<PAGE>
EXHIBIT 10.03
Lease between
Ellis-Middlefield Business Park
And
VeriSign, Inc.
Building 4
575 East Middlefield Road
Page i
<PAGE>
Lease between
Ellis-Middlefield Business Park and VeriSign, Inc.
Building 4 - 575 East Middlefield Road
[LOGO OF SOBRATO DEVELOPMENT COMPANIES]
<TABLE>
<CAPTION>
Section Page #
<S> <C>
Parties................................................................. 1
Premises................................................................ 1
Definitions.......................................................... 1
Description.......................................................... 1
Recordation of Parcel Map............................................ 1
Building 4 Development Approval...................................... 1
Use..................................................................... 2
Permitted Uses....................................................... 2
Uses Prohibited...................................................... 2
Advertisements and Signs............................................. 3
Covenants, Conditions and Restrictions............................... 3
Term and Rental......................................................... 3
Base Monthly Rent.................................................... 3
Late Charges......................................................... 3
Security Deposit..................................................... 4
Construction............................................................ 5
Building Shell Construction.......................................... 5
Tenant Improvement Construction...................................... 5
Pricing.............................................................. 6
Change Orders........................................................ 6
Building Shell Costs................................................. 6
Tenant Improvement Costs............................................. 6
Force Majeure........................................................ 6
General Contractor Overhead & Profit................................. 7
Tenant Delays........................................................ 7
Insurance............................................................ 7
Punch List & Warranty................................................ 7
Other Work by Tenant................................................. 7
Landlord's Failure to Complete Construction.......................... 8
Acceptance of Possession and Covenants to Surrender..................... 8
Delivery and Acceptance.............................................. 8
Condition Upon Surrender............................................. 8
Failure to Surrender................................................. 9
Alterations and Additions............................................... 9
Tenant's Alterations................................................. 9
Free From Liens...................................................... 9
Compliance With Governmental Regulations............................. 10
Maintenance of Premises................................................. 10
Landlord's Obligations............................................... 10
</TABLE>
Page ii
<PAGE>
<TABLE>
<S> <C>
Tenant's Obligations................................................... 10
Common Area Cost Sharing............................................... 11
Waiver of Liability.................................................... 11
Hazard Insurance.......................................................... 11
Tenant's Use........................................................... 11
Landlord's Insurance................................................... 11
Tenant's Insurance..................................................... 11
Waiver................................................................. 12
Taxes..................................................................... 12
Utilities................................................................. 12
Toxic Waste and Environmental Damage...................................... 12
Tenant's Responsibility................................................ 12
Tenant's Indemnity Regarding Hazardous Materials....................... 13
Actual Release by Tenant............................................... 13
Environmental Monitoring............................................... 14
Landlord's Indemnity Regarding Hazardous Materials..................... 14
Tenant's Default.......................................................... 15
Remedies............................................................... 15
Right to Re-enter...................................................... 15
Abandonment............................................................ 15
No Termination......................................................... 16
Non-Waiver............................................................. 16
Performance by Landlord................................................ 16
Habitual Default....................................................... 16
Landlord's Liability...................................................... 17
Limitation on Landlord's Liability..................................... 17
Limitation on Tenant's Recourse........................................ 17
Indemnification of Landlord............................................ 17
Destruction of Premises................................................... 17
Landlord's Obligation to Restore....................................... 17
Limitations on Landlord's Restoration Obligation....................... 18
Condemnation.............................................................. 18
Assignment or Sublease.................................................... 18
Consent by Landlord.................................................... 18
Assignment or Subletting Consideration................................. 19
No Release............................................................. 19
Reorganization of Tenant............................................... 20
Permitted Transfers.................................................... 20
Effect of Default...................................................... 20
Conveyance by Landlord................................................. 20
Successors and Assigns................................................. 21
Option to Extend the Lease Term........................................... 21
Grant and Exercise of Option........................................... 21
Determination of Fair Market Rental.................................... 21
Resolution of a Disagreement over the Fair Market Rental............... 22
Personal to Tenant..................................................... 22
General Provisions........................................................ 22
Attorney's Fees........................................................ 22
Authority of Parties................................................... 22
</TABLE>
Page iii
<PAGE>
<TABLE>
<S> <C>
Brokers................................................................ 23
Choice of Law.......................................................... 23
Dispute Resolution..................................................... 23
Entire Agreement....................................................... 24
Entry by Landlord...................................................... 24
Estoppel Certificates.................................................. 24
Exhibits............................................................... 24
Interest............................................................... 24
No Presumption Against Drafter......................................... 25
Notices................................................................ 25
Property Management.................................................... 25
Rent................................................................... 25
Representations........................................................ 25
Rights and Remedies.................................................... 25
Severability........................................................... 25
Submission of Lease.................................................... 25
Subordination.......................................................... 25
Survival of Indemnities................................................ 26
Time................................................................... 26
Transportation Demand Management Programs.............................. 26
Waiver of Right to Jury Trial.......................................... 26
Recordation............................................................ 26
Right of First Offer to Purchase.......................................... 26
Grant and Exercise of Option........................................... 26
Exclusions............................................................. 27
EXHIBIT A - Premises, Building & Project.................................. 29
EXHIBIT A-1 - Premises, Building & Project................................ 30
EXHIBIT B - Draft Letter of Credit........................................ 31
EXHIBIT C - Building Shell Definition..................................... 31
EXHIBIT D - Building Plans and Specifications............................. 35
EXHIBIT E - Preliminary Schematic Design Drawings......................... 36
EXHIBIT F - Tenant Improvement Plans and Specifications................... 37
</TABLE>
Page iv
<PAGE>
[LETTERHEAD HEAD OF SOBRATO DEVELOPMENT COMPANIES]
1. PARTIES: THIS LEASE, is entered into on this 27 day of October, 2000
--
("Effective Date") between Ellis-Middlefield Business Park, a California Limited
Partnership, whose address is 10600 North De Anza Boulevard, Suite 200,
Cupertino, CA 95014 and VeriSign, Inc., a Delaware corporation, whose address is
1350 Charleston Road, Mountain View, California, 94043, hereinafter called
respectively Landlord and Tenant.
2. PREMISES:
A. Definitions.
i. Building 1. The term "Building 1" or "Building" shall mean that
single-story building consisting of 32,500 rentable square feet and all
improvements therein, shown as Building 1 on Exhibit "A", commonly known as 455
-----------
East Middlefield Road, Mountain View, California.
ii. Building 2. The term "Building 2" shall mean that 2-story
building consisting of 49,362 rentable square feet and all improvements therein,
shown as Building 2 on Exhibit "A", commonly known as 487 East Middlefield Road,
-----------
Mountain View, California.
iii. Building 3. The term "Building 3" shall mean that 2-story
building consisting of 49,362 rentable square feet and all improvements therein,
shown as Building 3 on Exhibit "A", commonly known as 501 East Middlefield Road,
-----------
Mountain View, California.
iv. Building 4. The term "Building 4" shall mean that 4-story
office building consisting of approximately 102,000 rentable square feet and all
improvements therein, which Landlord intends to construct in the location
labeled as Building 4 on Exhibit "A", commonly known as 575 East Middlefield
-----------
Road, Mountain View, California, and including parking at a ratio of 3.2 spaces
per 1,000 square feet of Building. As part of construction of Building 4,
Landlord shall demolish an existing single-story building of 28,800 square feet
currently encumbering the site.
v. Common Area. The term "Common Area" shall mean that certain real
property and all improvements thereon surrounding Building 1, Building 2,
Building 3, and Building 4, including all parking and landscaped areas as shown
on Exhibit "A".
vi. Project. The term "Project" shall mean that certain real property
currently consisting of three parcels (APN 160-052-16, 160-052-17, and 160-052-
20 respectively) totaling approximately 10.8 acres along East Middlefield Road
in Mountain View, California, and all improvements constructed thereon
consisting of Building 1, Building 2, Building 3, Building 4, and the Common
Area as shown in Exhibit "A".
-----------
vii. Premises. The term "Premises" shall mean Building 4 and the right
to use and obligation to maintain the Common Area. Tenant acknowledges
Landlord's right, subject to receipt of all necessary governmental approvals, to
and hereby consents to Landlord's construction of Building 4 and Common Area.
B. Grant: Landlord hereby leases the Premises to Tenant, and Tenant hires
the Premises from Landlord.
C. Recordation of New Parcel Map: Tenant consents to recordation by
Landlord of a new parcel map ("Parcel Map") that would combine the three
existing parcels currently comprising the Project into one larger parcel to
facilitate Landlord's development and construction of Building 4; provided,
however, that Landlord's failure to record the Parcel Map shall in no way
invalidate this Lease.
D. Building 4 Development Approval: The parties acknowledge that Landlord
is currently negotiating with the city of Mountain View ("City") to rezone the
Property and obtain a transit-oriented development ("TOD") permit for
construction of Building 4 and the Common
Page 1
<PAGE>
Area, generally consistent with Exhibit "A". As part of such permit approval,
-----------
Tenant agrees to: (i) participate in the Valley Transportation Authority's
("VTA") Eco-Pass program for employees of Tenant within the VTA service area;
(ii) provide transit subsidies as required by the City for employees of Tenant
outside the VTA service area; and (iii) otherwise work cooperatively with
Landlord and the City towards meeting Tenant-applicable requirements of TOD
permit approval. In the event Landlord, in spite of its reasonable best efforts,
is unable to obtain TOD approval to construct Building 4 as generally shown on
Exhibit "A" on or before March 31, 2001, this Lease shall in no way be
----------
invalidated; however, in such event, Landlord shall notify Tenant in writing and
the following changes to the Lease shall take effect sixty (60) days following
such notice: (i) Lease Exhibit "A" shall be superceded by the attached Exhibit
---------- -------
"A-1" and all references in the Lease to Exhibit "A" shall change to Exhibit "A-
----- ----------- -----------
1"; (ii) the definition of Building 4 in Lease Section 2.A.(iv) shall be changed
--
to read as follows: The term "Building 4" shall mean that existing single-story
building consisting of 28,800 rentable square feet and all improvements therein,
shown as Building 4 on Exhibit "A-1", commonly known as 575 East Middlefield
------------
Road, Mountain View, California, and including parking for approximately 105
cars; (iii) the amount of the Security Deposit required under the first sentence
of Section 4.C. below shall be reduced to Two Hundred Sixteen Thousand and
No/100 Dollars ($216,000.00); (iv) Exhibits "C", "D", "E", and "F" shall be
eliminated from this Lease; and (v) Section 5 below shall be entirely deleted
and the following substituted in its place: Prior to the Commencement Date
Landlord shall ensure that the existing Building and Building systems are in
good operating condition and repair including the foundation, structural
components, exterior walls, plumbing, HVAC, sprinklers, electrical (including
panels and outlets), doors (both shipping and personnel), roof structure and
membrane, exterior landscaping, irrigation and lighting, and parking lot. "Good
operating condition and repair" as used in this paragraph means that all of the
foregoing systems for which Landlord is responsible shall be fully operational
and functional for use for the purposes for which such systems were intended,
and there is no deferred maintenance required. Without limitation of the
foregoing: (i) the roof membrane shall be inspected by a reputable and licensed
roofing contractor or roofing inspector and repaired as necessary to put into
good operating condition and repair based on such inspection; (ii) the HVAC
system shall be inspected by a reputable and licensed HVAC contractor and
repaired as necessary to put into good operating condition and repair based on
such inspection, as evidenced by a report by such contractor; (iii) all windows
shall be washed inside and out, and there shall be no cracked or broken windows;
(iv) all burned out, discolored or broken lightbulbs, ballasts and lenses shall
be replaced; and (v) the parking lot shall be re-sealed and striped by a
reputable and licensed asphalt contractor provided, however, that Landlord shall
have sixty days from the Commencement Date to complete the parking lot re-
sealing and striping.
3. USE:
A. Permitted Uses: Tenant shall use the Premises as permitted under
applicable zoning laws only for the following purposes and shall not change the
use of the Premises without the prior written consent of Landlord: Office,
research and development, marketing, light manufacturing, data center, ancillary
storage and other incidental uses. Tenant shall use only the number of parking
spaces allocated to Tenant under this Lease. All commercial trucks and delivery
vehicles shall (i) be parked at the rear of the Building, (ii) loaded and
unloaded in a manner which does not interfere with the businesses of other
occupants of the Project, and (iii) permitted to remain within the Project only
so long as is reasonably necessary to complete the loading and unloading.
Landlord makes no representation or warranty that any specific use of the
Premises desired by Tenant is permitted pursuant to any Laws.
B. Uses Prohibited: Tenant shall not commit or suffer to be committed on
the Premises any waste, nuisance, or other act or thing which may disturb the
quiet enjoyment of any other tenant in or around the Premises, nor allow any
sale by auction or any other use of the Premises for an unlawful purpose. Tenant
shall not (i) damage or overload the electrical, mechanical or plumbing systems
of the Premises, (ii) attach, hang or suspend anything from the ceiling, walls
or columns of the building in excess of the load limits for which such items are
designed or set any load on the floor in excess of the load limits for which for
which the floor is designed, or (iii) generate
Page 2
<PAGE>
dust, fumes or waste products which create a fire or health hazard or damage the
Premises or any portion of the Project, including without limitation the soils
or ground water in or around the Project. No materials, supplies, equipment,
finished products or semi-finished products, raw materials or articles of any
nature, or any waste materials, refuse, scrap or debris, shall be stored upon or
permitted to remain on any portion of the Premises outside of the Building
without Landlord's prior approval, which approval may be withheld in its
reasonable discretion.
C. Advertisements and Signs: Tenant will not place or permit to be placed,
in, upon or about the Premises any signs in violation of the city and other
governing authority having jurisdiction. Tenant will not place or permit to be
placed upon the Premises any large prominent outdoor signs, advertisements or
notices without the written consent of Landlord as to type, size, design,
lettering, coloring and location, which consent will not be unreasonably
withheld. Any sign placed on the Premises shall be removed by Tenant, at its
sole cost, prior to the Expiration Date or promptly following the earlier
termination of the Lease, and Tenant shall repair, at its sole cost, any damage
or injury to the Premises caused thereby, and if not so removed, then Landlord
may have same so removed at Tenant's expense.
D. Covenants, Conditions and Restrictions: This Lease is subject to the
effect of (i) any covenants, conditions, restrictions, easements, mortgages or
deeds of trust, ground leases, rights of way of record and any other matters or
documents of record; and (ii) any zoning laws of the city, county and state
where the Building is situated (collectively referred to herein as
"Restrictions") and Tenant will conform to and will not violate the terms of any
such Restrictions.
4. TERM AND RENTAL:
A. Base Monthly Rent: The term ("Lease Term") shall be for one hundred
twenty (120) months, with a commencement date ("Commencement Date") of either:
(i) substantial completion of construction as determined pursuant to Section
5.B, estimated to occur on August 1 2002; or (ii) sixty (60) days following
Landlord's notice to Tenant pursuant to Section 2.D. above that Landlord is
unable to obtain timely TOD approval, and ending one hundred twenty (120) months
thereafter ("Expiration Date"). Notwithstanding the parties' agreement that the
Lease Term begins on the Commencement Date, this Lease and all of the
obligations of Landlord and Tenant shall be binding and in full force and effect
from and after the Effective Date. In addition to all other sums payable by
Tenant under this Lease, Tenant shall pay as base monthly rent ("Base Monthly
Rent") for the Premises an amount equal to the product derived by multiplying:
(i) the rentable square footage ("Rentable Square Footage") of the Premises; by
(ii) the per-square-foot rental rate for Buildings 2 and 3 as of the
Commencement Date. The Base Monthly Rent shall at all times during this Lease be
calculated by using the same per-square-foot rate and subject to the same
increases, and at the same time, as for Buildings 2 and 3.
Upon Substantial Completion of construction, the Building shall be measured by
Tenant's Architect (as defined in Section 5.B) from outside wall/glass to
outside wall/glass of each floor, without deductions, to arrive at the actual
"Rentable Square Footage". If the Rentable Square Footage differs from 102,000
square feet, the Base Monthly Rent due during the Lease Term shall be modified
so as to equal at all times during the Lease Term the product of (i) the
Rentable Square Footage; and (ii) the then price-per-square-foot rate for
Buildings 2 and 3.
Base Monthly Rent shall be due in advance on or before the first day of each
calendar month during the Lease Term. All sums payable by Tenant under this
Lease shall be paid to Landlord in lawful money of the United States of America,
without offset or deduction and without prior notice or demand, at the address
specified in Section 1 of this Lease or at such place or places as may be
designated in writing by Landlord during the Lease Term. Base Monthly Rent for
any period less than a calendar month shall be a pro rata portion of the monthly
installment. On or before the date that is forty-five (45) days prior to the
Commencement Date, Tenant shall pay to Landlord the Base Monthly Rent due for
the first month of the Lease.
B. Late Charges: Tenant hereby acknowledges that late payment by Tenant to
Landlord of Base Monthly Rent and other sums due hereunder will cause Landlord
to incur costs not contemplated by this Lease, the exact amount of which is
extremely difficult to
Page 3
<PAGE>
ascertain. Such costs include but are not limited to: administrative,
processing, accounting, and late charges which may be imposed on Landlord by the
terms of any contract, revolving credit, mortgage, or trust deed covering the
Premises. Accordingly, if any installment of Base Monthly Rent or other sum due
from Tenant shall not be received by Landlord or its designee within five (5)
business days after receipt by Tenant of written notice from Landlord that such
installment or sum was not received when due, Tenant shall pay to Landlord a
late charge equal to five (5%) percent of such overdue amount, which late charge
shall be due and payable on the same date that the overdue amount was due. The
parties agree that such late charge represents a fair and reasonable estimate of
the costs Landlord will incur by reason of late payment by Tenant, excluding
interest and reasonable attorneys' fees and costs. If any rent or other sum due
from Tenant remains delinquent for a period in excess of thirty (30) days then,
in addition to such late charge, Tenant shall pay to Landlord interest on any
rent that is not paid when due at the Agreed Interest Rate specified in Section
19.J following the date such amount became due until paid. Acceptance by
Landlord of such late charge shall not constitute a waiver of Tenant's default
with respect to such overdue amount nor prevent Landlord from exercising any of
the other rights and remedies granted hereunder. In the event that a late charge
is payable hereunder, whether or not collected, for four (4) consecutive
installments of Base Monthly Rent, then the Base Monthly Rent shall
automatically become due and payable quarterly in advance, rather than monthly,
notwithstanding any provision of this Lease to the contrary.
C. Security Deposit: On or before April 1, 2001, Tenant shall deposit with
Landlord the sum of Seven Hundred Eighty Thousand and No/100 Dollars
($780,000.00) ("Security "Deposit"). Landlord shall not be deemed a trustee of
the Security Deposit, may use the Security Deposit in business, and shall not be
required to segregate it from its general accounts. Tenant shall not be entitled
to interest on the Security Deposit. If Tenant defaults with respect to any
provisions of the Lease, including but not limited to the provisions relating to
payment of Base Monthly Rent or other charges, Landlord may, to the extent
reasonably necessary to remedy Tenant's default, use any or all of the Security
Deposit towards payment of the following: (i) Base Monthly Rent or other charges
in default; (ii) any other amount which Landlord may spend or become obligated
to spend by reason of Tenant's default including, but not limited to Tenant's
failure to restore or clean the Premises following vacation thereof. If any
portion of the Security Deposit is so used or applied, Tenant shall, within ten
(10) days after written demand from Landlord, deposit cash with Landlord in an
amount sufficient to restore the Security Deposit to its full original amount,
and shall pay to Landlord such other sums as necessary to reimburse Landlord for
any sums paid by Landlord. If Tenant shall be in either monetary default or
material non-monetary default more than four (4) times in any twelve (12) month
period, then the Security Deposit shall, within ten (10) days after demand by
Landlord, be increased by Tenant to an amount equal to three (3) times the Base
Monthly Rent. Tenant may not assign or encumber the Security Deposit without the
consent of Landlord. Any attempt to do so shall be void and shall not be binding
on Landlord. The Security Deposit shall be returned to Tenant within thirty (30)
days after the Expiration Date and surrender of the Premises to Landlord, less
any amount deducted in accordance with this Section, together with Landlord's
written notice itemizing the amounts and purposes for such deduction. In the
event of termination of Landlord's interest in this Lease, Landlord may deliver
or credit the Security Deposit to Landlord's successor in interest in the
Premises and thereupon be relieved of further responsibility with respect to the
Security Deposit.
Landlord agrees that in lieu of a cash Security Deposit, Tenant may deposit a
letter of credit ("Letter of Credit") substantially in the form attached hereto
as Exhibit "B". Landlord shall be entitled to draw against the Letter of Credit
-----------
at any time provided only that Landlord certifies to the issuer of the Letter of
Credit that Tenant is in default under the Lease. Tenant shall keep the letter
of credit in effect during the entire Lease Term, as the same may be extended,
plus a period of four (4) weeks after expiration of the Lease Term. At least
thirty (30) days prior to expiration of any Letter of Credit, the term thereof
shall be renewed or extended for a period of at least one (1) year. Tenant's
failure to so renew or extend the Letter of Credit shall be a material default
of this Lease by Tenant. In the event Landlord draws against the Letter of
Credit, Tenant shall replenish the existing Letter of Credit or cause a new
Letter of Credit to be
Page 4
<PAGE>
issued such that the aggregate amount of letters of credit available to Landlord
at all times during the Lease Term is the amount of the Security Deposit
originally required.
5. CONSTRUCTION:
A. Building Shell Construction: Landlord shall cause the Building Shell (as
defined on the Building Shell Definition attached as Exhibit "C") and certain
-----------
Building Core Improvements (as defined below) to be constructed by Landlord's
affiliated construction company, Sobrato Construction Corporation ("General
Contractor") in accordance with Building Shell plans and guideline
specifications prepared by Arctec Associates ("Landlord's Architect") which
shall be attached by May 15, 2001 as Exhibit "D" ("Building Shell Plans and
-----------
Specifications"), and which shall be generally consistent with the schematic
design drawings prepared by Landlord's Architect ("Preliminary Schematic Design
Drawings") and attached as Exhibit "E". The Building Shell Plans and
-----------
Specifications include certain elements of the Building core ("Building Core
Improvements") which is defined as those items typically associated in the
industry with an office building core including elevators, restrooms, fire
sprinklers, HVAC and electrical systems distributed to each floor, exiting stair
finishes, and a finished building lobby. Although certain Building Core
Improvements have been designed by Landlord's Architect and incorporated into
the Building Shell Plans and Specifications, it is understood and agreed that
Building Core Improvements are classified as part of Tenant Improvements and all
costs associated with the design and construction thereof shall be paid by
Tenant pursuant to Section 5.F. below. The Building Shell and Building Core
Improvements shall be constructed in a good and workmanlike fashion and in
compliance with all codes, laws, rules and regulations of applicable
governmental authority.
B. Tenant Improvement Construction: Tenant, at Tenant's sole cost and
expense, shall retain an interior architect ("Tenant's Architect") to prepare
plans and outline specifications to be attached as Exhibit "F" ("Tenant
-----------
Improvement Plans and Specifications") with respect to the construction of the
balance of the improvements to the interior of the Premises ("Tenant
Improvements") necessary for Tenant's use and occupancy of the Building.
Landlord shall cause Tenant Improvements to be constructed by the General
Contractor in accordance with the Tenant Improvement Plans and Specifications.
The Tenant Improvement Plans and Specifications shall be completed for all
aspects of the work by July 31, 2001 with all detail necessary for submittal to
the city for issuance of building permits and for construction and shall include
any information required by the relevant agencies regarding Tenant's use of
Hazardous Materials if applicable. The Tenant Improvements shall consist of all
items not included within the scope of the Building Shell Definition, including
all Building Core Improvements. All Tenant Improvements shall be subject to
Landlord's approval, which shall not be unreasonably withheld, conditioned or
delayed. The Tenant Improvement Plans and Specifications shall provide for a
minimum build-out in all areas of the Premises consisting of: (i) fire
sprinklers, (ii) floor coverings, (iii) t-bar suspended ceiling (iv)
distribution of the HVAC system, (v) 2' x 4' drop-in florescent lighting, and
(vi) any other work required by the City of Mountain View necessary to obtain a
Certificate of Occupancy. Tenant shall not have the right to delay the
completion of the foregoing minimum Tenant Improvement build-out. The Tenant
Improvement Plans and Specifications shall be prepared in sufficient detail to
allow General Contractor to construct the Tenant Improvements. The Tenant
Improvements shall not be removed or altered by Tenant without the prior written
consent of Landlord as provided in Section 7 below. Tenant shall have the right
to depreciate and claim and collect any investment tax credits related to the
Tenant Improvements. Upon expiration of the Lease Term or any earlier
termination of the Lease, the Tenant Improvements shall become the property of
Landlord and shall remain upon and be surrendered with the Premises, and title
thereto shall automatically vest in Landlord without any payment therefore.
Landlord shall use its reasonable best efforts to obtain a building permit from
the City of Mountain View for the Tenant Improvements as soon as possible after
submittal of the Tenant Improvement Plans and Specifications, and thereafter to
cause the General Contractor to Substantially Complete the Tenant Improvements.
The Tenant Improvements shall be deemed substantially complete when the Tenant
Improvements have been substantially completed in accordance with the Tenant
Page 5
<PAGE>
Improvement Plans and Specifications, as evidenced by the issuance of a
certificate of occupancy or its equivalent by the appropriate governmental
authority. Installation of Tenant's data and phone cabling, Tenant's furniture,
or the exterior landscaping shall not be required in order to deem the Tenant
Improvements Substantially Complete.
C. Pricing: Within ten (10) days after completion of the Tenant
Improvements Plans and Specifications, Landlord shall cause the General
Contractor to submit to Tenant competitive bids from at least three (3)
subcontractors for each aspect of the work in excess of Fifty Thousand and
No/100 Dollars ($50,000.00) related to the Tenant Improvements. Landlord shall
cause the General Contractor to utilize the low bid in each case unless Tenant
approves General Contractor's use of another subcontractor, and the cost of the
Tenant Improvements shall be based upon construction expenses equal to (i) the
bid amounts as approved by Tenant, (ii) a five percent (5%) contingency to
protect the General Contractor against cost overruns, and (iii) the general
contractor fee specified in Section 5.H below ("Tenant Improvement Budget").
Upon Tenant's written approval of the Tenant Improvement Budget, which approval
shall not be unreasonably withheld or delayed, Landlord and Tenant shall be
deemed to have given their respective approvals of the final Tenant Improvement
Plans and Specifications on which the cost estimate was made, and Tenant shall
cause the General Contractor to proceed with the construction of the Tenant
Improvements in accordance with the terms of Section 5.G below. If Tenant does
not specifically approve or disapprove the bids within seven (7) days, Tenant
shall be deemed to have approved the bids.
D. Change Orders: With the exception of changes related to Building Core
Improvements, Tenant shall have the right to order changes in the manner and
type of construction of the Tenant Improvements subject to the reasonable
approval by Landlord. Upon request and prior to Tenant's submitting any binding
change order, Landlord shall cause the General Contractor to promptly provide
Tenant with written statements of the cost to implement and the time delay and
increased construction costs associated with any proposed change order, which
statements shall be binding on General Contractor. If no time delay or increased
construction cost amount is noted on the written statement, the parties agree
that there shall be no adjustment to the construction cost or the Commencement
Date associated with such change order. If ordered by Tenant, Landlord shall
cause the General Contractor to implement such change order and the cost of
constructing the Tenant Improvements shall be increased or decreased in
accordance with the cost statement previously delivered by General Contractor to
Tenant for any such change order.
E. Building Shell Costs: Landlord shall pay all costs and expenses
associated with construction of the Building Shell. The Building Shell
Definition shall be the governing document in specifying the costs associated
with the Building Shell.
F. Tenant Improvement Costs: Tenant shall pay all costs associated with the
Tenant Improvements (which includes Building Core Improvements) including, but
not limited to the following costs incurred by General Contractor in connection
with the construction of Tenant Improvements: construction costs, all permit
fees, construction taxes or other costs imposed by governmental authorities
related to the Tenant Improvements, and the General Contractor overhead as
described in Section 5.H below. During the course of construction of Tenant
Improvements, Landlord shall cause the General Contractor to deliver to Tenant
not more than once each calendar month a written request for payment ("Progress
Invoice") which shall include and be accompanied by General Contractor's
certified statements setting forth the amount requested, certifying the
percentage of completion of each item for which reimbursement is requested.
General Contractor shall use applicable standard AIA forms in such process.
Tenant shall pay directly to the General Contractor the amount due pursuant to
the Progress Invoice, within thirty (30) days after Tenant's receipt of the
above items. All costs for Tenant Improvements shall be fully documented to
Tenant and at Tenant's election, Tenant may verify such costs.
G. Force Majeure: Any prevention, delay or stoppage due to strikes,
lockouts, inclement weather, labor disputes, inability to obtain labor,
materials, fuel or reasonable substitutes therefor, governmental restrictions,
regulations, controls, civil commotion, fire or other act of God, and another
causes beyond the reasonable control of Landlord (except financial inability)
shall extend
Page 6
<PAGE>
the dates contained in this Section 5 by a period equal to the period of any
said prevention, delay or stoppage. If Landlord cannot obtain building permits
or substantially complete construction by the dates set forth herein, this Lease
shall not be void or voidable nor shall Landlord be liable for any loss or
damage resulting therefrom.
H. General Contractor Overhead & Profit: As compensation to General
Contractor for its services related to construction of the Building Shell and
Tenant Improvements, General Contractor shall receive a fee of seven percent
(7%) of the cost of construction to cover all of the following: construction
supervision and administration, temporary on-site facilities, home office
administration, supervision, and coordination and construction profit. Except as
provided therein, Landlord or General Contractor shall not receive any other fee
or payment from Tenant in connection with General Contractor's services.
I. Tenant Delays: A "Tenant Delay" shall mean any delay in substantial
completion of the Building as a result of any of the following: (i) Tenant's
failure to complete or approve the Tenant Improvement Plans by the dates set
forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction
by the dates set forth in Section 5.C, (iii) changes to the plans requested by
Tenant which delay the progress of the work, (iv) Tenant's request for materials
components, or finishes which are not available in a commercially reasonable
time given the target Commencement Date, (v) Tenant's failure to make a progress
payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's
request for more than one (1) rebidding of the cost of all or a portion of the
work, and (vii) any errors or omissions in the Tenant Improvement Plans provided
by Tenant's architect. Notwithstanding anything to the contrary set forth in
this Lease, and regardless of the actual date the Premises are substantially
complete, the Commencement Date shall be deemed to be the date the Commencement
Date would have occurred if no Tenant Delay had occurred as reasonably
determined by Landlord. In addition, if a Tenant Delay results in an increase in
the cost of the labor or materials, Tenant shall pay the cost of such increases.
J. Insurance: Landlord shall cause the General Contractor to procure (as a
cost of the Building Shell) a "Broad Form" liability insurance policy in the
amount of Three Million Dollars ($3,000,000.00). Landlord shall also procure (as
a cost of the Building Shell) builder's risk insurance for the full replacement
cost of the Building Shell and Tenant Improvements while the Building and Tenant
Improvements are under construction, up until the date that the casualty
insurance policy described in Section 9 is in full force and effect.
K. Punch List & Warranty: After the Building Shell and Tenant Improvements
are substantially complete, Landlord shall cause the General Contractor to
immediately correct any construction defect or other "punch list" item which
Tenant brings to General Contractor's attention. All such work shall be
performed so as to reasonably minimize the interruption to Tenant and its
activities on the Premises. General Contractor shall provide a standard
contractor's warranty with respect to the Building Shell and the Tenant
Improvements for one (1) year from the Commencement Date. Such warranty shall
exclude routine maintenance, damage caused by Tenant's negligence or misuse, and
acts of God.
L. Other Work by Tenant: All work not described in the Shell Plans and
Specifications or Tenant Improvement Plans and Specifications, such as
furniture, telephone equipment, telephone wiring and office equipment work,
shall be furnished and installed by Tenant at Tenant' cost. Prior to substantial
completion, Tenant shall be obligated to (i) provide active phone lines to any
elevators, and (ii) contract with a firm to monitor the fire system. When the
construction of the Tenant Improvements has proceeded to the point where
Tenant's work of installing its fixtures and equipment in the Premises can be
commenced, General Contractor shall notify Tenant and shall permit Tenant and
its authorized representatives and contractors access to the Premises before the
Commencement Date for the purpose of installing Tenant's trade fixtures and
equipment. Any such installation work by Tenant or its authorized
representatives and contractor prior to the Commencement Date shall be
undertaken upon the following conditions: (i) the entry into the Premises by
Tenant or its representatives or contractors shall not interfere with or delay
General Contractor's work, and (ii) any contractor used by Tenant in connection
with such entry and installation shall use union labor.
M. Landlord's Failure to Complete
Page 7
<PAGE>
Construction: If the Building is not Substantially Complete in accordance with
the Building Shell Plans and Specifications and Tenant Improvements Plans and
Specifications by that date that is twenty-two (22) months from the date
Landlord has received all necessary governmental approvals to commence
construction of the Building Shell ("Deadline Date"), then Tenant, upon written
notice to Landlord, shall be entitled to complete construction of the Building
and offset the cost of construction for which Landlord is responsible under this
Lease, plus interest at the Agreed Interest Rate, against Tenant's obligation
for the Base Monthly Rent due under this Lease. The completion by Tenant of
Landlord's construction obligations as provided in this Section 5.N. shall be
the sole and exclusive remedy of Tenant with respect to the failure by Landlord
to achieve Substantial Completion of the Building by the Deadline Date. In the
event that Tenant shall be required to complete Landlord's Work, Landlord agrees
to promptly assign to Tenant upon demand all plans and specifications relating
to construction for which Landlord is responsible under this Lease in order to
effectuate the completion thereof, and to cooperate with Tenant in connection
with the completion of such work. Nothing herein shall diminish Landlord's
obligation to act in good faith to promptly commence and diligently prosecute
the Landlord's Work.
The foregoing notwithstanding, the Deadline Date shall be extended one day for
every day of Force Majeure Delay or Tenant Delay as defined in Sections 5.G. and
5.I. above.
6. ACCEPTANCE OF POSSESSION AND COVENANTS TO SURRENDER:
A. Delivery and Acceptance: On the Commencement Date, Landlord shall
deliver and Tenant shall accept possession of the Premises. Tenant acknowledges
that it has had an opportunity to conduct, and has conducted, such inspections
of the Premises as it deems necessary to evaluate its condition. Except as
otherwise specifically provided herein, Tenant agrees to accept possession of
the Premises in its then existing condition, subject to all Restrictions and
without representation or warranty by Landlord.
B. Condition Upon Surrender: Tenant further agrees on the Expiration Date
or on the sooner termination of this Lease, to surrender the Premises to
Landlord in good condition and repair, normal wear and tear excepted. In this
regard, "normal wear and tear" shall be construed to mean wear and tear caused
to the Premises by the natural aging process which occurs in spite of prudent
application of the best standards for maintenance, repair replacement, and
janitorial practices, and does not include items of neglected or deferred
maintenance. In any event, Tenant shall cause the following to be done prior to
the Expiration Date or sooner termination of this Lease: (i) all interior walls
shall be painted or cleaned so that they appear freshly painted, (ii) all tiled
floors shall be cleaned and waxed, (iii) all carpets shall be cleaned and
shampooed, (iv) all broken, marred, stained or nonconforming acoustical ceiling
tiles shall be replaced, (v) all cabling placed above the ceiling by Tenant or
Tenant's contractors shall be removed unless such cabling has been placed in
trays especially designed for such purpose and is not weighing directly on the
ceiling, (vi) all windows shall be washed; (vii) the HVAC system shall be
serviced by a reputable and licensed service firm and left in "good operating
condition and repair" as evidenced by a report by such firm, (viii) the plumbing
and electrical systems and lighting shall be placed in good order and repair
(including replacement of any burned out, discolored or broken light bulbs,
ballasts, or lenses. On or before the Expiration Date or sooner termination of
this Lease, Tenant shall remove all its personal property and trade fixtures
from the Premises. All property and fixtures not so removed shall be deemed as
abandoned by Tenant. At the expiration of the Lease Term, Landlord shall not
have the right to require that Tenant remove from the Premises any Alterations
(as defined in Section 7 below) made with Landlord's consent unless Landlord, at
the time of granting such consent, indicates that the subject Alteration must be
removed upon the expiration of the Lease Term. With respect to Permitted
Alterations as defined in Section 7A. below, Tenant shall ascertain from
Landlord within ninety (90) days before the Expiration Date whether Landlord
desires to have such Permitted Alterations removed. If Landlord so elects,
Tenant shall, at its sole cost and expense, remove such Alterations as Landlord
has required and shall repair and restore the affected areas of the Premises
prior to the Expiration Date to a standard open office plan with materials and
finishes consistent with the other open office areas within the Premises. Such
repair and restoration shall include
Page 8
<PAGE>
causing the Premises to be brought into compliance with all applicable building
codes and laws in effect at the time of the removal to the extent such
compliance is necessitated by the repair and restoration work.
C. Failure to Surrender: If the Premises are not surrendered at the
Expiration Date or sooner termination of this Lease in the condition required by
this Section 6, Tenant shall be deemed in a holdover tenancy pursuant to this
Section 6.D. and Tenant shall indemnify, defend, and hold Landlord harmless
against loss or liability resulting from delay by Tenant in so surrendering the
Premises including, without limitation, any claims made by any succeeding tenant
founded on such delay and costs incurred by Landlord in returning the Premises
to the required condition, plus interest at the Agreed Interest Rate. Any
holding over after the termination or Expiration Date with Landlord's express
written consent, shall be construed as month-to-month tenancy, terminable on
thirty (30) days written notice from either party, and Tenant shall pay as Base
Monthly Rent to Landlord a rate equal to one hundred twenty five percent (125%)
of the Base Monthly Rent due in the month preceding the termination or
Expiration Date, plus all other amounts payable by Tenant under this Lease. Any
holding over shall otherwise be on the terms and conditions herein specified,
except those provisions relating to the Lease Term and any options to extend or
renew, which provisions shall be of no further force and effect following the
expiration of the applicable exercise period. If Tenant remains in possession of
the Premises after the Expiration Date or sooner termination of this Lease
without Landlord's consent, Tenant's continued possession shall be on the basis
of a tenancy at sufferance and Tenant shall pay as rent during the holdover
period an amount equal to one hundred fifty percent (150%) of the Base Monthly
Rent due in the month preceding the termination or Expiration Date, plus all
other amounts payable by Tenant under this Lease. This provision shall survive
the termination or expiration of the Lease.
7. ALTERATIONS AND ADDITIONS:
A. Tenant's Alterations: Tenant shall not make, or suffer to be made, any
alteration or addition to the Premises ("Alterations"), or any part thereof,
without obtaining Landlord's prior written consent and delivering to Landlord
the proposed architectural and structural plans for all such Alterations at
least fifteen (15) days prior to the start of construction. If such Alterations
affect the structure of the Building, Tenant additionally agrees to reimburse
Landlord its reasonable out-of-pocket costs incurred in reviewing Tenant's
plans. After obtaining Landlord's consent, which consent shall state whether or
not Landlord will require Tenant to remove such Alteration at the expiration or
earlier termination of this Lease, Tenant shall not proceed to make such
Alterations until Tenant has obtained all required governmental approvals and
permits. Tenant agrees to provide Landlord (i) written notice of the anticipated
and actual start-date of the work, (ii) a complete set of half-size (15" X 21")
vellum as-built drawings, and (iii) a certificate of occupancy for the work upon
completion of the Alterations. All Alterations shall be constructed in
compliance with all applicable building codes and laws including, without
limitation, the Americans with Disabilities Act of 1990 as amended from time to
time. Upon the Expiration Date, all Alterations, except movable furniture and
trade fixtures, shall become a part of the realty and belong to Landlord but
shall nevertheless be subject to removal by Tenant as provided in Section 6
above. Alterations which are not deemed as trade fixtures include heating,
lighting, electrical systems, air conditioning, walls, carpeting, or any other
installation which has become an integral part of the Premises (excepting backup
power generators or a UPS system, which Tenant shall have the right to remove).
All Alterations shall be maintained, replaced or repaired by Tenant at its sole
cost and expense.
Notwithstanding the foregoing, Tenant shall be entitled, without obtaining
Landlord's consent, to make Alterations which do not affect the structure of the
Building and which do not cost more than Seventy Thousand Dollars ($70,000.00)
per Alteration ("Permitted Alterations"); provided, however, that: (i) Tenant
shall still be required to comply with all other provisions of this paragraph;
and (ii) such Permitted Alterations are subject to removal by Tenant at
Landlord's election pursuant to Section 6.C. above at the expiration or earlier
termination of the Lease.
B. Free From Liens: Tenant shall keep the Premises free from all liens
arising out of work performed, materials furnished, or obligations incurred by
Tenant or claimed to have been performed for Tenant. In the event
Page 9
<PAGE>
Tenant fails to discharge any such lien within sixty (60) days after receiving
notice of the filing, Landlord shall be entitled to discharge the lien at
Tenant's expense and all resulting costs incurred by Landlord, including
attorney's fees shall be due from Tenant as additional rent.
C. Compliance With Governmental Regulations: The term Laws or Governmental
Regulations shall include all federal, state, county, city or governmental
agency laws, statutes, ordinances, standards, rules, requirements, or orders now
in force or hereafter enacted, promulgated, or issued. The term also includes
government measures regulating or enforcing public access, traffic mitigation,
occupational, health, or safety standards for employers, employees, landlords,
or tenants. Tenant, at Tenant's sole expense shall make all repairs,
replacements, alterations, or improvements needed to comply with all
Governmental Regulations. The judgment of any court of competent jurisdiction or
the admission of Tenant in any action or proceeding against Tenant (whether
Landlord be a party thereto or not) that Tenant has violated any such law,
regulation or other requirement in its use of the Premises shall be conclusive
of that fact as between Landlord and Tenant.
The foregoing notwithstanding, if any repair, replacement, alteration or
improvement is required to the Building foundation, exterior load bearing walls,
roof structure or any other structural component of the Building (excluding
structural components installed by Tenant) as a result of any Governmental
Regulations and such required work is not caused by Tenant's specific use or
Alterations, the cost of such repair, replacement, alteration or improvement
shall be allocated between Landlord and Tenant such that Tenant shall pay to
Landlord upon completion of such work, the portion of the cost equal to the
product of such cost multiplied by a fraction, the numerator of which is the
number of years remaining in the Lease Term, the denominator of which is the
useful life (in years) of the repair, replacement, alteration or addition;
provided, however, that if the Tenant thereafter exercises a renewal option,
then upon Tenant's exercise of the renewal option, the numerator of the fraction
shall be adjusted to the sum of: (i) the Lease Term remaining at the time the
repair, replacement, alteration or addition was made; and (ii) the number of
years in the Option Term; and Landlord's reimbursement obligation shall
immediately thereafter be re-calculated.
8. MAINTENANCE OF PREMISES:
A. Landlord's Obligations: Landlord at its sole cost and expense, shall
maintain in good condition, order, and repair, and replace as and when
necessary, the foundation, exterior load bearing walls and roof structure, and
all other structural components of the Building, excluding any components
installed by Tenant.
B. Tenant's Obligations: Tenant shall clean, maintain, repair and replace
when necessary the Premises and every part thereof through regular inspections
and servicing, including but not limited to: (i) all plumbing and sewage
facilities, (ii) all heating ventilating and air conditioning facilities and
equipment, (iii) all fixtures, interior walls floors, carpets and ceilings, (iv)
all windows, door entrances, plate glass and glazing systems including caulking
& skylights, (v) all electrical facilities & equipment, (vi) all automatic fire
extinguisher equipment, (vii) the parking lot and all underground utility
facilities servicing the Premises, (viii) all elevator equipment, (ix) the roof
membrane system, and (x) all waterscape, landscaping and shrubbery. All wall
surfaces and floor tile are to be maintained in an as good a condition as when
Tenant took possession free of holes, gouges, or defacements. With respect to
items (ii), (viii) and (ix) above, Tenant shall provide Landlord a copy of a
service contract between Tenant and a licensed service contractor providing for
periodic maintenance of all such systems or equipment in conformance with the
manufacturer's recommendations. Tenant shall provide Landlord a copy of such
preventive maintenance contracts and paid invoices for the recommended work if
requested by Landlord.
If as a part of Tenant's fulfillment of its maintenance obligations during the
last three (3) years of the Lease Term a replacement of the roof membrane is
necessary, Landlord shall reimburse Tenant for the cost of the replacement less
the sum of (i) Thirty Thousand Dollars ($30,000.00) plus (ii) that portion of
the cost over $30,000.00 equal to the product of such cost multiplied by a
fraction, the numerator of which is the number of years remaining in the Lease
Term, the denominator of which is the useful life (in years) of the roof
replacement; provided, however, that if the roof replacement is made during the
initial Lease Term and Tenant thereafter exercises a renewal option, then upon
Tenant's exercise of the renewal option, the
Page 10
<PAGE>
numerator of the fraction shall be adjusted to the sum of: (i) the Lease Term
remaining at the time the roof replacement was made; and (ii) the number of
years in the Option Term; and Landlord's reimbursement obligation shall
immediately thereafter be re-calculated.
C. Common Area Cost Sharing: Pursuant to Tenant's maintenance obligations
under this Lease, Tenant is solely responsible for the Common Area so long as it
is leasing all buildings within the Project. In the event Tenant does not lease
all buildings within the Project, Tenant shall remain obligated for such
expenses; however, the Lease shall be amended to provide for Landlord's
management of the Common Area and reimbursement by Tenant of only its pro rata
share, such share to be calculated based on leased square footage within the
Project.
D. Waiver of Liability: Failure by Landlord to perform any defined
services, or any cessation thereof, when such failure is caused by accident,
breakage, repairs, strikes, lockout or other labor disturbances or labor
disputes of any character or by any other cause, similar or dissimilar, shall
not render Landlord liable to Tenant in any respect, including damages to either
person or property, except to the extent due to Landlord's active negligence or
willful misconduct, nor be construed as an eviction of Tenant, nor cause an
abatement of rent, nor relieve Tenant from fulfillment of any covenant or
agreement hereof. Should any equipment or machinery utilized in supplying the
services listed herein break down or for any cause cease to function properly,
upon receipt of written notice from Tenant of any deficiency or failure of any
services, Landlord shall use reasonable diligence to repair the same promptly,
but Tenant shall have no right to terminate this Lease and shall have no claim
for rebate of rent or damages on account of any interruptions in service
occasioned thereby or resulting therefrom, except to the extent due to
Landlord's active negligence or willful misconduct. Tenant waives the provisions
of California Civil Code Sections 1941 and 1942 concerning the Landlord's
obligation of tenantability and Tenant's right to make repairs and deduct the
cost of such repairs from the rent. Landlord shall not be liable for a loss of
or injury to person or property, however occurring, through or in connection
with or incidental to furnishing, or its failure to furnish, any of the
foregoing.
9. HAZARD INSURANCE:
A. Tenant's Use: Tenant shall not use or permit the Premises, or any part
thereof, to be used for any purpose other than that for which the Premises are
hereby leased; and no use of the Premises shall be made or permitted, nor acts
done, which will cause an increase in premiums or a cancellation of any
insurance policy covering the Premises or any part thereof, nor shall Tenant
sell or permit to be sold, kept, or used in or about the Premises, any article
prohibited by the standard form of fire insurance policies. Tenant shall, at its
sole cost, comply with all requirements of any insurance company or organization
necessary for the maintenance of reasonable fire and public liability insurance
covering the Premises and appurtenances.
B. Landlord's Insurance: Landlord agrees to purchase and keep in force
fire, extended coverage insurance in an amount equal to the replacement cost of
the Building (not including any Tenant Improvements or Alterations paid for by
Tenant) as determined by Landlord's insurance company's appraisers. At
Landlord's election, such fire and property damage insurance may be endorsed to
cover loss caused by such additional perils against which Landlord may elect to
insure, including earthquake and/or flood, and shall contain reasonable
deductibles. Additionally Landlord may maintain a policy of (i) commercial
general liability insurance insuring Landlord (and such others designated by
Landlord) against liability for personal injury, bodily injury, death and damage
to property occurring or resulting from an occurrence in, on or about the
Premises or Project in an amount as Landlord determines is reasonably necessary
for its protection, and (ii) rental loss insurance covering a twelve (12) month
period. Tenant agrees to pay Landlord as additional rent, on demand, the full
cost of said insurance as evidenced by insurance billings to Landlord, and in
the event of damage covered by said insurance, the amount of any deductible
under such policy. Payment shall be due to Landlord within ten (10) days after
written invoice to Tenant. It is understood and agreed that Tenant's obligation
under this Section will be prorated to reflect the Lease Commencement and
Expiration Dates.
C. Tenant's Insurance: Tenant agrees, at its sole cost, to insure its
personal property, Tenant Improvements, and Alterations for their
Page 11
<PAGE>
full replacement value (without depreciation) and to obtain worker's
compensation and public liability and property damage insurance for occurrences
within the Premises with a combined single limit of not less than Five Million
Dollars ($5,000,000.00). Tenant's liability insurance shall be primary insurance
containing a cross-liability endorsement, and shall provide coverage on an
"occurrence" rather than on a "claims made" basis. Tenant shall name Landlord
and Landlord's lender as an additional insured and shall deliver a copy of the
policies and renewal certificates to Landlord. All such policies shall provide
for thirty (30) days' prior written notice to Landlord of any cancellation,
termination, or reduction in coverage.
D. Waiver: Landlord and Tenant hereby waive all rights each may have
against the other on account of any loss or damage sustained by Landlord or
Tenant, as the case may be, or to the Premises or its contents, which may arise
from any risk covered by their respective insurance policies (or which would
have been covered had such insurance policies been maintained in accordance with
this Lease) as set forth above. The Parties shall use their reasonable efforts
to obtain from their respective insurance companies a waiver of any right of
subrogation which said insurance company may have against Landlord or Tenant, as
the case may be.
10. Taxes: Tenant shall be liable for and shall pay as additional rental, prior
to delinquency, the following: (i) all taxes and assessments levied against
Tenant's personal property and trade or business fixtures; (ii) all real estate
taxes and assessment installments or other impositions or charges which may be
levied on the Premises or upon the occupancy of the Premises, including any
substitute or additional charges which may be imposed applicable to the Lease
Term; and (iii) real estate tax increases due to an increase in assessed value
resulting from a sale, transfer or other change of ownership of the Premises as
it appears on the City and County tax bills during the Lease Term. All real
estate taxes shall be prorated to reflect the Lease Commencement and Expiration
Dates. If, at any time during the Lease Term a tax, excise on rents, business
license tax or any other tax, however described, is levied or assessed against
Landlord as a substitute or addition, in whole or in part, for taxes assessed or
imposed on land or Buildings, Tenant shall pay and discharge its pro rata share
of such tax or excise on rents or other tax before it becomes delinquent; except
that this provision is not intended to cover net income taxes, inheritance, gift
or estate tax imposed upon Landlord. In the event that a tax is placed, levied,
or assessed against Landlord and the taxing authority takes the position that
Tenant cannot pay and discharge its pro rata share of such tax on behalf of
Landlord, then Landlord may increase the Base Monthly Rent by the exact amount
of such tax and Tenant shall pay such increase. If by virtue of any application
or proceeding brought by Landlord, there results a reduction in the assessed
value of the Premises during the Lease Term, Tenant agrees to pay Landlord a fee
consistent with the fees charged by a third party appeal firm for such services.
Notwithstanding the foregoing, if property taxes increase during the first three
years of the Lease Term as a result of a reassessment due to a voluntary change
of ownership, Tenant shall be responsible for payment of the resulting property
tax increase as follows: during the first twelve months, Tenant shall be
responsible for payment of thirty three percent (33%) of the tax increase;
during the second twelve months, Tenant shall be responsible for payment of
sixty seven percent (67%) of the tax increase, thereafter Tenant shall be
responsible for payment of the entire tax increase.
11. Utilities: Tenant shall pay directly to the providing utility all water,
gas, electric, telephone, and other utilities supplied to the Premises. Landlord
shall not be liable for loss of or injury to person or property, however
occurring, through or in connection with or incidental to furnishing or the
utility company's failure to furnish utilities to the Premises, and in such
event Tenant shall not be entitled to abatement or reduction of any portion of
Base Monthly Rent or any other amount payable under this Lease.
12. Toxic Waste and Environmental Damage:
A. Tenant's Responsibility: Without the prior written consent of
Landlord, Tenant or Tenant's agents, employees, contractors and invitees
("Tenant's Agents") shall not bring, use, or permit upon the Premises, or
generate, create, release, emit, or dispose (nor permit any of the same) from
the Premises any chemicals, toxic or hazardous gaseous, liquid or solid
materials or waste, including without limitation, material or substance having
characteristics of ignitability,
Page 12
<PAGE>
corrosivity, reactivity, or toxicity or substances or materials which are listed
on any of the Environmental Protection Agency's lists of hazardous wastes or
which are identified in Division 22 Title 26 of the California Code of
Regulations as the same may be amended from time to time or any other similar
wastes, materials or substances which are or may become regulated by or under
the authority of any applicable local, state or federal laws, judgments,
ordinances, orders, rules, regulations, codes or other governmental
restrictions, guidelines or requirements ("Hazardous Materials") except for
those substances customary in typical office uses for which no consent shall be
required. In order to obtain consent, Tenant shall deliver to Landlord its
written proposal describing the toxic material to be brought onto the Premises,
measures to be taken for storage and disposal thereof, safety measures to be
employed to prevent pollution of the air, ground, surface and ground water.
Landlord's approval may be withheld in its reasonable judgment. In the event
Landlord consents to Tenant's use of Hazardous Materials on the Premises or such
consent is not required, Tenant represents and warrants that it shall comply
with all Governmental Regulations applicable to Hazardous Materials including
doing the following: (i) adhere to all reporting and inspection requirements
imposed by Federal, State, County or Municipal laws, ordinances or regulations
and will provide Landlord a copy of any such reports or agency inspections; (ii)
obtain and provide Landlord copies of all necessary permits required for the use
and handling of Hazardous Materials on the Premises; (iii) enforce Hazardous
Materials handling and disposal practices consistent with industry standards;
(iv) surrender the Premises free from any Hazardous Materials arising from
Tenant's bringing, using, permitting, generating, creating, releasing, emitting
or disposing of Hazardous Materials; and (v) properly close the facility with
regard to Hazardous Materials including the removal or decontamination of any
process piping, mechanical ducting, storage tanks, containers, or trenches which
have come into contact with Hazardous Materials and obtain a closure certificate
from the local administering agency prior to the Expiration Date. Landlord
acknowledges and consents to the storage on the Premises by Tenant of diesel
fuel for Tenant's emergency generators, such storage to be in above-ground tanks
reasonably approved by Landlord.
B. Tenant's Indemnity Regarding Hazardous Materials: Tenant shall, at its
sole cost and expense, comply with all laws pertaining to, and shall with
counsel reasonably acceptable to Landlord, indemnify, defend and hold harmless
Landlord and Landlord's trustees, shareholders, directors, officers, employees,
partners, affiliates, and agents from, any claims, liabilities, costs or
expenses incurred or suffered arising from the bringing, using, permitting,
generating, emitting or disposing of Hazardous Materials by Tenant or Tenant's
Agents through the surface soils of the Premises during the Lease Term or the
violation of any Governmental Regulation or environmental law, by Tenant or
Tenant's Agents. Tenant's foregoing indemnification, defense, and hold harmless
obligations include, without limitation, the following: (i) claims, liability,
costs or expenses resulting from or based upon administrative, judicial (civil
or criminal) or other action, legal or equitable, brought by any private or
public person under common law or under the Comprehensive Environmental
Response, Compensation and Liability Act of 1980 as amended ("CERCLA"), the
Resource Conservation and Recovery Act of 1980 ("RCRA") or any other federal,
state, county or municipal law, ordinance or regulation now or hereafter in
effect; (ii) claims, liabilities, costs or expenses pertaining to the
identification, monitoring, cleanup, containment, or removal of Hazardous
Materials from soils, riverbeds or aquifers including the provision of an
alternative public drinking water source; (iii) all costs of defending such
claims; (iv) losses attributable to diminution in the value of the Premises or
the Building; (v) loss or restriction of use of rentable space in the Building;
(vi) adverse effect on the marketing of any space in the Building; and (vi) all
other liabilities, obligations, penalties, fines, claims, actions (including
remedial or enforcement actions of any kind and administrative or judicial
proceedings, orders or judgments), damages (including consequential and punitive
damages), and costs (including attorney, consultant, and expert fees and
expenses) resulting from the release or violation. This Section 12.B shall
survive the expiration or termination of this Lease.
C. Actual Release by Tenant: Tenant agrees to notify Landlord of any
lawsuits or orders which relate to the remedying of or actual release of
Hazardous Materials on or into the soils or ground water at or under the
Page 13
<PAGE>
Premises. Tenant shall also provide Landlord all notices required by Section
25359.7(b) of the Health and Safety Code and all other notices required by law
to be given to Landlord in connection with Hazardous Materials. Without limiting
the foregoing, Tenant shall also deliver to Landlord, within twenty (20) days
after receipt thereof, any written notices from any governmental agency alleging
a material violation of, or material failure to comply with, any federal, state
or local laws, regulations, ordinances or orders, the violation of which or
failure to comply with poses a foreseeable and material risk of contamination of
the ground water or injury to humans (other than injury solely to Tenant or
Tenant's Agents).
In the event of any release on or into the Premises or into the soil or
ground water under the Premises, the Building or the Project of any Hazardous
Materials used, treated, stored or disposed of by Tenant or Tenant's Agents,
Tenant agrees to comply, at its sole cost, with all laws, regulations,
ordinances and orders of any federal, state or local agency relating to the
monitoring or remediation of such Hazardous Materials. In the event of any such
release of Hazardous Materials Tenant shall immediately give verbal and
follow-up written notice of the release to Landlord, and Tenant agrees to meet
and confer with Landlord and its Lender to attempt to eliminate and mitigate any
financial exposure to such Lender and resultant exposure to Landlord under
California Code of Civil Procedure Section 736(b) as a result of such release,
and promptly to take reasonable monitoring, cleanup and remedial steps given,
inter alia, the historical uses to which the Property has and continues to be
used, the risks to public health posed by the release, the then available
technology and the costs of remediation, cleanup and monitoring, consistent with
acceptable customary practices for the type and severity of such contamination
and all applicable laws. Nothing in the preceding sentence shall eliminate,
modify or reduce the obligation of Tenant under 12.B of this Lease to indemnify,
defend and hold Landlord harmless from any claims liabilities, costs or expenses
incurred or suffered by Landlord. Tenant shall provide Landlord prompt written
notice of Tenant's monitoring, cleanup and remedial steps.
In the absence of an order of any federal, state or local governmental or
quasi-governmental agency relating to the cleanup, remediation or other response
action required by applicable law, any dispute arising between Landlord and
Tenant concerning Tenant's obligation to Landlord under this Section 12.C
concerning the level, method, and manner of cleanup, remediation or response
action required in connection with such a release of Hazardous Materials shall
be resolved by mediation and/or arbitration pursuant to this Lease.
D. Environmental Monitoring: Landlord and its agents shall have the right
to inspect, investigate, sample and monitor the Premises including any air,
soil, water, ground water or other sampling or any other testing, digging,
drilling or analysis to determine whether Tenant is complying with the terms of
this Section 12. If Landlord discovers that Tenant is not in compliance with the
terms of this Section 12, any such costs incurred by Landlord, including
attorneys' and consultants' fees, shall be due and payable by Tenant to Landlord
within thirty (30) days following Landlord's written demand therefore.
E. Landlord's Indemnity Regarding Hazardous Materials: Landlord shall, at
its sole cost and expense, with counsel reasonably acceptable to Tenant,
indemnify, defend, and hold Tenant harmless from any claims, liabilities, costs
or expenses incurred or suffered by Tenant related to the release, existence,
removal, investigation, monitoring or remediation of Hazardous Materials which
are present or which come to be present on or beneath the Premises except to the
extent the presence of such Hazardous Materials is caused by Tenant or Tenant's
agents. Landlord's indemnification and hold harmless obligations include,
without limitation, (i) claims, liability, costs or expenses resulting from or
based upon administrative, judicial (civil or criminal) or other action, legal
or equitable, brought by any private or public person under common law or
CERCLA, RCRA, or any other federal, state, county or municipal law, ordinance or
regulation now or hereinafter in effect, (ii) claims, liabilities, costs or
expenses pertaining to the identification, monitoring, cleanup, containment, or
removal of Hazardous Materials from soils, riverbeds or aquifers including the
provision of an alternative public drinking water source, and (iii) all costs of
defending such claims. In no event shall Landlord be liable for any
consequential damages suffered or incurred by Tenant as a result of any such
Page 14
<PAGE>
contamination.
13. Tenant's Default: The occurrence of any of the following shall constitute a
default and breach of this Lease by Tenant: (i) Tenant's failure to pay the Base
Monthly Rent including additional rent or any other payment due under this Lease
within five (5) business days after receipt by Tenant of written notice from
Landlord that such Base Monthly Rent or other payment was not received when due,
(ii) the abandonment of the Premises by Tenant; (iii) Tenant's failure to
observe and perform any other required provision of this Lease, where such
failure continues for thirty (30) days after written notice from Landlord;
provided, however, that if the nature of the default is such that it cannot
reasonably be cured within the 30-day period, Tenant shall not be deemed in
default if it commences within such period to cure, and thereafter diligently
prosecutes the same to completion; (iv) Tenant's making of any general
assignment for the benefit of creditors; (v) the filing by or against Tenant of
a petition to have Tenant adjudged a bankrupt or of a petition for
reorganization or arrangement under any law relating to bankruptcy (unless, in
the case of a petition filed against Tenant, the same is dismissed within sixty
(60) days after the filing); (vi) the appointment of a trustee or receiver to
take possession of substantially all of Tenant's assets located at the Premises
or of Tenant's interest in this Lease, where possession is not restored to
Tenant within sixty (60) days; or (vii) the attachment, execution or other
judicial seizure of substantially all of Tenant's assets located at the Premises
or of Tenant's interest in this Lease, where such seizure is not discharged
within sixty (60) days.
A. Remedies: In the event of any such default by Tenant, then in addition
to other remedies available to Landlord at law or in equity, Landlord shall have
the immediate option to terminate this Lease and all rights of Tenant hereunder
by giving written notice of such intention to terminate. In the event Landlord
elects to so terminate this Lease, Landlord may recover from Tenant all the
following: (i) the worth at time of award of any unpaid rent which had been
earned at the time of such termination; (ii) the worth at time of award of the
amount by which the unpaid rent which would have been earned after termination
until the time of award exceeds the amount of such rental loss for the same
period that Tenant proves could have been reasonably avoided; (iii) the worth at
time of award of the amount by which the unpaid rent for the balance of the
Lease Term after the time of award exceeds the amount of such rental loss that
Tenant proves could be reasonably avoided; (iv) any other amount necessary to
compensate Landlord for all detriment proximately caused by Tenant's failure to
perform its obligations under this Lease, or which in the ordinary course of
things would be likely to result therefrom; including the following: (x)
expenses for repairing, altering or remodeling the Premises for purposes of
reletting, (y) broker's fees, advertising costs or other expenses of reletting
the Premises, and (z) costs of carrying the Premises such as taxes, insurance
premiums, utilities and security precautions; and (v) at Landlord's election,
such other amounts in addition to or in lieu of the foregoing as may be
permitted by applicable California law. The term "rent", as used herein, is
defined as the minimum monthly installments of Base Monthly Rent and all other
sums required to be paid by Tenant pursuant to this Lease, all such other sums
being deemed as additional rent due hereunder. As used in (i) and (ii) above,
"worth at the time of award" shall be computed by allowing interest at a rate
equal to the discount rate of the Federal Reserve Bank of San Francisco plus
five (5%) percent per annum. As used in (iii) above, "worth at the time of
award" shall be computed by discounting such amount at the discount rate of the
Federal Reserve Bank of San Francisco at the time of award plus one (1%)
percent.
B. Right to Re-enter: In the event of any such default by Tenant,
Landlord shall have the right, after terminating this Lease, to re-enter the
Premises and remove all persons and property. Such property may be removed and
stored in a public warehouse or elsewhere at the cost of and for the account of
Tenant, and disposed of by Landlord in any manner permitted by law.
C. Abandonment: If Landlord does not elect to terminate this Lease as
provided in Section 13.A or 13.B above, then the provisions of California Civil
Code Section 1951.4, (Landlord may continue the lease in effect after Tenant's
breach and abandonment and recover rent as it becomes due if Tenant has a right
to sublet and assign, subject only to reasonable limitations) as amended from
time to time, shall apply and Landlord may from time to time, without
terminating this Lease, either recover all rental as it becomes due or relet the
Premises or
Page 15
<PAGE>
any part thereof for such term or terms and at such rental or rentals and upon
such other terms and conditions as Landlord in its reasonable discretion may
deem advisable, with the right to make alterations and repairs to the Premises.
In the event that Landlord elects to so relet, rentals received by Landlord from
such reletting shall be applied in the following order to: (i) the payment of
any indebtedness other than Base Monthly Rent due hereunder from Tenant to
Landlord; (ii) the payment of any cost of such reletting; (iii) the payment of
the cost of any alterations and repairs to the Premises; and (iv) the payment of
Base Monthly Rent due and unpaid hereunder. The residual rentals, if any, shall
be held by Landlord and applied in payment of future Base Monthly Rent as the
same may become due and payable hereunder. Landlord shall have the obligation to
market the space but shall have no obligation to relet the Premises following a
default if Landlord has other comparable available space within the Building or
Project. In the event the portion of rentals received from such reletting which
is applied to the payment of rent hereunder during any month be less than the
rent payable during that month by Tenant hereunder, then Tenant shall pay such
deficiency to Landlord immediately upon demand. Such deficiency shall be
calculated and paid monthly. Tenant shall also pay to Landlord, as soon as
ascertained, any costs and expenses incurred by Landlord in such reletting or in
making such alterations and repairs not covered by the rentals received from
such reletting.
D. No Termination: Landlord's re-entry or taking possession of the
Premises pursuant to 13.B or 13.C shall not be construed as an election to
terminate this Lease unless written notice of such intention is given to Tenant
or unless the termination is decreed by a court of competent jurisdiction.
Notwithstanding any reletting without termination by Landlord because of any
default by Tenant, Landlord may at any time after such reletting elect to
terminate this Lease for any such default.
E. Non-Waiver: Landlord may accept Tenant's payments without waiving any
rights under this Lease, including rights under a previously served notice of
default. No payment by Tenant or receipt by Landlord of a lesser amount than any
installment of rent due shall be deemed as other than payment on account of the
amount due. If Landlord accepts payments after serving a notice of default,
Landlord may nevertheless commence and pursue an action to enforce rights and
remedies under the previously served notice of default without giving Tenant any
further notice or demand. Furthermore, the Landlord's acceptance of rent from
the Tenant when the Tenant is holding over without express written consent does
not convert Tenant's Tenancy from a tenancy at sufferance to a month to month
tenancy. No waiver of any provision of this Lease shall be implied by any
failure of Landlord to enforce any remedy for the violation of that provision,
even if that violation continues or is repeated. Any waiver by Landlord of any
provision of this Lease must be in writing. Such waiver shall affect only the
provision specified and only for the time and in the manner stated in the
writing. No delay or omission in the exercise of any right or remedy by Landlord
shall impair such right or remedy or be construed as a waiver thereof by
Landlord. No act or conduct of Landlord, including, without limitation, the
acceptance of keys to the Premises, shall constitute acceptance of the surrender
of the Premises by Tenant before the Expiration Date. Only written notice from
Landlord to Tenant of acceptance shall constitute such acceptance of surrender
of the Premises. Landlord's consent to or approval of any act by Tenant which
requires Landlord's consent or approvals shall not be deemed to waive or render
unnecessary Landlord's consent to or approval of any subsequent act by Tenant.
F. Performance by Landlord: If Tenant fails to perform any obligation
required under this Lease or by law or governmental regulation, Landlord in its
sole discretion may, after ten (10) days prior written notice to Tenant, without
waiving any rights or remedies and without releasing Tenant from its obligations
hereunder, perform such obligation, in which event Tenant shall pay Landlord as
additional rent all sums paid by Landlord in connection with such substitute
performance, including interest at the Agreed Interest Rate (as defined in
Section 19.J) within ten (10) days of Landlord's written notice for such
payment.
G. Habitual Default: The provisions of Section 13 notwithstanding, the
Parties agree that if Tenant has been in either monetary default or material
non-monetary default (beyond applicable notice and cure periods) in the
performance of any (but not necessarily the same) term or condition of this
Lease for four or more times during any twelve (12) month period during the
Lease Term, then such
<PAGE>
conduct shall, at the election of the Landlord, represent a separate event of
default which cannot be cured by Tenant. Tenant acknowledges that the purpose of
this provision is to prevent repetitive defaults by Tenant, which work a
hardship upon Landlord and deprive Landlord of Tenant's timely performance under
this Lease.
14. Landlord's Liability:
A. Limitation on Landlord's Liability: In the event of Landlord's failure
to perform any of its covenants or agreements under this Lease, Tenant shall
give Landlord written notice of such failure and shall give Landlord thirty (30)
days to cure or commence to cure such failure prior to any claim for breach or
resultant damages, provided, however, that if the nature of the default is such
that it cannot reasonably be cured within the 30-day period, Landlord shall not
be deemed in default if it commences within such period to cure, and thereafter
diligently prosecutes the same to completion. In addition, upon any such failure
by Landlord, Tenant shall give notice by registered or certified mail to any
person or entity with a security interest in the Premises ("Mortgagee") that has
provided Tenant with notice of its interest in the Premises, and shall provide
Mortgagee a reasonable opportunity to cure such failure, including such time to
obtain possession of the Premises by power of sale or judicial foreclosure, if
such should prove necessary to effectuate a cure. Tenant agrees that each of the
Mortgagees to whom this Lease has been assigned is an expressed third-party
beneficiary hereof. Tenant waives any right under California Civil Code Section
1950.7 or any other present or future law to the collection of any payment or
deposit from Mortgagee or any purchaser at a foreclosure sale of Mortgagee's
interest unless Mortgagee or such purchaser shall have actually received and not
refunded the applicable payment or deposit. Tenant further waives any right to
terminate this Lease and to vacate the Premises on Landlord's default under this
Lease, except in the event of a constructive eviction under law. Tenant's sole
remedy on Landlord's default is an action for damages or injunctive or
declaratory relief.
B. Limitation on Tenant's Recourse: If Landlord is a corporation, trust,
partnership, joint venture, unincorporated association or other form of business
entity, then (i) the obligations of Landlord shall not constitute personal
obligations of the officers, directors, trustees, partners, joint venturers,
members, owners, stockholders, or other principals or representatives except to
the extent of their interest in the Premises. Tenant shall have recourse only to
the interest of Landlord in the Premises or for the satisfaction of the
obligations of Landlord and shall not have recourse to any other assets of
Landlord for the satisfaction of such obligations.
C. Indemnification of Landlord: As a material part of the consideration
rendered to Landlord, Tenant hereby waives all claims against Landlord for
damages to goods, wares and merchandise, and all other personal property in,
upon or about said Premises and for injuries to persons in or about said
Premises, from any cause arising at any time to the fullest extent permitted by
law, except to the extent caused by the willful misconduct or active negligence
of Landlord, and Tenant shall indemnify, defend with counsel reasonably
acceptable to Landlord and hold Landlord, and their shareholders, directors,
officers, trustees, employees, partners, affiliates and agents from any claims,
liabilities, costs or expenses incurred or suffered arising from the use of
occupancy of the Premises or any part of the Project by Tenant or Tenant's
Agents, the acts or omissions of Tenant or Tenant's Agents, Tenant's breach of
this Lease, or any damage or injury to person or property from any cause, except
to the extent caused by the willful misconduct or active negligence of Landlord
or from the failure of Tenant to keep the Premises in good condition and repair
as herein provided, except to the extent due to the active negligence or willful
misconduct of Landlord. Further, in the event Landlord is made party to any
litigation due to the acts or omission of Tenant and Tenant's Agents, Tenant
will indemnify, defend (with counsel reasonably acceptable to Landlord) and hold
Landlord harmless from any such claim or liability including Landlord's costs
and expenses and reasonable attorney's fees incurred in defending such claims.
15. Destruction of Premises:
A. Landlord's Obligation to Restore: In the event of a destruction of the
Premises during the Lease Term Landlord shall repair the same to a similar
condition to that which existed prior to such destruction. Such destruction
shall not annul or void this Lease; however, Tenant shall be entitled to a
proportionate reduction of Base
Page 17
<PAGE>
Monthly Rent while repairs are being made, such proportionate reduction to be
based upon the extent to which the repairs interfere with Tenant's business in
the Premises, as reasonably determined by Landlord. In no event shall Landlord
be required to replace or restore Alterations, Tenant Improvements, or Tenant's
fixtures or personal property. With respect to a destruction which Landlord is
obligated to repair or may elect to repair under the terms of this Section,
Tenant waives the provisions of Section 1932, and Section 1933, Subdivision 4,
of the Civil Code of the State of California, and any other similarly enacted
statute, and the provisions of this Section 15 shall govern in the case of such
destruction.
B. Limitations on Landlord's Restoration Obligation: Notwithstanding the
provisions of Section 15.A, Landlord shall have no obligation to repair, or
restore the Premises if any of the following occur: (i) if the repairs cannot be
made within two hundred seventy (270) days from the date of receipt of all
governmental approvals necessary under the laws and regulations of State,
Federal, County or Municipal authorities, as reasonably determined by Landlord,
(ii) if the holder of the first deed of trust or mortgage encumbering the
Building elects not to permit the insurance proceeds payable upon damage or
destruction to be used for such repair or restoration, (iii) the damage or
destruction is not fully covered by the insurance (plus any deductible amount)
maintained by Landlord, (iv) the damage or destruction occurs in the last twenty
four (24) months of the Lease Term, (v) Tenant is in default pursuant to the
provisions of Section 13, or (vi) Tenant has vacated the Premises for more than
the immediately preceding one hundred twenty (120) days. In any such event
Landlord may elect either to complete the repair or restoration, or terminate
this Lease by providing Tenant written notice of its election within sixty (60)
days following the damage or destruction. Tenant shall also have a right to
terminate this Lease if the repairs cannot be made within two hundred seventy
(270) days from the date of receipt of all governmental approvals necessary
under the laws and regulations of State, Federal, County or Municipal
authorities, by providing Landlord written notice of its election within sixty
(60) days following the damage or destruction.
16. Condemnation: If any part of the Premises shall be taken for any public or
quasi-public use, under any statute or by right of eminent domain or private
purchase in lieu thereof, and only a part thereof remains which is susceptible
of occupation hereunder as reasonably determined by Tenant, this Lease shall, as
to the part so taken, terminate as of the day before title vests in the
condemnor or purchaser ("Vesting Date") and Base Monthly Rent payable hereunder
shall be adjusted so that Tenant is required to pay for the remainder of the
Lease Term only such portion of Base Monthly Rent as the value of the part
remaining after such taking bears to the value of the entire Premises prior to
such taking. If all of the Premises or such part thereof be taken so that there
does not remain a portion susceptible for occupation hereunder as reasonably
determined by Tenant, this Lease shall terminate on the Vesting Date. If part or
all of the Premises be taken, all compensation awarded upon such taking shall go
to Landlord, and Tenant shall have no claim thereto; except Landlord shall
cooperate with Tenant, without cost to Landlord, to recover compensation for
damage to or taking of any Alterations, Tenant Improvements, or for Tenant's
moving costs, loss of or damage to Tenant's personal property, loss to Tenant
because of interruption of business, Tenant's loss of goodwill, and the value
attributable to any leasehold value for the difference between the market value
of the Premises for the remainder or the term above the value, at the date of
taking, of the rent payable for the remainder of the term. Tenant will have no
right to pursue a claim based upon the residual value of the Land after
expiration of the term or pursue claims or retain any award to which Landlord is
entitled so as inequitably to diminish Landlord's award. Tenant hereby waives
the provisions of California Code of Civil Procedures Section 1265.130 and any
other similarly enacted statue, and the provisions of this Section 16 shall
govern in the case of a taking.
17. Assignment or Sublease:
A. Consent by Landlord: Except as specifically provided in this Section
17, Tenant may not assign, sublet, hypothecate, or allow a third party to use
the Premises without the express written consent of Landlord, which consent
shall not be unreasonably withheld or delayed. In the event Tenant desires to
assign this Lease or any interest herein or sublet the Premises or any part
thereof, Tenant shall deliver to Landlord (i) executed counterparts of
Page 18
<PAGE>
any agreement and of all ancillary agreements with the proposed
assignee/subtenant, (ii) current financial statements of the transferee covering
the preceding three years, (iii) the nature of the proposed transferee's
business to be carried on in the Premises, (iv) a statement outlining all
consideration to be given on account of the Transfer, and (v) a current
financial statement of Tenant. Landlord may condition its approval of any
Transfer on receipt of a certification from both Tenant and the proposed
transferee of all consideration to be paid to Tenant in connection with such
Transfer. At Landlord's request, Tenant shall also provide additional
information reasonably required by Landlord to determine whether it will consent
to the proposed assignment or sublease. Landlord shall have a eight (8)
business-day period following receipt of all the foregoing within which to
notify Tenant in writing that Landlord elects to: (i) terminate this Lease in
the event the proposed sublease or assignment is for substantially all of space
in the Premises (provided, however, that Landlord shall not have the right to
terminate on any sublease or assignment expiring, including any options in favor
of sublessee/assignee, more than three (3) years prior to the Lease Expiration
Date, including any options under this Lease which have been exercised by
Tenant); (ii) permit Tenant to assign or sublet such space to the named
assignee/subtenant on the terms and conditions set forth in the notice; or (iii)
refuse consent. If Landlord should fail to notify Tenant in writing of such
election within the 30-day period, Landlord shall be deemed to have elected
option (ii) above. In the event Landlord elects option (i) above, this Lease
shall expire with respect to such part of the Premises on the date upon which
the proposed sublease or transfer was to commence, and from such date forward,
Base Monthly Rent and all other costs and charges shall be adjusted based upon
the proportion that the rentable area of the Premises remaining bears to the
total rentable area of the Building. In the event Landlord elects option (ii)
above, Landlord's written consent to the proposed assignment or sublease shall
not be unreasonably withheld, provided and upon the condition that: (i) the
proposed assignee or subtenant is engaged in a business that is limited to the
use expressly permitted under this Lease; (ii) the proposed assignment or
sublease is in form reasonably satisfactory to Landlord; (iii) the proposed
sublease will not result in there being more than two (2) subtenants within the
Premises at any time during the Lease Term; (iv) Tenant reimburses Landlord on
demand for any reasonable costs that may be incurred by Landlord in connection
with said assignment or sublease, including the costs of making investigations
as to the acceptability of the proposed assignee or subtenant and legal costs
(not to exceed $2,000.00 per occurance) incurred in connection with the granting
of any requested consent; and (v) Tenant shall not have advertised or publicized
in any way the availability of the Premises without prior notice to Landlord. In
the event all or any one of the foregoing conditions are not satisfied, Landlord
shall be considered to have acted reasonably if it withholds its consent.
B. Assignment or Subletting Consideration: Landlord and Tenant hereby
agree that fifty percent (50%) of any rent or other economic consideration (not
including any payments for Tenant's furniture or other personal property owned
by Tenant, any payment for utilities or for other office services provided by
Tenant); (i) realized by Tenant under any sublease or assignment, or (ii)
realized by any subtenant under any sub-sublease of the Premises, in excess of
the Base Monthly Rent payable hereunder after deducting reasonable subletting
and assignment costs directly related to such sublease or assignment including
lease commissions, attorneys fees, costs of demising or otherwise preparing the
sublease space for occupancy, and the unamortized cost of Alterations applicable
to the space so sublet or assigned, shall be paid to Landlord. Tenant's
obligation to pay over Landlord's portion of the consideration constitutes an
obligation for additional rent hereunder. The above provisions relating to
Landlord's right to terminate the Lease and relating to the allocation of excess
rent are independently negotiated terms of the Lease which constitute a material
inducement for the Landlord to enter into the Lease, and are agreed by the
Parties to be commercially reasonable. No assignment or subletting by Tenant
shall relieve it of any obligation under this Lease. Any assignment or
subletting which conflicts with the provisions hereof shall be void.
C. No Release: Any assignment or sublease shall be made only if and shall
not be effective until the assignee or subtenant shall execute, acknowledge, and
deliver to Landlord an agreement, in form and substance satisfactory to
Landlord, whereby the assignee or subtenant shall assume all the applicable
<PAGE>
obligations of this Lease on the part of Tenant to be performed or observed and
shall be subject to all the covenants, agreements, terms, provisions and
conditions in this Lease. Notwithstanding any such sublease or assignment and
the acceptance of rent by Landlord from any subtenant or assignee, Tenant and
any guarantor shall remain fully liable for the payment of Base Monthly Rent and
additional rent due, and to become due hereunder, for the performance of all the
covenants, agreements, terms, provisions and conditions contained in this Lease
on the part of Tenant to be performed and for all acts and omissions of any
licensee, subtenant, assignee or any other person claiming under or through any
subtenant or assignee that shall be in violation of any of the terms and
conditions of this Lease, and any such violation shall be deemed a violation by
Tenant. Tenant shall indemnify, defend and hold Landlord harmless from and
against all losses, liabilities, damages, costs and expenses (including
reasonable attorney fees) resulting from any claims that may be made against
Landlord by the proposed assignee or subtenant (except to the extent caused by
Landlord's gross negligence or willful misconduct) or by any real estate brokers
or other persons claiming compensation in connection with the proposed
assignment or sublease.
D. Reorganization of Tenant: The provisions of this Section 17.D shall
apply if Tenant is a corporation and: (i) there is a dissolution, merger,
consolidation, or other reorganization of or affecting Tenant, where Tenant is
not the surviving corporation, or (ii) there is a sale or transfer to one person
or entity (or to any group of related persons or entities) of stock possessing
more than 50% of the total combined voting power of all classes of Tenant's
capital stock issued, outstanding and entitled to vote for the election of
directors, and after such sale or transfer of stock Tenant's stock is no longer
publicly traded. In a transaction under clause (i) the surviving corporation
shall promptly execute and deliver to Landlord an agreement in form reasonably
satisfactory to Landlord under which such surviving corporation assumes the
obligations of Tenant hereunder, and in a transaction under clause (ii) the
transferee or buyer shall promptly execute and deliver to Landlord an agreement
in form reasonably satisfactory to Landlord under which such transferee or buyer
assumes the obligations of Tenant under the Lease.
E. Permitted Transfers: Notwithstanding anything contained in this
Section 17, so long as Tenant otherwise complies with the provisions of this
Article, Tenant may enter into any of the following transfers (a "Permitted
Transfer") without Landlord's prior consent, and Landlord shall not be entitled
to terminate the Lease or to receive any part of any subrent resulting therefrom
that would otherwise be due pursuant to Sections 17.A and 17.B. Tenant may
sublease all or part of the Premises or assign its interest in this Lease to (i)
any corporation which controls, is controlled by, or is under common control
with the original Tenant to this Lease by means of an ownership interest of more
than 50%; (ii) a corporation which results from a merger, consolidation or other
reorganization in which Tenant is not the surviving corporation, so long as the
surviving corporation has a net worth at the time of such assignment that is
equal to or greater than the net worth of Tenant immediately prior to such
transaction; and (iii) a corporation which purchases or otherwise acquires all
or substantially all of the assets of Tenant so long as such acquiring
corporation has a net worth at the time of such assignment that is equal to or
greater than the net worth of Tenant immediately prior to such transaction.
F. Effect of Default: In the event of Tenant's default, Tenant hereby
assigns all rents due from any assignment or subletting to Landlord as security
for performance of its obligations under this Lease, and Landlord may collect
such rents as Tenant's Attorney-in-Fact, except that Tenant may collect such
rents unless a default occurs as described in Section 13 above. A termination of
the Lease due to Tenant's default shall not automatically terminate an
assignment or sublease then in existence; rather at Landlord's election, such
assignment or sublease shall survive the Lease termination, the assignee or
subtenant shall attorn to Landlord, and Landlord shall undertake the obligations
of Tenant under the sublease or assignment; except that Landlord shall not be
liable for prepaid rent, security deposits or other defaults of Tenant to the
subtenant or assignee, or for any acts or omissions of Tenant and Tenant's
Agents.
G. Conveyance by Landlord: As used in this Lease, the term "Landlord" is
defined only as the owner for the time being of the Premises, so that in the
event of any sale or other conveyance of the Premises or in the event of a
Page 20
<PAGE>
master lease of the Premises, Landlord shall be entirely freed and relieved of
all its covenants and obligations hereunder, and it shall be deemed and
construed, without further agreement between the Parties and the purchaser at
any such sale or the master tenant of the Premises, that the purchaser or master
tenant of the Premises has assumed and agreed to carry out any and all covenants
and obligations of Landlord hereunder. Such transferor shall transfer and
deliver Tenant's security deposit to the purchaser at any such sale or the
master tenant of the Premises, and thereupon the transferor shall be discharged
from any further liability in reference thereto.
F. Successors and Assigns: Subject to the provisions this Section 17, the
covenants and conditions of this Lease shall apply to and bind the heirs,
successors, executors, administrators and assigns of all Parties hereto; and all
Parties hereto comprising Tenant shall be jointly and severally liable
hereunder.
18. Option to Extend the Lease Term:
A. Grant and Exercise of Option: Provided Tenant simultaneously exercises
its option to extend the lease for Building 2 and Building 3, Landlord grants to
Tenant, subject to the terms and conditions set forth in this Section 18.A, two
(2) options (the "Options") to extend the Lease Term for an additional term (the
"Option Term"). Each Option Term shall be for a period of sixty (60) months and
shall be exercised, if at all, by written notice to Landlord no later than nine
(9) months prior to the date the Lease Term would expire but for such exercise,
time being of the essence for the giving of such notice. If Tenant exercises the
Option, all of the terms, covenants and conditions of this Lease except for the
grant of additional Options pursuant to this Section, provided that Base Monthly
Rent for the Premises payable by Tenant during the Option Term shall be the
greater of (i) the Base Monthly Rent applicable to the period immediately prior
to the commencement of the Option Term, and (ii) ninety five percent (95%) of
the Fair Market Rental as hereinafter defined. Notwithstanding anything herein
to the contrary, if Tenant is in monetary or material non-monetary default under
any of the terms, covenants or conditions of this Lease (beyond applicable cure
periods) either at the time Tenant exercises the Option or at any time
thereafter prior to the commencement date of the Option Term, then Landlord
shall have, in addition to all of Landlord's other rights and remedies provided
in this Lease, the right to terminate the Option upon notice to Tenant, in which
event the Lease Term shall not be extended pursuant to this Section 18.A. As
used herein, the term "Fair Market Rental" is defined as the rental and all
other monetary payments, including any escalations and adjustments thereto
(including without limitation Consumer Price Indexing) that Landlord could
obtain during the Option Term from a third party desiring to lease the Premises,
based upon the current use and other potential uses of the Premises, as
determined by the rents then being obtained for new leases of space comparable
in age and quality to the Premises in the same real estate submarket as the
Building. The appraisers shall be instructed that the foregoing five percent
(5%) discount is intended to offset comparable rents that include the following
costs which Landlord will not incur in the event Tenant exercises its option (i)
brokerage commissions, (ii) tenant improvement allowances, (iii) building
improvement costs, and (iv) vacancy costs.
B. Determination of Fair Market Rental: If Tenant exercises the Option,
Landlord shall send Tenant notice no later than two hundred forty (240) days
before to the Lease Expiration Date setting forth the Fair Market Rental for the
Option Term. If Tenant disputes Landlord's determination of Fair Market Rental
for the Option Term, Tenant shall, within thirty (30) days after the date of
Landlord's notice setting forth Fair Market Rental for the Option Term, send to
Landlord a notice stating that Tenant either elects to terminate its exercise of
the Option, in which event the Option shall lapse and this Lease shall terminate
on the Expiration Date, or that Tenant disagrees with Landlord's determination
of Fair Market Rental for the Option Term and elects to resolve the disagreement
as provided in Section 18.C below. If Tenant does not send Landlord a notice as
provided in the previous sentence, Landlord's determination of Fair Market
Rental shall be the basis for computing the Base Monthly Rent payable by Tenant
during the Option Term. If Tenant elects to resolve the disagreement as provided
in Section 18.C and such procedures are not concluded prior to the commencement
date of the Option Term, Tenant shall pay to Landlord as Base Monthly Rent
ninety five percent (95%) of the Fair Market Rental as determined by Landlord in
the manner provided above. If the Fair Market Rental as
Page 21
<PAGE>
finally determined pursuant to Section 18.C is greater than Landlord's
determination, Tenant shall pay Landlord the difference between the amount paid
by Tenant and ninety five percent (95%) of the Fair Market Rental as so
determined in Section 18.C within thirty (30) days after such determination. If
the Fair Market Rental as finally determined in Section 18.C is less than
Landlord's determination, the difference between the amount paid by Tenant and
ninety five percent (95%) of the Fair Market Rental as so determined in Section
18.C shall be credited against the next installments of Base Monthly Rent due
from Tenant to Landlord hereunder.
C. Resolution of a Disagreement over the Fair Market Rental: Any
disagreement regarding Fair Market Rental shall be resolved as follows:
1. Within thirty (30) days after Tenant's response to Landlord's
notice setting forth the Fair Market Rental, Landlord and Tenant shall meet at a
mutually agreeable time and place, in an attempt to resolve the disagreement.
2. If within the 30-day period referred to above, Landlord and
Tenant cannot reach agreement as to Fair Market Rental, each party shall select
one appraiser to determine Fair Market Rental. Each such appraiser shall arrive
at a determination of Fair Market Rental and submit their conclusions to
Landlord and Tenant within thirty (30) days after the expiration of the 30-day
consultation period described above.
3. If only one appraisal is submitted within the requisite time
period, it shall be deemed as Fair Market Rental. If both appraisals are
submitted within such time period and the two appraisals so submitted differ by
less than ten percent (10%), the average of the two shall be deemed as Fair
Market Rental. If the two appraisals differ by more than 10%, the appraisers
shall immediately select a third appraiser who shall, within thirty (30) days
after his selection, make and submit to Landlord and Tenant a determination of
Fair Market Rental. This third appraisal will then be averaged with the closer
of the two previous appraisals and the result shall be Fair Market Rental.
4. All appraisers specified pursuant to this Section shall be
members of the American Institute of Real Estate Appraisers with not less than
ten (10) years experience appraising office and industrial properties in the
Santa Clara Valley. Each party shall pay the cost of the appraiser selected by
such party and one-half of the cost of the third appraiser.
D. Personal to Tenant: All Options provided to Tenant in this Lease are
personal and granted to VeriSign, Inc. (and any permitted transferee pursuant to
Section 17.E. above) and are not exercisable by any third party should Tenant
assign or sublet all or a portion of its rights under this Lease, unless
Landlord consents to permit exercise of any option by any assignee or subtenant,
in Landlord's sole and absolute discretion. In the event Tenant has multiple
options to extend this Lease, a later option to extend the Lease cannot be
exercised unless the prior option has been properly exercised.
19. General Provisions:
A. Attorney's Fees: In the event a suit or alternative form of dispute
resolution is brought for the possession of the Premises, for the recovery of
any sum due hereunder, to interpret the Lease, or because of the breach of any
other covenant herein; then the losing party shall pay to the prevailing party
reasonable attorney's fees including the expense of expert witnesses,
depositions and court testimony as part of its costs which shall be deemed to
have accrued on the commencement of such action. The prevailing party shall also
be entitled to recover all costs and expenses including reasonable attorney's
fees incurred in enforcing any judgment or award against the other party. The
foregoing provision relating to post-judgment costs is severable from all other
provisions of this Lease.
B. Authority of Parties: Tenant represents and warrants that it is duly
formed and in good standing, and is duly authorized to execute and deliver this
Lease on behalf of said corporation, in accordance with a duly adopted
resolution of the Board of Directors of said corporation or in accordance with
the by-laws of said corporation, and that this Lease is binding upon said
corporation in accordance with its terms. At Landlord's request, Tenant shall
provide Landlord with corporate resolutions or other proof in a form acceptable
to Landlord, authorizing the execution of the Lease.
Page 22
<PAGE>
C. Brokers: Tenant represents it has not utilized or contacted a real
estate broker or finder with respect to this Lease other than Cornish & Carey
Commercial and Tenant agrees to indemnify, defend and hold Landlord harmless
against any claim, cost, liability or cause of action asserted by any other
broker or finder claiming through Tenant.
D. Choice of Law: This Lease shall be governed by and construed in
accordance with California law. Except as provided in Section 19.E, venue shall
be Santa Clara County.
E. Dispute Resolution: Landlord and Tenant and any other party that may
become a party to this Lease or be deemed a party to this Lease including any
subtenants agree that, except for any claim by Landlord for unlawful detainer or
any claim within the jurisdiction of the small claims court (which small claims
court shall be the sole court of competent jurisdiction), any controversy,
dispute, or claim of whatever nature arising out of, in connection with or in
relation to the interpretation, performance or breach of this Lease, including
any claim based on contract, tort, or statute, shall be resolved at the request
of any party to this agreement through a two-step dispute resolution process
administered by J.A.M.S. or another judicial mediation service mutually
acceptable to the parties located in Santa Clara County, California. The dispute
resolution process shall involve first, mediation, followed, if necessary, by
final and binding arbitration administered by and in accordance with the then
existing rules and practices of J.A.M.S. or other judicial mediation service
selected. In the event of any dispute subject to this provision, either party
may initiate a request for mediation and the parties shall use reasonable
efforts to promptly select a J.A.M.S. mediator and commence the mediation. In
the event the parties are not able to agree on a mediator within thirty (30)
days, J. A. M. S. or another judicial mediation service mutually acceptable to
the parties shall appoint a mediator. The mediation shall be confidential and in
accordance with California Evidence Code (S). 1119 et. seq. The mediation shall
be held in Santa Clara County, California and in accordance with the existing
rules and practice of J. A. M. S. (or other judicial and mediation service
selected). The parties shall use reasonable efforts to conclude the mediation
within sixty (60) days of the date of either party's request for mediation. The
mediation shall be held prior to any arbitration or court action (other than a
claim by Landlord for unlawful detainer or any claim within the jurisdiction of
the small claims court which are not subject to this mediation/arbitration
provision and may be filed directly with a court of competent jurisdiction).
Should the prevailing party in any dispute subject to this Section 19.E attempt
an arbitration or a court action before attempting to mediate, the prevailing
party shall not be entitled to attorney's fees that might otherwise be available
to them in a court action or arbitration and in addition thereto, the party who
is determined by the arbitrator to have resisted mediation, shall be sanctioned
by the arbitrator or judge.
IF A MEDIATION IS CONDUCTED BUT IS UNSUCCESSFUL, IT SHALL BE FOLLOWED BY FINAL
AND BINDING ARBITRATION ADMINISTERED BY AND IN ACCORDANCE WITH THE THEN EXISTING
RULES AND PRACTICES OF J.A.M.S. OR THE OTHER JUDICIAL AND MEDIATION SERVICE
SELECTED, AND JUDGMENT UPON ANY AWARD RENDERED BY THE ARBITRATOR(S) MAY BE
ENTERED BY ANY STATE OR FEDERAL COURT HAVING JURISDICTION THEREOF AS PROVIDED BY
CALIFORNIA CODE OF CIVIL PROCEDURE SECTION 1280 ET. SEQ, AS SAID STATUTES THEN
APPEAR, INCLUDING ANY AMENDMENTS TO SAID STATUTES OR SUCCESSORS TO SAID STATUTES
OR AMENDED STATUTES, EXCEPT THAT IN NO EVENT SHALL THE PARTIES BE ENTITLED TO
PROPOUND INTERROGATORIES OR REQUEST FOR ADMISSIONS DURING THE ARBITRATION
PROCESS. THE ARBITRATOR SHALL BE A RETIRED JUDGE OR A LICENSED CALIFORNIA
ATTORNEY. THE VENUE FOR ANY SUCH ARBITRATION OR MEDIATION SHALL BE IN SANTA
CLARA COUNTY, CALIFORNIA.
NOTICE: BY INITIALING IN THE SPACE BELOW YOU ARE AGREEING TO HAVE ANY DISPUTE
ARISING OUT OF THE MATTERS INCLUDED IN THE "MEDIATION AND ARBITRATION OF
DISPUTES" PROVISION DECIDED BY NEUTRAL ARBITRATION AS PROVIDED BY CALIFORNIA LAW
AND YOU ARE GIVING UP ANY RIGHTS YOU MIGHT POSSESS TO HAVE THE DISPUTE LITIGATED
IN A COURT OR JURY TRIAL. BY INITIALING IN THE SPACE BELOW YOU ARE GIVING UP
YOUR JUDICIAL RIGHTS TO DISCOVERY AND APPEAL, UNLESS THOSE
Page 23
<PAGE>
RIGHTS ARE SPECIFICALLY INCLUDED IN THE "MEDIATION AND ARBITRATION OF DISPUTES"
PROVISION. IF YOU REFUSE TO SUBMIT TO ARBITRATION AFTER AGREEING TO THIS
PROVISION, YOU MAY BE COMPELLED TO ARBITRATE UNDER THE AUTHORITY OF THE
CALIFORNIA CODE OF CIVIL PROCEDURE. YOUR AGREEMENT TO THIS ARBITRATION PROVISION
IS VOLUNTARY.
WE HAVE READ AND UNDERSTAND THE FOREGOING AND AGREE TO SUBMIT DISPUTES ARISING
OUT OF THE MATTERS INCLUDED IN THE "MEDIATION AND ARBITRATION OF DISPUTES"
PROVISION TO NEUTRAL ARBITRATION.
LANDLORD: /s/ JMS TENANT: /s/ DLE
------------- -------------
F. Entire Agreement: This Lease and the exhibits attached hereto contains
all of the agreements and conditions made between the Parties hereto and may not
be modified orally or in any other manner other than by written agreement signed
by all parties hereto or their respective successors in interest. This Lease
supersedes and revokes all previous negotiations, letters of intent, lease
proposals, brochures, agreements, representations, promises, warranties, and
understandings, whether oral or in writing, between the parties or their
respective representatives or any other person purporting to represent Landlord
or Tenant.
G. Entry by Landlord: Upon prior notice to Tenant and subject to Tenant's
reasonable security regulations, Tenant shall permit Landlord and his agents to
enter into and upon the Premises at all reasonable times, and without any rent
abatement or reduction or any liability to Tenant for any reasonable loss of
occupation or quiet enjoyment of the Premises thereby occasioned, for the
following purposes: (i) inspecting and maintaining the Premises; (ii) making
repairs, alterations or additions to the Premises; (iii) erecting additional
building(s) and improvements on the land where the Premises are situated or on
adjacent land owned by Landlord; (iv) performing any obligations of Landlord
under the Lease including remediation of Hazardous Materials if determined to be
the responsibility of Landlord, (v) posting and keeping posted thereon notices
of non-responsibility for any construction, alteration or repair thereof, as
required or permitted by any law, and (vi) showing the Premises to Landlord's or
the Master Landlord's existing or potential successors, purchaser, tenants and
lenders. Tenant shall permit Landlord and his agents, at any time within one
hundred eighty (180) days prior to the Expiration Date (or at any time during
the Lease if Tenant is in default hereunder), to place upon the Premises "For
Lease" signs and exhibit the Premises to real estate brokers and prospective
tenants at reasonable hours.
H. Estoppel Certificates: At any time during the Lease Term, each party
(the "Responding Party") shall, within ten (10) business days following written
notice from the other party (the "Requesting Party"), execute and deliver to the
Requesting Party a written statement certifying, if true, the following: (i)
that this Lease is unmodified and in full force and effect (or, if modified,
stating the nature of such modification); (ii) the date to which rent and other
charges are paid in advance, if any; (iii) acknowledging that there are not, to
Responding Party's knowledge, any uncured defaults on Requesting Party's part
hereunder (or specifying such defaults if they are claimed); and (iv) such other
information as Requesting Party may reasonably request. Any such statement may
be conclusively relied upon by any prospective purchaser or encumbrancer of
Requesting Party's interest in the Premises. The Responding Party's failure to
deliver such statement within such time shall be conclusive upon the Responding
Party that this Lease is in full force and effect without modification, except
as may be represented by the Requesting Party, and that there are no uncured
defaults in Requesting Party's performance. Tenant agrees to provide, within
five (5) days of Landlord's request, Tenant's most recent three (3) years of
audited financial statements for Landlord's use in financing or sale of the
Premises or Landlord's interest therein.
I. Exhibits: All exhibits referred to are attached to this Lease and
incorporated by reference.
J. Interest: All rent due hereunder, if not paid when due, shall bear
interest at the rate of the Reference Rate published by Bank of America, San
Francisco Branch, plus two percent (2%) per annum from that date until paid in
full ("Agreed Interest Rate"). This provision shall survive the expiration or
sooner termination of the Lease. Despite any other
Page 24
<PAGE>
provision of this Lease, the total liability for interest payments shall not
exceed the limits, if any, imposed by the usury laws of the State of California.
Any interest paid in excess of those limits shall be refunded to Tenant by
application of the amount of excess interest paid against any sums outstanding
in any order that Landlord requires. If the amount of excess interest paid
exceeds the sums outstanding, the portion exceeding those sums shall be refunded
in cash to Tenant by Landlord. To ascertain whether any interest payable exceeds
the limits imposed, any non-principal payment (including late charges) shall be
considered to the extent permitted by law to be an expense or a fee, premium, or
penalty rather than interest.
K. This section intentionally left blank.
L. No Presumption Against Drafter: Landlord and Tenant understand, agree
and acknowledge that this Lease has been freely negotiated by both Parties; and
that in any controversy, dispute, or contest over the meaning, interpretation,
validity, or enforceability of this Lease or any of its terms or conditions,
there shall be no inference, presumption, or conclusion drawn whatsoever against
either party by virtue of that party having drafted this Lease or any portion
thereof.
M. Notices: All notices, demands, requests, or consents required to be
given under this Lease shall be sent in writing by U.S. certified mail, return
receipt requested, or by personal delivery addressed to the party to be notified
at the address for such party specified in Section 1 of this Lease, or to such
other place as the party to be notified may from time to time designate by at
least fifteen (15) days prior notice to the notifying party. When this Lease
requires service of a notice, that notice shall satisfy rather than supplement
any similar statutorily required notice, including any notice required by Code
of Civil Procedure Section 1161 or any similar or successor statute. When a
statute requires service of a notice in a particular manner, service of such
notice in the manner described in the first sentence of this Section 19.M. shall
satisfy such statutory requirement.
N. Property Management: In addition, Tenant agrees to pay Landlord along
with the expenses to be reimbursed by Tenant a monthly fee for management
services rendered by either Landlord or a third party manager engaged by
Landlord (which may be a party affiliated with Landlord), in the amount of three
percent (3%) of the Base Monthly Rent.
O. Rent: All monetary sums due from Tenant to Landlord under this Lease,
including, without limitation those referred to as "additional rent", shall be
deemed as rent.
P. Representations: Tenant acknowledges that neither Landlord nor any of
its employees or agents have made any agreements, representations, warranties or
promises with respect to the Premises or with respect to present or future
rents, expenses, operations, tenancies or any other matter. Except as herein
expressly set forth herein, Tenant relied on no statement of Landlord or its
employees or agents for that purpose.
Q. Rights and Remedies: Subject to Section 14 above, All rights and
remedies hereunder are cumulative and not alternative to the extent permitted by
law, and are in addition to all other rights and remedies in law and in equity.
R. Severability: If any term or provision of this Lease is held
unenforceable or invalid by a court of competent jurisdiction, the remainder of
the Lease shall not be invalidated thereby but shall be enforceable in
accordance with its terms, omitting the invalid or unenforceable term.
S. Submission of Lease: Submission of this document for examination or
signature by the parties does not constitute an option or offer to lease the
Premises on the terms in this document or a reservation of the Premises in favor
of Tenant. This document is not effective as a lease or otherwise until executed
and delivered by both Landlord and Tenant.
T. Subordination: This Lease is subject and subordinate to ground and
underlying leases, mortgages and deeds of trust (collectively "Encumbrances")
which may now affect the Premises, to any covenants, conditions or restrictions
of record, and to all renewals, modifications, consolidations, replacements and
extensions thereof; provided, however, if the holder or holders of any such
Encumbrance ("Holder") require that this Lease be prior and superior thereto,
within seven (7) days after written request of Landlord to Tenant, Tenant shall
execute, have acknowledged and deliver all documents or instruments, in the
commercially reasonable form presented to
Page 25
<PAGE>
Tenant, which Landlord or Holder deems necessary or desirable for such purposes.
Landlord shall have the right to cause this Lease to be and become and remain
subject and subordinate to any and all Encumbrances which are now or may
hereafter be executed covering the Premises or any renewals, modifications,
consolidations, replacements or extensions thereof, for the full amount of all
advances made or to be made thereunder and without regard to the time or
character of such advances, together with interest thereon and subject to all
the terms and provisions thereof; provided only, that in the event of
termination of any such lease or upon the foreclosure of any such mortgage or
deed of trust, Holder agrees to recognize Tenant's rights under this Lease as
long as Tenant is not in default either at the time Holder recognizes such
rights or at any time thereafter. Within ten (10) business days after Landlord's
written request, Tenant shall execute any documents in commercially reasonable
form required by Landlord or the Holder to make this Lease subordinate to any
lien of the Encumbrance, provided that within those documents the Tenant's
rights under this Lease are recognized only as long as Tenant is not in default.
If Tenant fails to do so, then in addition to such failure constituting a
default by Tenant, it shall be deemed that this Lease is so subordinated to such
Encumbrance. Notwithstanding anything to the contrary in this Section, Tenant
hereby attorns and agrees to attorn to any entity purchasing or otherwise
acquiring the Premises at any sale or other proceeding or pursuant to the
exercise of any other rights, powers or remedies under such encumbrance.
Landlord shall cause the existing lender to furnish to Tenant, within sixty (60)
days of the date of both parties' execution of this Lease, with a written
agreement providing for (i) recognition by the lender of all of the terms and
conditions of this Lease; and (ii) continuation of this Lease upon foreclosure
of existing lender's security interest in the Premises. In the event that
Landlord is unable to provide such agreement, Tenant's sole remedy shall be
termination of the Lease, which election shall be made within fourteen (14) days
following the expiration of such sixty (60) day period.
U. Survival of Indemnities: All indemnification, defense, and hold harmless
obligations of Landlord and Tenant under this Lease shall survive the expiration
or sooner termination of the Lease.
V. Time: Time is of the essence hereunder.
W. Transportation Demand Management Programs: Should a government agency or
municipality require Landlord to institute TDM (Transportation Demand
Management) facilities and/or programs, Tenant agrees that the cost of TDM
imposed facilities and programs required on the Premises, including but not
limited to employee showers, lockers, cafeteria, or lunchroom facilities, shall
be paid by Tenant. Further, any ongoing costs or expenses associated with a TDM
program which are required for the Premises and not provided by Tenant, such as
an on-site TDM coordinator, shall be provided by Landlord with such costs being
included as additional rent and reimbursed to Landlord by Tenant within thirty
(30) days after demand. If TDM facilities and programs are instituted on a
Project wide basis, Tenant shall pay its proportionate share of such costs in
accordance with Section 8 above.
X. Waiver of Right to Jury Trial: Landlord and Tenant waive their
respective rights to trial by jury of any contract or tort claim, counterclaim,
cross-complaint, or cause of action in any action, proceeding, or hearing
brought by either party against the other on any matter arising out of or in any
way connected with this Lease, the relationship of Landlord and Tenant, or
Tenant's use or occupancy of the Premises, including any claim of injury or
damage or the enforcement of any remedy under any current or future law,
statute, regulation, code, or ordinance.
Y. Recordation: A short form Memorandum of Lease, in form and content
reasonably acceptable to the parties, will be executed in recordable form by
each party following execution of this Lease, delivered to Tenant, and may be
recorded by Tenant at its expense.
20. RIGHT OF FIRST OFFER TO PURCHASE:
A. Grant and Exercise of Option: In the event Landlord elects to sell
the Building either separately or as part of a larger sale including other
building(s) within the Project ("Offered Property"), Landlord (referred to
hereinafter in this Section 20 as "Seller") hereby grants Tenant a right of
first offering to
Page 26
<PAGE>
purchase. Prior to Seller committing to sell its interest in the Offered
Property to a third party, Seller shall give Tenant written notice of such
desire and the terms and other information under which Seller intends to sell
the Offered Property. Provided at the time of such written notice: (i) Tenant
leases at least two buildings within the Project; and (ii) Tenant is not in
default under the Lease beyond the expiration of any applicable cure period,
Tenant shall have the option, which must be exercised, if at all, by written
notice to Seller within fifteen (15) days after Tenant's receipt of Seller's
notice, to purchase Seller's interest in the Offered Property at the sales price
and terms of sale specified in the notice. In the event Tenant timely exercises
such option to purchase its interest in the Offered Property, Seller shall sell
its interest in the Offered Property to Tenant, and Tenant shall purchase its
interest in the Offered Property from Seller in accordance with the price and
terms specified in Seller's notice. Seller and Tenant shall, in good faith,
attempt to reach agreement on the terms of a mutually acceptable purchase
agreement consistent with the terms set forth in Seller's notice within thirty
(30) days of Tenant's exercise of its option to purchase. In the event either:
(i) Tenant fails to exercise Tenant's option within said 15-day period; or (ii)
after Tenant's exercise, Seller and Tenant are unable to reach agreement on a
mutually acceptable purchase agreement within the subsequent 30-day period;
Seller shall have one hundred eighty (180) days thereafter to sell its interest
in the Offered Property at no less than ninety percent (90%) of the sales price
and upon substantially the same other terms of sale as specified in the notice
to Tenant. In the event Seller fails to sell its interest in the Offered
Property within said one hundred eighty (180) day period or in the event Seller
proposes to sell its interest in the Offered Property at less than ninety
percent (90%) of the sales price or on other material terms which are more
favorable to the prospective buyer than that proposed to Tenant, Seller shall be
required to resubmit such offer to Tenant in accordance with this Right of First
Offering except that Tenant shall be required to respond to any resubmission
within a seven (7) day period.
B. Exclusions: This Right of First Offering shall automatically terminate
(i) upon the expiration or sooner termination of the Lease, or (ii) in the event
of a foreclosure or other involuntary transfer of Landlord's interest in the
Building. Further, this Right of First Offering shall not apply to transfers
(but shall survive such transfers) of all or a portion of the Building or
Project to (i) John A. Sobrato and/or John M. Sobrato (individually and
collectively "Sobrato"), (ii) any immediate family member of Sobrato, (iii) any
trust established, in whole or in part, for the benefit of Sobrato and/or any
immediate family member of Sobrato, (iv) any partnership in which Sobrato or any
immediate family member, either directly or indirectly (e.g., through a
partnership or corporate entity or a trust) retains a general partner interest,
and/or (v) any corporation under the control, either directly or indirectly, by
Sobrato or any immediate family member of Sobrato.
Page 27
<PAGE>
IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease on the day and
year first above written.
Landlord: Ellis-Middlefield Business Park, Tenant: VeriSign, Inc.
a California Limited Partnership a Delaware corporation
By: /s/ John M. Sobrato * By: /s/ Dana L. Evan
--------------------------------- ---------------------------
Its: GP Its: CFO, EVP
-------------------------------- ---------------------------
* By: /s/ Stratton D. Sclavos
----------------------------
Its: President/CEO
---------------------------
* NOTE: This lease must either: (i) be signed by two (2) officers of such
corporation: one being the chairman of the board, the president, or a vice
president, and the other being the secretary, an assistant secretary, the chief
financial officer or an assistant treasurer; or (ii) signed by the chief
financial officer and accompanied by a corporate resolution authorizing such
signing. With respect to item (i) above, if one (1) individual is signing in two
(2) of the foregoing capacities, that individual must sign twice; once as one
officer and again as the other officer and in such event, Tenant must deliver to
Landlord a certified copy of a corporate resolution authorizing the signatory to
execute this Lease.
Page 28
<PAGE>
Exhibit "A" - Premises, Building & Project
[PLAN]
Page 29
<PAGE>
Exhibit "A-1" - Premises, Building & Project
[PLAN]
Page 30
<PAGE>
EXHIBIT "B" - Draft Letter of Credit
IRREVOCABLE STANDBY LETTER OF CREDIT NO.
DATE:
BENEFICIARY:
APPLICANT:
AMOUNT: $
EXPIRY DATE:
LOCATION: AT OUR COUNTER IN SANTA CLARA
DEAR SIR/MADAM:
WE HEREBY ESTABLISH OUR IRREVOCABLE STANDBY LETTER OF CREDIT NO. ______________
IN YOUR FAVOR. AVAILABLE FOR PAYMENT BY BANK,
, CA , ATTN: INT'L DEPT. OF BENEFICIARY'S DRAFT AT SIGHT DRAWN ON
US, AND ACCOMPANIED BY THE FOLLOWING DOCUMENTS:
1. THE ORIGINAL OF THIS LETTER OF CREDIT AND ALL AMENDMENTS IF ANY.
2. A SIGNED AND DATED CERTIFICATE FROM A DULY AUTHORIZED OFFICER OR
MEMBER OF THE BENEFICIARY FOLLOWED BY ITS DESIGNATED TITLE STATING THE
FOLLOWING.
"AN EVENT OF DEFAULT (AS DEFINED IN THE LEASE) HAS OCCURRED BY
, AS TENANT UNDER THAT CERTAIN LEASE AGREEMENT
DATED ____________ BETWEEN TENANT, AND ______________ AS LANDLORD.
FURTHERMORE THIS IS TO CERTIFY THAT; (I) LANDLORD HAS GIVEN WRITTEN
NOTICE TO TENANT TO CURE THE DEFAULT PURSUANT TO THE TERMS OF THE
LEASE; (II) SUCH DEFAULT HAS NOT BEEN CURED UP TO THIS DATE OF DRAWING
UNDER THIS LETTER OF CREDIT; AND (III) THE TERMS AND CONDITIONS OF THE
LEASE AUTHORIZE LANDLORD TO NOW DRAW DOWN ON THE LETTER OF CREDIT.
SPECIAL CONDITION:
IT IS A CONDITION OF THIS LETTER OF CREDIT THAT IT WILL BE DEEMED AUTOMATICALLY
RENEWED WITHOUT AN AMENDMENT FOR A PERIOD OF ONE YEAR FROM THE PRESENT OR EACH
FUTURE EXPIRATION DATE UNLESS AT LEAST THIRTY (30) DAYS PRIOR TO SUCH EXPIRY
DATE WE NOTIFY YOU IN WRITING SENT BY OVERNIGHT MAIL THAT WE ELECT NOT TO RENEW
THIS LETTER OF CREDIT FOR SUCH ADDITIONAL PERIOD, OR TENANT FAILS TO REPLACE A
NEW LETTER OF CREDIT, IN WHICH EVENT LANDLORD MAY DRAW UPON THIS LETTER OF
CREDIT AND THEREAFTER TREAT SUCH CASH AS A PORTION OF THE SECURITY DEPOSIT.
IN NO EVENT SHALL THIS LETTER OF CREDIT BE AUTOMATICALLY EXTENDED BEYOND
PARTIAL DRAWINGS ARE PERMITTED.
ALL DOCUMENTS INCLUDING DRAFT(S) MUST INDICATE THE NUMBER AND DATE OF THIS
CREDIT.
EACH DRAFT PRESENTED HEREUNDER MUST BE ACCOMPANIED BY THIS ORIGINAL LETTER OF
CREDIT FOR OUR ENDORSEMENT THEREON OF THE AMOUNT OF SUCH DRAFT(S).
DOCUMENTS MUST BE SENT TO USE VIA OVERNIGHT COURIER (I.E. FEDERAL EXPRESS, UPS,
DHL OR ANY OTHER EXPRESS COURIER) AT OUR ADDRESS:
, CA 95054
ATTN:
WE HEREBY ENGAGE WITH DRAWERS AND/OR BONAFIDE HOLDERS THAT DRAFT(S) DRAWN UNDER
AND NEGOTIATED IN CONFORMANCE WITH THE TERMS AND CONDITIONS OF THE SUBJECT
CREDIT WILL BE DULY HONORED ON PRESENTATION.
THIS CREDIT IS SUBJECT TO THE UNIFORM CUSTOMS AND PRACTICE FOR DOCUMENTARY
CREDITS (1993 REVISION), INTERNATIONAL CHAMBER OF COMMERCE PUBLICATION 500.
_______________________________ _____________________________
AUTHORIZED SIGNATURE AUTHORIZED SIGNATURE
Page 31
<PAGE>
EXHIBIT "C" - Building Shell Definition
1. Building Structure
(a) Foundations including footings, grade beams, or other building foundation
components required to support the Building structure.
(b) Five inch (5") thick concrete slab on grade with welded wire mesh and any
other reinforcing or structural connections that may be necessary or required as
specified by structural engineer.
(c) Complete structural framing system comprised of rolled steel beams,
columns, and braced-frame steel construction with corrugated metal deck and
concrete fill, all members required by code to be fireproofed. Upper floor
systems provide a minimum of 3" concrete over metal deck and are designed for an
80 lb. live load plus 20 lb. partition load. Structural framing will include
intermediate beams for HVAC units at the roof, and for major shafts on each
floor.
(d) Exterior Building skin consisting of performance glass with aluminum
framing, GFRC panels, and glass block. All exterior doors, door closer and
locking devices as necessary.
(e) Four (4) ply built up roofing by Owens-Corning, John Manville, or equal and
all flashings over a perlite board and corrugated metal deck roof assembly.
Title 24 code required roof insulation is included.
(f) Exterior painting of all non-finished metals and caulking of all exterior
joints.
(g) Concrete pan-filled stairs in the interior core of the building, and two
(2) concrete pan-filled stair sets at the Building perimeter.
(h) Riser for building sprinkler system (no sprinkler grid or drops).
2. Sitework
(a) All work outside the Building perimeter walls shall be considered site work
for the Building Shell
Page 32
<PAGE>
and shall include asphalt concrete paving, parking (including a parking
structure for approximately 380 cars as generally shown on Exhibit "A"),
landscaping, landscape irrigation, storm drainage, utility service laterals,
curbs, gutters, sidewalks, retaining walls, planters, trash enclosures, parking
lot and landscape lighting and other exterior lighting per code.
(b) Paving sections for automobile and truck access shall be according to the
Geologic Soils Report.
(c) All parking lot striping to include handicap spaces and signage.
(d) Underground site storm drainage system shall be connected to the city storm
system main.
3. Plumbing
(a) Underground sanitary sewer laterals connected to the city sewer main in the
street and stubbed to the core of the Building.
(b) Domestic water mains connected to the city water main in the street and
stubbed to the Building.
(c) Roof drain leaders and downspouts piped and connected to the site storm
drainage system.
(d) Gas lines connected to the city or public utility mains and run to gas
meters adjacent to, and in close proximity to the building. Meter supplied by
utility company.
4. Electrical
(a) A primary and secondary electrical service from the street to the building
electrical room limited to underground conduit, pull-string, and transformer
pad. Transformer supplied by utility company.
(b) Two 4" underground conduit from the street to the building for telephone
trunk lines by Pacific Bell.
(c) An electrically operated landscape irrigation system, with controller, that
is a complete and functioning system.
Page 33
<PAGE>
(d) Underground conduit with pull-string from the Building to the main fire
protection system post indicated valve (PIV) for installation of supervisory
alarm wiring.
6. General
(a) All construction shall conform to State and Local Building Codes, Title 24
Regulations, and shall be ADA Compliant.
All other costs shall be deemed Tenant Improvements.
Page 34
<PAGE>
EXHIBIT "D" - Building Plans and Specifications
(to be attached)
Page 35
<PAGE>
EXHIBIT "E" - Preliminary Schematic Design Drawings
Page 36
<PAGE>
EXHIBIT "F" - Tenant Improvement Plans and Specifications
Page 37
