, interior of
cabinets and fume hoods) for signs of contamination and
deterioration. Visual inspection of all bench and hood sinks and
readily accessible drain lines for signs of deterioration, loss
of integrity and leakage. The Interior Site Assessment shall
include detailed written documentation of all observations and
dated photos to document the existing condition thereof.
3. Wastewater Collection System Assessment consisting of a flush and
clean-out of all discharge piping and traps with observation of
effluent during the clean-out. Videotaping of the Wastewater
Collection System shall be required along with a written report
for each ten foot (10") piping segment.
4. In order to verify that there is no contamination of the
laboratory hoods and exhaust system, an inspection shall be made
consisting of an inspection of the laboratory hoods and exhaust
system with detailed documentation of all observances, including
without limitation, observed solids, liquids, odors or Hazardous
Materials entrapment. Such inspection shall include inspection of
the roof area to determine the existence of any deterioration
from condensation of hazardous materials in the exhaust system.
<PAGE> 1
EXHIBIT 10.69
THE TRANSFER OF THIS WARRANT IS SUBJECT TO
RESTRICTIONS CONTAINED HEREIN. THIS WARRANT
HAS BEEN ISSUED IN RELIANCE UPON THE
REPRESENTATION OF THE HOLDER THAT IT HAS BEEN
ACQUIRED FOR INVESTMENT PURPOSES AND NOT WITH
A VIEW TOWARD THE RESALE OR OTHER DISTRIBUTION
THEREOF. NEITHER THIS WARRANT NOR THE SHARES
ISSUABLE UPON THE EXERCISE OF THIS WARRANT,
HAVE BEEN REGISTERED UNDER THE SECURITIES
ACT OF 1933 OR ANY STATE SECURITIES LAWS.
COMBICHEM, INC.
COMMON STOCK PURCHASE WARRANT
To Subscribe for and Purchase February 23, 1999
Shares of Common Stock
of COMBICHEM, INC.
VOID AFTER 5:00 P.M., PACIFIC TIME
FEBRUARY 22, 2006
THIS CERTIFIES that, for value received, Lee M. Chesnut, or his
registered assigns (the "Holder"), is entitled to subscribe for and purchase
from COMBICHEM, INC., a Delaware corporation (hereinafter called the
"Corporation"), up to ONE HUNDRED EIGHTY THOUSAND (180,000) shares (subject to
adjustment as hereinafter provided) of fully paid and non-assessable Common
Stock of the Corporation, (the "Common Stock"), at $8.00 per share (subject to
adjustment as hereinafter provided and hereinafter called the "Warrant Price"),
at any time from the Commencement Date, as defined in that certain Lease dated
as of February 23, 1999 by and between the Corporation and LMC-Shoreham
Investment Company, LLC and Convoy Court Investment Company, LLC, but at or
prior to 5:00 p.m. Pacific time on February 22, 2006 (the "Exercise Period"),
subject however, to the provisions and upon the terms and conditions hereinafter
set forth.
This Warrant and any Warrant or Warrants subsequently issued upon
exchange or transfer hereof are hereinafter collectively called the "Warrant."
Section 1. Exercise of Warrant. The rights represented by this Warrant
may be exercised by the Holder, in whole or in part (but not as to fractional
shares) at any time or from time to time in part, but not as to a fractional
share of Common Stock, by the completion of the purchase form attached hereto
and by the surrender of this Warrant (properly endorsed) at the office of the
Corporation specified herein for notice purposes (as the same may be modified
pursuant to Section 10), and by payment to the Corporation of the Warrant Price
in cash or by certified or official bank check, for each share being purchased.
In the event of any exercise of
<PAGE> 2
the rights represented by this Warrant, a certificate or certificates for the
shares of Common Stock so purchased, registered in the name of the Holder, or
its nominee or other party designated in the purchase form by the Holder hereof,
shall be delivered to the Holder within a reasonable time after the date on
which the rights represented by this Warrant shall have been so exercised (the
Corporation shall order such certificates from the transfer agent within three
(3) business days of such exercise date and shall use reasonable best efforts to
cause the transfer agent to deliver such certificates to Holder as soon as
possible); and, unless this Warrant has expired or has been exercised in full, a
new Warrant representing the number of shares (except a remaining fractional
share), if any, with respect to which this Warrant shall not then have been
exercised shall also be issued to the Holder within such time. The person in
whose name any certificate for shares of Common Stock is issued upon exercise of
this Warrant shall for all purposes be deemed to have become the Holder of
record of such shares on the date on which this Warrant was surrendered together
with payment of the Warrant Price. No fractional shares shall be issued upon
exercise of this Warrant. If any fractional interest in a share of Common Stock
would, except for the provision of this Section 1, be delivered upon such
exercise, the Corporation, in lieu of delivery of a fractional share thereof,
shall pay to the Holder an amount in cash equal to the current market price of
such fractional share as determined in good faith by the Board of Directors of
the Corporation (the "Board").
Section 2. Net Issuance.
(a) Right to Convert. In addition to and without limiting
the rights of the Holder under the terms of this Warrant, the Holder shall have
the right to convert this Warrant or any portion thereof (the "Conversion
Right") into shares of Common Stock as provided in this Section 2 at any time or
from time to time during the Exercise Period. Upon exercise of the Conversion
Right with respect to a particular number of shares subject to the Warrant (the
"Converted Warrant Shares"), the Corporation shall deliver to the Holder
(without payment by the Holder of any exercise price or any cash or other
consideration) that number of shares of fully paid and nonassessable Common
Stock computed using the following formula:
X = Y (A - B)
-------
A
Where X = the number of shares of Common Stock to be delivered
to the Holder
Y = the number of Converted Warrant Shares
A = the fair market value of one share of the Corporation's
Common Stock on the Conversion Date (as defined below)
B = the per share exercise price of the Warrant (as adjusted
to the Conversion Date, if applicable, as provided herein)
The Conversion Right may only be exercised with respect to a whole number of
shares subject to the Warrant. No fractional shares shall be issuable upon
exercise of the Conversion Right, and if the number of shares to be issued
determined in accordance with the foregoing formula is other than a whole
number, the Corporation shall pay to the Holder an amount in cash equal to the
fair market value of the resulting fractional share on the Conversion Date (as
defined below). Shares
2
<PAGE> 3
issued pursuant to the Conversion Right shall be treated as if they were issued
upon the exercise of the Warrant.
(b) Method of Exercise. The Conversion Right may be
exercised by the Holder by the surrender of the Warrant at the principal office
of the Corporation together with a written statement specifying that the Holder
thereby intends to exercise the Conversion Right and indicating the total number
of shares under the Warrant that the Holder is exercising through the Conversion
Right. Such conversion shall be effective upon receipt by the Corporation of the
Warrant together with the aforesaid written statement, or on such later date as
is specified therein (the "Conversion Date"). Certificates for the shares
issuable upon exercise of the Conversion Right and, if applicable, a new warrant
evidencing the balance of the shares remaining subject to the Warrant, shall be
issued as of the Conversion Date and shall be delivered to the Holder promptly
following the Conversion Date. The Corporation shall order such certificates
from the transfer agent within three (3) business days of the Conversion Date
and shall use reasonable best efforts to cause the transfer agent to deliver
such certificates to Holder as soon as possible.
(c) Determination of Fair Market Value. For purposes of this
Section 2, fair market value of a share of Common Stock on the Conversion Date
shall mean:
(i) If traded on a stock exchange, the fair market
value of the Common Stock shall be deemed to be the average of the closing
selling prices of the Common Stock on the stock exchange determined by the Board
to be the primary market for the Common Stock over the ten (10) trading day
period (or such shorter period immediately following the closing of an initial
public offering) ending on the date prior to the Conversion Date, as such prices
are officially quoted in the composite tape of transactions on such exchange;
(ii) If traded over-the-counter, the fair market
value of the Common Stock shall be deemed to be the average of the closing bid
prices (or, if such information is available, the closing selling prices) of the
Common Stock over the ten (10) trading day period (or such shorter period
immediately following the closing of an initial public offering) ending on the
date prior to the Conversion Date, as such prices are reported by the National
Association of Securities Dealers through its NASDAQ system or any successor
system; and
(iii) If at any time the Common Stock is not listed on
any securities exchange or quoted on the NASDAQ System or the over-the-counter
market, the fair market value of the Common Stock shall be the highest price per
share which the Corporation could obtain from a willing buyer (not a current
employee or director) for shares of the Common Stock sold by the Corporation,
from authorized but unissued shares, as determined in good faith by its Board of
Directors (and promptly upon any request therefor by the Holder), unless the
Corporation shall become subject to a merger, acquisition or other consolidation
pursuant to which the Corporation is not the surviving party, in which case the
fair market value of the Common Stock shall be deemed to be the value received
by the holders of the Corporation's Common Stock on a common stock equivalent
basis pursuant to such merger or acquisition.
Section 3. Adjustments and Covenants.
3
<PAGE> 4
(a) Split/Consolidation. In the event that the outstanding
shares of Common Stock shall be split, combined or consolidated, by dividend,
reclassification or otherwise, into a greater or lesser number of shares of
Common Stock, the Warrant Price in effect immediately prior to such combination
or consolidation and the number of shares purchasable under this Warrant shall,
concurrently with the effectiveness of such combination or consolidation, be
proportionately adjusted.
(b) Merger or Sale. If there shall be effected any
consolidation or merger of the Corporation with another corporation, or a sale
of all or substantially all of the Corporation's assets to another corporation,
and if the holders of Common Stock shall be entitled pursuant to the terms of
any such transaction to receive stock, securities or assets with respect to or
in exchange for Common Stock, then, as a condition of such consolidation, merger
or sale, lawful and adequate provisions shall be made whereby the Holder of this
Warrant shall thereafter have the right to receive, upon the basis and upon the
terms and conditions specified herein and in lieu of the shares of Common Stock
immediately theretofore receivable upon the exercise of such Warrant, such
shares of stock, securities or assets as may be issuable or payable with respect
to or in exchange for a number of outstanding shares of such Common Stock equal
to the number of shares of such Common Stock immediately theretofore so
receivable had such consolidation, merger or sale not taken place, and in any
such case appropriate provisions shall be made with respect to the rights and
interests of the Holder to the end that the provisions hereof shall thereafter
be applicable, as nearly as may be, in relation to any shares of stock,
securities or assets thereafter deliverable upon the exercise of this Warrant.
(c) Dividends or Distributions. If the Corporation shall
declare a dividend or distribution payable to holders of the Common Stock
(whether payable in cash, securities or other assets of the Corporation), then
upon any exercise of this Warrant the Holder shall be entitled to receive, and
the Corporation shall promptly pay to the Holder, any such dividend(s) and/or
distribution(s) (as well as any other cash, securities or other assets which the
Holder would have received had it held any securities received in any such
dividend(s) and/or distribution(s)), also giving effect to the other provisions
of this Section 3.
(d) Notice of Adjustment. Promptly following any adjustment
of the per share exercise price of the Warrant or the number or type of
securities issuable upon the exercise of this Warrant, the Corporation shall
give written notice thereof to the Holder, which notice shall advise, in
reasonable detail, regarding any such adjustment (including the method of
calculation and the facts upon which such calculation is based).
(e) Stock to Be Reserved. The Corporation will at all times
reserve and keep available out of its authorized Common Stock, solely for the
purpose of issue upon the exercise of this Warrant as herein provided, such
number of shares of Common Stock as shall then be issuable upon the exercise of
this Warrant. The Corporation shall from time to time in accordance with
applicable law increase the authorized amount of its Common Stock if at any time
the number of shares of Common Stock remaining unissued and available for
issuance shall not be sufficient to permit exercise of this Warrant. The
Corporation covenants that all shares of Common Stock which shall be so issued
shall be duly and validly issued and fully paid and nonassessable and free from
all taxes, liens and charges with respect to the issue thereof, and, without
limiting the generality of the foregoing, the Corporation will take all such
action as may
4
<PAGE> 5
be necessary to assure that all such shares of Common Stock may be so issued
without violation of any applicable law or regulation, or of any requirements of
any national securities exchange or interdealer quotation system upon which
shares of capital stock of the Corporation may be listed or quoted.
(f) Issue Tax. The issuance of certificates for shares of
Common Stock upon exercise of this Warrant shall be made without charge to the
Holders of this Warrant for any issuance tax in respect thereof provided that
the Corporation shall not be required to pay any tax which may be payable in
respect of any transfer involved in the issuance and delivery of any certificate
in a name other than that of the Holder of this Warrant.
(g) Closing of Books. The Corporation will at no time close
its transfer books against the transfer of the shares of Common Stock issued or
issuable upon the exercise of this Warrant in any manner which interferes with
the timely exercise of this Warrant.
(h) Listed. Prior to the issuance of any securities upon an
exercise of this Warrant, the Corporation shall secure the listing or quotation
of such securities upon each national securities exchange or automated quotation
system, if any, upon which shares of such securities are then listed or traded
(subject to official notice of issuance upon exercise of this Warrant) and shall
maintain, so long as any other shares of such securities shall be so listed or
traded, such listing or quotation of all securities from time to time issuance
upon the exercise of this Warrant.
(i) Public Reporting. With a view to making available to the
Holder the benefits of Rule 144 ("Rule 144") promulgated under the Securities
Act of 1933, as amended (the "Securities Act"), and any other rule or regulation
of the Securities and Exchange Commission (the "SEC") that may at any time
permit the Holder to sell securities of the Corporation to the public without
registration, the Corporation agrees that, for so long as a class of its
securities is registered under Section 12 of the Securities Exchange Act of
1934, as amended (the "Exchange Act"), the Corporation will: (i) make and keep
public information available, as those terms are understood and defined in Rule
144, at all times; and (ii) file with the SEC in a timely manner all reports and
other documents required of the Corporation under the Securities Act and the
Exchange Act.
Section 4. Notices of Record Dates. In the event of
(1) any taking by the Corporation of a record of the holders
of any class of securities for the purpose of determining the holders thereof
who are entitled to receive any dividend or other distribution, or any right to
subscribe for, purchase or otherwise acquire any shares of stock of any class or
any other securities or property, or to receive any other right, or
(2) any capital reorganization of the Corporation, any
reclassification or recapitalization of the capital stock of the Corporation or
any transfer of all or substantially all the assets of the Corporation to or
consolidation or merger of the Corporation with or into any other entity, or
(3) any voluntary or involuntary dissolution, liquidation or
winding-up of the Corporation, then and in each such event the Corporation will
give notice to the Holder of this
5
<PAGE> 6
Warrant specifying (i) the date on which any such record is to be taken for the
purpose of such dividend, distribution or right and stating the amount and
character of such dividend, distribution or right, and (ii) the date on which
any such reorganization, reclassification, recapitalization, transfer,
consolidation, merger, dissolution, liquidation or winding-up is to take place,
and the time, if any is to be fixed, as of which the holders of record of Common
Stock will be entitled to exchange their shares of Common Stock for securities
or other property deliverable upon such reorganization, reclassification,
recapitalization, transfer, consolidation, merger, dissolution, liquidation or
winding-up. Such notice shall be given at least 10 days and not more than 90
days prior to the date therein specified. In addition to the notice requirements
above, the Corporation shall provide written notice to the Holder on or before
six months prior to the expiration date of this Warrant setting forth the
expiration date of this Warrant.
Section 5. No Shareholder Rights or Liabilities. This Warrant shall not
entitle the Holder hereof to any voting rights or, except as expressly provided
herein, other rights as a shareholder of the Corporation. No provision hereof,
in the absence of affirmative action by the Holder hereof to purchase shares of
Common Stock, and no mere enumeration hereon of the rights or privileges of the
Holder hereof, shall give rise to any liability of such Holder for the Warrant
Price or as a shareholder of the Corporation, whether such liability is asserted
by the Corporation or by creditors of the Corporation.
Section 6. Representations of Holder.
The Holder hereby represents and acknowledges to the Corporation that:
(1) this Warrant and the Common Stock issuable upon exercise
of this Warrant are "restricted securities" as such term is used in the rules
and regulations under the Securities Act and that such securities have not been
and will not be registered under the Securities Act or any state securities law,
and that such securities must be held indefinitely unless a transfer can be made
pursuant to appropriate exemptions;
(2) the Holder has read, and fully understands, the terms of
this Warrant set forth on its face and the attachments hereto, including the
restrictions on transfer contained herein;
(3) the Holder has either a pre-existing personal or
business relationship with the Corporation or one of its officers, directors or
controlling persons;
(4) the Holder is purchasing for investment for its own
account and not with a view to or for sale in connection with any distribution
of this Warrant or the Common Stock of the Corporation issuable upon exercise of
this Warrant and it has no intention of selling such securities in a public
distribution in violation of the federal securities laws or any applicable state
securities laws; provided that nothing contained herein will prevent Holder from
transferring such securities in compliance with the terms of this Warrant and
the applicable federal and state securities laws;
(5) the Holder is an "accredited investor" within the
meaning of paragraph (a) of Rule 501 of Regulation D promulgated by the
Securities and Exchange Commission (the
6
<PAGE> 7
"Commission") and an "excluded purchaser" within the meaning of Section 25102(f)
of the California Corporate Securities Law of 1968; and
(6) the Corporation may affix the following legend to
certificates for shares of Common Stock (or other securities) issued upon
exercise of this Warrant ("Warrant Shares"):
"These securities have not been registered under the Securities
Act of 1933, as amended. They may not be sold, offered for sale,
pledged or hypothecated in the absence of a registration
statement in effect with respect to the securities under such
Act or an opinion of counsel satisfactory to the Company that
such registration is not required or unless sold pursuant to
Rule 144 of such Act."
Section 7. Notice of Proposed Transfers. The Holder of this Warrant, by
acceptance hereof, agrees to comply in all respects with the provisions of this
Section 7. Prior to any proposed transfer of this Warrant or any Warrant Shares
(except in transactions in compliance with Rule 144), the Holder of such
securities shall give written notice to the Corporation of such Holder's
intention to effect such transfer. Each such notice shall describe the manner
and circumstances of the proposed transfer in sufficient detail, and shall be
accompanied (except in transactions in compliance with Rule 144) by either (i) a
written opinion of legal counsel who shall be reasonably satisfactory to the
Corporation addressed to the Corporation and reasonably satisfactory in form and
substance to the Corporation's counsel, to the effect that the proposed transfer
of the Warrant and/or Warrant Shares may be effected without registration under
the Securities Act, or (ii) a "no action" letter from the Commission to the
effect that the transfer of such securities without registration will not result
in a recommendation by the staff of the Commission that enforcement action be
taken with respect thereto, whereupon the Holder of such securities shall be
entitled to transfer such securities in accordance with the terms of the notice
delivered by the Holder to the Corporation. Each new certificate evidencing the
Warrant and/or Warrant Shares so transferred shall bear the appropriate
restrictive legend set forth in Section 6 above, except that such certificate
shall not bear such restrictive legend if, in the opinion of counsel for the
Corporation, such legend is not required in order to establish or assist in
compliance with any provisions of the Securities Act or any applicable state
securities laws.
Section 8. Lost, Stolen, Mutilated or Destroyed Warrant. If this Warrant
is lost, stolen, mutilated or destroyed, the Corporation shall, on such terms as
to indemnity or otherwise as it may in its discretion reasonably impose (which
shall, in the case of a mutilated Warrant, include the surrender thereof), issue
a new Warrant of like denomination and tenor as the Warrant so lost, stolen,
mutilated or destroyed. Any such new Warrant shall constitute an original
contractual obligation of the Corporation, whether or not the allegedly lost,
stolen, mutilated or destroyed Warrant shall be at any time enforceable by
anyone.
Section 9. Presentment. Prior to due presentment of this Warrant
together with a completed assignment form attached hereto for registration of
transfer, the Corporation may deem and treat the Holder as the absolute owner of
the Warrant, notwithstanding any notation of ownership or other writing thereon,
for the purpose of any exercise thereof and for all other purposes.
7
<PAGE> 8
Section 10. Notice. Notice or demand pursuant to this Warrant shall be
sufficiently given or made, if sent by first-class mail, postage prepaid,
addressed, if to the Holder of this Warrant, to the Holder at its last known
address as it shall appear in the records of the Corporation, and if to the
Corporation, at 9050 Camino Santa Fe, San Diego, California 92121, Attention:
Secretary. The Corporation may alter the address to which communications are to
be sent by giving notice of such change of address in conformity with the
provisions of this Section 10 for the giving of notice.
Section 11. Governing Law. The validity, interpretation and performance
of this Warrant shall be governed by the laws of the State of California without
regard to principles of conflicts of laws.
Section 12. Successors. The terms of this Warrant shall be binding upon
the successors of the Corporation.
Section 13. Amendment. This Warrant may be modified, amended or
terminated by a writing signed by the Corporation and the Holder of this
Warrant.
Section 14. Severability. Should any part but not the whole of this
Warrant for any reason be declared invalid, such decision shall not affect the
validity of any remaining portion, which remaining portion shall remain in force
and effect as if this Warrant had been executed with the invalid portion thereof
eliminated, and it is hereby declared the intention of the parties hereto that
they would have executed the remaining portion of this Warrant without including
therein any such part which may, for any reason, be hereafter declared invalid.
Section 15. Termination. In the event the Commencement Date, as defined
in that certain Lease dated as of February 23, 1999 by and between the
Corporation and LMC-Shoreham Investment Company, LLC and Convoy Court Investment
Company, LLC, does not occur on or before June 30, 2000, this Warrant shall
terminate and be deemed null and void, without the need of further action by the
Corporation or the Holder.
[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]
8
<PAGE> 9
IN WITNESS WHEREOF, the Corporation has caused this Warrant to be duly
executed and delivered on and as of the day and year first above written by one
of its officers thereunto duly authorized.
COMBICHEM, INC., a Delaware corporation
Dated: _____2-23_________ ____, 1999 By: /S/ Karin Eastham
-------------------------------------
Karin Eastham
Vice President, Finance and
Administration and
Chief Financial Officer
The undersigned Holder agrees and accepts this Warrant and acknowledges
that it has read and confirms each of the representations contained in Section
6.
/s/ Lee M. Chesnut
----------------------------------------
LEE M. CHESNUT
Address:
9627 Grossmont Summit Drive
----------------------------------------
La Mesa CA 91941
----------------------------------------
----------------------------------------
[SIGNATURE PAGE TO COMBICHEM COMMON STOCK
PURCHASE WARRANT]
<PAGE> 10
PURCHASE FORM
(To be executed by the Warrant Holder if he desires to exercise the Warrant in
whole or in part)
To: COMBICHEM, INC.
The undersigned, whose Social Security or other identifying number is
______________, hereby irrevocably elects the right of purchase represented by
the within Warrant for, and to purchase thereunder, ____________________ shares
of securities provided for therein and tenders payment herewith to the order of
COMBICHEM, INC.
in the amount of
$___________
The undersigned requests that certificates for such shares be issued as follows:
Name:
---------------------------------------
Address:
-------------------------------------
Deliver to:
---------------------------------
Address:
------------------------------------
and, if said number of shares shall not be all the shares purchasable hereunder,
that a new Warrant for the balance remaining of the shares purchasable under the
within Warrant be registered in the name of, and delivered to, the undersigned
at the address stated below
Address:
------------------------------------
Dated: ________________ ____, _____
Signature.
------------------------------
(Signature must conform in all respects
to the name of the Warrant Holder as
specified on the face of the Warrant,
without alteration, enlargement or any
change whatsoever)
<PAGE> 11
ASSIGNMENT
(To be executed by the Warrant Holder if he desires to effect a transfer of the
Warrant)
FOR VALUE RECEIVED, the undersigned hereby sells, assigns and transfers
unto ______________________________ whose Social Security or other
identification number is ______________________________ [residing/located] at
______________________________ the attached Warrant, and appoints
__________________________ residing at ______________________________ the
undersigned's attorney-in-fact to transfer said Warrant on the books of the
Corporation, with full power of substitution in the premises.
Dated: ________________ ____, _____
In the presence of:
- ----------------------------------- ----------------------------------------
(Signature must conform in all respects
to the name of the Warrant Holder as
specified on the face of the Warrant,
without alteration, enlargement or any
change whatsoever).
<TABLE> <S> <C>
<ARTICLE> 5
<LEGEND>
THIS SCHEDULE CONTAINS SUMMARY FINANCIAL INFORMATION EXTRACTED FROM THE
CONDENSED FINANCIAL STATEMENTS AS OF AND FOR THE THREE MONTHS ENDED MARCH 31,
1999 (UNAUDITED) AND IS QUALIFIED IN ITS ENTIRETY BY REFERENCE TO SUCH FORM 10-Q
FOR THE QUARTERLY PERIOD ENDED MARCH 31, 1999.
</LEGEND>
<S> <C>
<PERIOD-TYPE> 3-MOS
<FISCAL-YEAR-END> DEC-31-1999
<PERIOD-START> JAN-01-1999
<PERIOD-END> MAR-31-1999
<CASH> 28,245
<SECURITIES> 0
<RECEIVABLES> 1,378
<ALLOWANCES> 0
<INVENTORY> 0
<CURRENT-ASSETS> 31,235
<PP&E> 11,296
<DEPRECIATION> 3,467
<TOTAL-ASSETS> 40,020
<CURRENT-LIABILITIES> 8,760
<BONDS> 0
0
0
<COMMON> 13
<OTHER-SE> 27,389
<TOTAL-LIABILITY-AND-EQUITY> 40,020
<SALES> 0
<TOTAL-REVENUES> 2,918
<CGS> 0
<TOTAL-COSTS> 5,850
<OTHER-EXPENSES> 0
<LOSS-PROVISION> 0
<INTEREST-EXPENSE> 220
<INCOME-PRETAX> (3,137)
<INCOME-TAX> 0
<INCOME-CONTINUING> (3,137)
<DISCONTINUED> 0
<EXTRAORDINARY> 0
<CHANGES> 0
<NET-INCOME> (3,137)
<EPS-PRIMARY> (0.24)
<EPS-DILUTED> (0.24)
</TABLE>
