FORM 10-Q
SECURITIES AND EXCHANGE COMMISSION
WASHINGTON, D.C. 20549
[x] QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
SECURITIES EXCHANGE ACT OF 1934
For the quarterly period ended March 31, 1997
OR
[ ] TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
SECURITIES EXCHANGE ACT OF 1934
Commission file number 1-7411
ALLCITY INSURANCE COMPANY
(Exact name of registrant as specified in its charter)
New York 13-2530665
(State or other jurisdiction of (I.R.S. Employer
incorporation or organization) Identification No.)
122 Fifth Avenue, New York, New York 10011
(Address of principal executive offices) (Zip Code)
Registrant's telephone number, including area code: (212)387-3000
Indicate by check mark whether the Registrant (1) has filed all reports required
to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during
the preceding 12 months (or for such shorter period that the Registrant was
required to file such reports), and (2) has been subject to such filing
requirements for the past 90 days. Yes[X] No[ ]
On May 6, 1997 there were 7,078,625 shares of Common Stock outstanding.
<PAGE>
ALLCITY INSURANCE COMPANY
-------------------------
INDEX
-----
PART I Financial Information PAGE
- ------ --------------------- ----
Item 1. Interim Consolidated Financial Statements (Unaudited)
Consolidated Balance Sheets - March 31, 1997 and December 31,
1996................................................................. 2
Consolidated Statements of Income - Three months ended March
31, 1997 and March 31, 1996.......................................... 3
Consolidated Statements of Cash Flows - Three months ended March
31, 1997 and March 31, 1996.......................................... 4
Consolidated Statements of Changes in Shareholders' Equity - Three
months ended March 31, 1997 and March 31, 1996....................... 5
Notes to Interim Consolidated Financial Statements................... 6
Item 2. Management's Discussion and Analysis of Financial Condition
and Interim Results of Operations............................. 7-8
PART II Other Information
- ------- -----------------
Item 6. Exhibits and Reports on Form 8-K.............................. 9
Signatures............................................................. 10
-1-
<PAGE>
CONSOLIDATED BALANCE SHEETS
ALLCITY INSURANCE COMPANY
(Thousands of dollars, except par value amounts)
March 31, December 31,
1997 1996
---------- -------------
(Unaudited)
ASSETS
Investments:
Available for sale (aggregate cost of
$251,271 in 1997 and $254,645 in 1996) $246,618 $252,073
Held to maturity (aggregate fair value
of $482 in 1997 and $485 in 1996) 476 477
Short term (at cost) 7,578 20,442
--------- ---------
TOTAL INVESTMENTS 254,672 272,992
Cash 3,264 2,232
Agents' balances, less allowance for doubtful
accounts ($1,400 in 1997 and $1,363 in 1996) 20,255 17,814
Accrued investment income 3,784 2,822
Reinsurance balances receivable 266,105 264,159
Prepaid reinsurance premiums 68,564 70,061
Deferred policy acquisition costs 8,083 7,707
Deferred income taxes 13,721 13,019
Other assets 3,545 2,924
--------- ---------
TOTAL ASSETS $641,993 $653,730
========= =========
LIABILITIES
Unpaid losses $353,817 $353,536
Unpaid loss adjustment expenses 52,552 52,551
Unearned premiums 113,290 111,657
Accounts payable and accrued liabilities 2,472 2,644
Drafts payable 5,000 5,712
Due to affiliates 3,007 14,232
Unearned service fee income 6,116 5,461
Reserve for servicing carrier claim expenses 7,742 8,043
Other postretirement benefits 3,759 3,819
Reinsurance balances payable 3,212 4,887
Other liabilities 1,602 1,415
Surplus note 14,263 14,115
--------- ---------
TOTAL LIABILITIES 566,832 578,072
--------- ---------
SHAREHOLDERS' EQUITY
Common stock, par value $1.00: 7,368,420
shares authorized; 7,078,625 shares issued
and outstanding in 1997 and 1996 7,079 7,079
Additional paid-in capital 9,331 9,331
Net unrealized losses on investments (3,025) (1,672)
Retained earnings 61,776 60,920
--------- ---------
TOTAL SHAREHOLDERS' EQUITY 75,161 75,658
--------- ---------
TOTAL LIABILITIES AND SHAREHOLDERS' EQUITY $641,993 $653,730
========= =========
See Notes to Interim Consolidated Financial Statements.
-2-
<PAGE>
CONSOLIDATED STATEMENTS OF INCOME (Unaudited)
ALLCITY INSURANCE COMPANY
(Thousands of dollars, except per share amounts)
Three Months Ended
March 31
-------------------
1997 1996
---- ----
REVENUES
Premiums earned $22,222 $24,943
Net investment income less expenses of $100
in 1997 and $98 in 1996 3,863 4,072
Service fee income 1,895 1,230
Net securities gains 17 464
Other income 111 175
-------- --------
28,108 30,884
-------- --------
LOSSES AND EXPENSES
Losses 17,124 18,565
Loss adjustment expenses 2,825 3,414
Other underwriting expenses less deferrals
of $4,312 in 1997 and $5,868 in 1996 2,757 3,008
Amortization of deferred policy acquisition
costs 3,936 4,892
Interest on surplus note 149 149
-------- --------
26,791 30,028
-------- --------
INCOME BEFORE FEDERAL INCOME TAXES 1,317 856
FEDERAL INCOME TAXES
Current 435 930
Deferred (benefit) 26 (630)
-------- --------
461 300
-------- --------
NET INCOME $ 856 $ 556
======== ========
Per share data, based on 7,078,625 average shares outstanding in 1997 and 1996:
NET INCOME PER SHARE $0.12 $0.08
======== ========
See Notes to Interim Consolidated Financial Statements.
-3-
<PAGE>
CONSOLIDATED STATEMENTS OF CASH FLOWS (Unaudited)
ALLCITY INSURANCE COMPANY
(Thousands of dollars)
Three Months Ended
March 31
------------------
1997 1996
---- ----
NET CASH FLOWS FROM OPERATING ACTIVITIES
Net income $ 856 556
Adjustments to reconcile net income to net
cash (used for) provided by operations:
Provision for deferred tax benefits 26 (630)
Amortization 4,072 5,026
Provision for doubtful accounts 37 75
Net securities gains (17) (464)
Policy acquisition costs incurred and deferred (4,312) (5,868)
Net change in:
Agents' balances (2,478) (4,210)
Reinsurance balances receivable (1,946) (5,636)
Prepaid reinsurance premiums 1,497 (5,311)
Unpaid losses and loss adjustment expenses 282 7,852
Unearned premiums 1,633 11,842
Drafts payable (712) 493
Due to affiliates (11,225) 1,577
Unearned services fees 655 1,605
Reserve for servicing carrier claim expense (301) 987
Reinsurance balances payable (1,675) (1,402)
Other (1,351) (2,546)
--------- --------
NET CASH (USED FOR) PROVIDED BY OPERATING ACTIVITIES (14,959) 3,946
--------- --------
NET CASH FLOWS FROM INVESTING ACTIVITIES
Available for sale:
Acquisition of fixed maturities (27,433) (93,588)
Proceeds from sale of fixed maturities 29,554 75,974
Proceeds from maturities of fixed maturities 1,006 7,694
Net change in short-term investments 12,864 7,705
--------- --------
NET CASH PROVIDED BY (USED FOR) INVESTING ACTIVITIES 15,991 (2,215)
--------- --------
NET INCREASE IN CASH 1,032 1,731
Cash at beginning of period 2,232 3,272
--------- --------
Cash at the end of period $ 3,264 $ 5,003
--------- --------
See Notes to Interim Consolidated Financial Statements.
-4-
<PAGE>
CONSOLIDATED STATEMENTS OF CHANGES IN SHAREHOLDERS' EQUITY (Unaudited)
ALLCITY INSURANCE COMPANY
(Thousands of dollars)
Net
Common Unrealized
Shares Additional Gain
$1 Par Paid-in (Loss) on Retained
Value Capital Investments Earnings Total
------- ---------- ----------- -------- -----
Balance, January 1, 1996 $7,079 $9,331 $ 1,240 $58,286 $75,936
Net change in unrealized
gain (loss) on
investments (3,247) (3,247)
Net income 556 556
------- ------ --------- ------- -------
Balance, March 31, 1996 $7,079 $9,331 $ (2,007) $58,842 $73,245
======= ====== ========= ======= =======
Balance, January 1, 1997 $7,079 $9,331 $ (1,672) $60,920 $75,658
Net change in unrealized
(loss) on investments (1,353) (1,353)
Net income 856 856
------- ------ --------- ------- -------
Balance, March 31, 1997 $7,079 $9,331 $ (3,025) $61,776 $75,161
======= ====== ========= ======= =======
See Notes to Interim Consolidated Financial Statements.
-5-
<PAGE>
ALLCITY INSURANCE COMPANY
NOTES TO INTERIM CONSOLIDATED FINANCIAL STATEMENTS
1. The unaudited interim consolidated financial statements, which reflect all
adjustments (consisting only of normal recurring items) that management believes
necessary to fairly present interim results of operations, should be read in
conjunction with the Notes to Consolidated Financial Statements (including the
Summary of Significant Accounting Policies) included in the Company's audited
consolidated financial statements for the year ended December 31, 1996, which
are included in the Company's Annual Report filed on Form 10-K for such year
(the "1996 10-K"). Results of operations for interim periods are not necessarily
indicative of annual results of operations. The consolidated balance sheet at
December 31, 1996 was extracted from the audited annual financial statements and
does not include all disclosures required by generally accepted accounting
principles for annual financial statements.
2. Certain amounts for prior periods have been reclassified to conform with
the 1997 presentation.
-6-
<PAGE>
Item 2. Management's Discussion and Analysis of Financial Condition and
- ------- ---------------------------------------------------------------
Interim Results of Operations
-----------------------------
The following should be read in conjunction with "Management's Discussion
and Analysis of Financial Condition and Results of Operations" included in the
1996 10-K.
LIQUIDITY AND CAPITAL RESOURCES
During each of the three month periods ended March 31, 1997 and 1996 the
Company operated profitably. In 1997, the Company had a negative cash flow from
operations principally due to decreased premiums and increased loss and loss
adjustment expense payments as a result of a program to reduce pending claims.
Cash required to fund operations was principally provided from the maturity of
short-term investments.
The Company maintains cash, short-term and readily marketable securities in
an amount sufficient to satisfy its anticipated cash needs and believes it has
sufficient capital to meet its currently anticipated level of operations.
RESULTS OF OPERATIONS--THREE MONTHS ENDED MARCH 31, 1997 COMPARED TO THE THREE
MONTHS ENDED MARCH 31, 1996
Earned premium revenues for the first quarter 1997 were $2.7 million, or
11%, lower than those of the first quarter 1996. This decrease was primarily due
to the depopulation of the assigned risk automobile pools and reduced volume in
certain commercial lines resulting from tighter underwriting standards and
increased competition.
Investment income decreased by $0.2 million, or 5%, when compared to the
first quarter 1996 due largely to the decrease in invested assets caused by the
negative cash flow from operations.
-7-
<PAGE>
Service fee income for the first quarter 1997 was $0.7 million, or 54%,
higher than the first quarter 1996. The increase is largely the result of
reductions in the estimates of fees earned as a servicing carrier for the New
York Public Automobile Pool and assigned risk business in the first quarter
1996.
Losses incurred for the first quarter 1997 were $1.4 million, or 8%, less
than the first quarter 1996 generally as a result of the reduced volume of
business. The loss ratio is higher in 1997 primarily as a result of higher loss
reserves on assigned risk business arising from a depopulating New York
Automobile Insurance Plan.
Loss adjustment expenses for the first quarter 1997 were $0.6 million, or
17%, lower than the first quarter 1996. The decrease is mainly due to certain
unusual expense charges which were recorded in the first quarter 1996, a portion
of which is allocated to loss adjustment expense.
The combination of other underwriting expenses and the amortization of
deferred policy acquisition costs for the first quarter 1997 was $1.2 million,
or 15%, less than the first quarter 1996. The decrease is the result of lower
operating costs due to reduced premium volume in 1997 and certain unusual
expense charges recorded in the first quarter 1996.
-8-
<PAGE>
Part II - Other Information
------- -----------------
Item 6. Exhibits and Reports on Form 8-K
- ------ --------------------------------
a) Exhibits
The following exhibit is filed herewith:
Exhibit Number Description of Document
-------------- -----------------------
10(a) Lease Agreement, dated June 27, 1996, between
Empire Insurance Company (the Parent Company of
the registrant) and Brooklyn Renaissance Plaza
LLC, as Landlord, BRPII LLC, as Sublandlord.
27 Financial Data Schedule
b) Reports on Form 8-K
There were no reports on Form 8-K filed for the three months ended
March 31, 1997.
-9-
<PAGE>
SIGNATURES
----------
Pursuant to the requirements of the Securities Exchange Act of 1934,
the Registrant has duly caused this report to be signed on its behalf by the
undersigned thereunto duly authorized.
ALLCITY INSURANCE COMPANY
Registrant
Date: May 12, 1997 By FRANCIS M. COLALUCCI
---------------- -----------------------------------------
Francis M. Colalucci
Senior Vice President, CFO and Treasurer
(Principal Financial and Accounting
Officer)
-10-
<PAGE>
EXHIBIT 10 (a)
<PAGE>
AGREEMENT OF LEASE
BETWEEN
BROOKLYN RENAISSANCE PLAZA LLC, AS
LANDLORD, BRP II LLC, AS SUBLANDLORD,
AND
EMPIRE INSURANCE COMPANY, AS TENANT
JUNE 27, 1996
<PAGE>
TABLE OF CONTENTS
ARTICLE 1 ................................................................ 3
DEFINITIONS .................................................... 3
ARTICLE 2 ................................................................ 15
ARTICLE 2 ................................................................ 15
LANDLORD'S WORK - TENANT'S PLAN - CONSTRUCTION ................. 15
Section 2.0 Tenant's Improvement Fund ..................... 15
Section 2.1 Tenant's Work Plan ............................ 17
Section 2.2 Construction .................................. 24
Section 2.3 Building Under Construction ................... 34
Section 2.4 Section 223(a) of Real Property Law............ 35
ARTICLE 3 ................................................................ 36
RENT ........................................................... 36
Section 3.1 Payment ....................................... 36
Section 3.2 Base Annual Rent............................... 38
Section 3.3 Adjustment to Base Annual Rent................. 38
Definitions .......................................... 38
Taxes ................................................ 48
Office Portion Operating Expenses .................... 50
General .............................................. 54
Section 3.4 Late Charges .................................. 56
ARTICLE 4 ................................................................ 57
COMMON AREAS ................................................... 57
Section 4.1 Common Areas .................................. 57
ARTICLE 5 ................................................................ 62
UTILITIES - SERVICES ........................................... 62
Section 5.0 Sublandlord ................................... 62
Section 5.1 Electricity ................................... 62
Section 5.2 Access ........................................ 64
Section 5.3 Elevator Service .............................. 65
Section 5.4 Heat .......................................... 66
Section 5.5 Air-Conditioning .............................. 66
Section 5.6 Water ......................................... 67
Section 5.7 Directory ..................................... 68
Section 5.8 Cleaning ...................................... 69
Section 5.9 Extra Services ................................ 70
Section 5.10 Parking ...................................... 71
ii
<PAGE>
Section 5.11 Interruption of Services ..................... 71
Section 5.12 Miscellaneous ................................ 74
ARTICLE 6 ................................................................ 74
LANDLORD'S ADDITIONAL COVENANTS ................................ 74
Section 6.0 Sublandlord ................................... 74
Section 6.1 Repairs by Landlord ........................... 75
Section 6.2 Quiet Enjoyment ............................... 77
Section 6.3 Landlord's and Sublandlord's Title ............ 78
Section 6.4 Landlord's Liability .......................... 78
Section 6.5 Taxes, Assessments, Water Rates, Sewer Rents .. 81
Section 6.6 Legal Fees .................................... 82
Section 6.7 Insurance...................................... 83
Section 6.8 Funding of Tenant Improvements ................ 83
Section 6.9 Landlord's Indemnification of Tenant .......... 84
ARTICLE 7 ................................................................ 85
TENANT'S ADDITIONAL COVENANTS .................................. 85
Section 7.1 Affirmative Covenants .......................... 85
Section 7.2 Negative Covenants ............................. 100
Section 7.3 Indemnification of Sublandlord ................. 108
Section 7.4 Environmental Indemnity ........................ 113
ARTICLE 8 ................................................................ 116
DESTRUCTION, CONDEMNATION ...................................... 116
Section 8.1 Destruction, Fire and Other Casualty........... 116
Section 8.2 Eminent Domain................................. 121
ARTICLE 9 ................................................................ 125
DEFAULTS AND REMEDIES .......................................... 125
Section 9.1 Default ....................................... 125
Section 9.2 Remedies ...................................... 128
Section 9.3 Trial by Jury: Counterclaim ................... 131
Section 9.4 Landlord's and Sublandlord's Right
to Cure Defaults ..................................... 132
Section 9.5 Waiver of Default ............................. 132
ARTICLE 10 ............................................................... 133
TENANT'S OPTION TO EXTEND TERM ................................. 133
Section 10.1 Option to Extend ............................. 133
ARTICLE 11 ............................................................... 137
ASSIGNMENT AND SUBLETTING ...................................... 137
iii
<PAGE>
ARTICLE 12 ............................................................... 139
AMENDMENT OF LEASE ............................................. 139
ARTICLE 13 ............................................................... 140
SUBORDINATION AND ATTORNMENT ................................... 140
Section 13.1 Subordination................................. 140
Section 13.2 Attornment.................................... 142
ARTICLE 14 ............................................................... 148
MISCELLANEOUS PROVISIONS ...................................... 148
Section 14.1 Notices ...................................... 148
Section 14.2 Brokerage .................................... 149
Section 14.3 Estoppel Certificates ........................ 150
Section 14.4 Applicable Law and Construction .............. 151
Section 14.5 Relationship of the parties .................. 152
Section 14.6 Construction on Adjacent Premises
or Buildings ......................................... 152
Section 14.7 Short Form lease ............................. 153
Section 14.8 Binding Effect of Lease ...................... 153
Section 14.9 Effect of Unavoidable Delays ................. 153
Section 14.10 No Oral changes ............................. 155
Section 14.11 Executed Counterparts of Lease .............. 155
Section 14.12 Arrangement of Entrances. Etc. .............. 155
Section 14.13 Condominium ................................. 156
Section 14.14 Waiver of Subrogation ....................... 157
Section 14.15 Access by HANDICAPPED PERSONS ............... 158
Section 14.16 Diligence ................................... 158
Section 14.17 Condominimn Documents........................ 158
Section 14.18 Interest on Offset Amounts .................. 158
Section 14.19 No Termination. ............................. 159
Section 14.20 Due Authorization ........................... 160
ARTICLE 15 ............................................................... 160
ARBITRATION .................................................... 160
SECTION 15.0 SUBLANDLORD .................................. 160
SECTION 15.1 ARBITRATION .................................. 160
SECTION 15.2 EXPEDITED DISPUTE RESOLUTION ................. 161
ARTICLE 16 ............................................................... 165
CERTIFICATE OF OCCUPANCY - COMPLIANCE WITH LAWS ................ 165
iv
<PAGE>
SCHEDULE OF EXHIBITS
TO
LEASE BETWEEN
CARLYLE, MUSS, LEUCADIA J.V.
AND
EMPIRE INSURANCE COMPANY
Exhibit A Base Building/Building Specifications
B Floor Plans
C The Land
D Preliminary Plans and Specifications
E Rules and Regulations
F Standard Building Hours and Days
G Title Matters
H Cleaning Specifications
I City of New York Benefits
<PAGE>
AGREEMENT OF LEASE made as of the 27th day of June, 1996
between BROOKLYN RENAISSANCE PLAZA LLC, a New York limited liability company
having an office at 118-35 Queens Boulevard, Forest Hills, New York 11375,
hereinafter referred to as "Landlord"), BRP II LLC, a New York limited
liability company having an office at 118-35 Queens Boulevard, Forest Hills, New
York 11375 ("Sublandlord") and EMPIRE INSURANCE COMPANY having an address at 122
Fifth Avenue New York, New York 10011 (hereinafter referred to as "Tenant").
B E C I T A L
- - - - - - -
WHEREAS, the parties hereto desire to enter into a lease for
the Premises (as hereinafter defined); and
WHEREAS, concurrently herewith, it is intended that financing
for the construction of the "Building" be obtained in part through the issuance
of notes SECURED BY THE "SANDWICH LEASE", the principal of and interest on which
is to be payable solely from "Possession Rent" payable by Tenant under this
Lease; and
WHEREAS, Landlord immediately prior to the execution of this
Lease, leased "Office Unit 2" to Sublandlord, subject to this Lease, pursuant to
a lease (the "Sandwich Lease"), which, among other things, (i) is for a term
that expires one (1) day prior to
<PAGE>
the expiration or earlier termination of the "Ground Lease, , and (ii)
provides that, except for ensuring the proper application of funds received
pursuant to this Lease, Sublandlord is to have no liabilities under or with
respect to this Lease or to Tenant during the Term (excluding any "Renewal
Period";
NOW, THEREFORE, Sublandlord hereby leases to Tenant and Tenant
hereby hires and takes from Sublandlord, the "Premises", located in the
proposed building known as Brooklyn Renaissance Plaza located between Jay and
Adams Streets at the foot of Myrtle Avenue, Brooklyn, New York, together with
(a) the exclusive right to use all "Limited Common Elements". appurtenant solely
to "Office Unit 2", (b) a nonexclusive right, together with other occupants of
the "Building", to use all "Limited Common Elements" appurtenant both to "Office
Unit 2" and to another "Unit" and (c) a nonexclusive right, together with other
occupants of the "Building", to use the "General Common Elements", all for a
term of twenty (20) -years commencing on the "Commencement DATE" (THE "Term"),
subject to the terms, covenants, conditions and provisions of this lease and
subject to "Title Matters".
The capitalized terms contained in the foregoing paragraphs
and enclosed in quotation marks and not defined above are defined hereinafter.
2
<PAGE>
ARTICLE 1
DEFINITIONS
Whenever used in this Lease, the following terms shall have the meanings
indicated below.
Actual Office Portion As defined in Section 3.3C(i)(c)
Operating Expenses
Affiliate Any Person which controls or is controlled by the
Person in question or is controlled by the same
Persons which shall then control the Person in
question and any Person which is a member (or
controls or is controlled by a Person who is a
member) with the Person in question in a
relationship of joint venture, partnership
or other form of business association; the term
"control" means having a 20% or greater voting or
stock ownership interest of the controlled entity.
Agency New York City Industrial Development Agency.
Arbiter AS DEFINED IN SECTION 15.2A.
Architect William B. Tabler Architects, or any other
registered architect selected by Landlord.
Base Annual Rent (a) $4,906,435 per Lease Year for each of the
first (1st) through fifth (5th) Lease Years
($17.12 PER square foot);
3
<PAGE>
(b) $5,642,401 per Lease Year from the sixth (6th)
through tenth ( lOth) Lease Years ($19.69 per
square foot );
(c) $6,489,406 per Lease Year from the eleventh
(11th ) through fifteenth (15th) Lease Years
($22.65 per square foot);
(d) $7,462,946 per Lease Year from the sixteenth
(16th) through twentieth (20th) Lease Years
($26.05 per square foot );
The Base Annual Rent is subject to further
increase as provided in Articles 3 and 10 of this
Lease.
Base Building As set forth in Exhibit A annexed hereto and made
a part hereof.
Board of Managers The Board of Managers of the Condominium
Bond Support Payments As defined in Section 3.1B.
Bond Trustee United States Trust Company of New York, in its
capacity as Trustee of the Empire Notes.
Building The building as described in the Preliminary Plans
and Specifications (including footings and
foundations ) and other improvements and
appurtenances of every kind and description
hereafter erected, constructed, or placed upon the
land, and any and all alterations and replacements
thereof, additions thereto and substitutions
therefor and
4
<PAGE>
any and all fixtures, equipment, machinery and
personal property of every kind and nature affixed
or attached to, or used or procured in connection
with the operation, use or occupancy of, the
Building, but excluding furniture, trade fixtures
or articles of personal property installed leaf by
or for Tenant or by or for other tenants in the
Building.
Building Systems As defined in Section 7.2C.
Business Days Means all days, other than Saturday and Sunday and
official holidays of The City of New York.
City of New York Benefits As described in Section 2.0 and in Exhibit I
hereto.
Cleaning Specifications As set forth in Exhibit H annexed hereto and made
a part hereof.
Commencement Date As defined in Section 3.1B(ii).
Commencement of Construction Shall mean the date on which all of the following
requirements have been met: (A) the building
permit or permits required for landlord to
commence construction of the building have been
issued, (B) a binding commitment have been issued
for steel or equivalent structural material and a
copy thereof delivered to tenant, and (C) Landlord
has commenced demolition and excavation work on
the land.
Common Areas As defined in Section 4.1.
5
<PAGE>
Common Elements As defined in the Condominium Documents
Completion Date As defined in Section 2.2D.
Concession Period As defined in Section 3.1B(i).
Condominium That certain condominium consisting of the several
leasehold interests held by Landlord, Hotel LLC
and all other owners of Units from time to time in
and to the Land and the Building, which
condominium is constituted pursuant to the
Condominium Documents.
Condominium Documents That certain Declaration of Easements made by MWR
of even date herewith and intended to be recorded
in the Office of the City Register, New York
County, immediately following the date hereof, and
any other or further documents required to
constitute the Condominium pursuant to the New
York Real Property Law Article 9-B, as all of the
foregoing may hereafter be constituted or amended.
Construction Commencement
Date As defined in Section 2.1A.
Date Certain Agreement As defined in Section 2.2A.
Dispute Notice Notice of a party pursuant to Section 15.2A.
Empire Notes Those certain New York City Industrial Development
Agency 8.80% Taxable Industrial Development
Revenue Bonds (1996 Empire Insurance Company
Office Unit Project) due 2018 of even date
herewith, issued by New York City Industrial
6
<PAGE>
Development Agency and payable to the registered
holders thereof in the original principal amount
of $53,433,000, with a scheduled maturity equal to
the Term hereof, including any additions,
extensions, modifications, restatements,
assignments, amendments or the like of all or any
portion of such indebtedness, but excluding any
refinancing of such indebtedness which increases
the principal amount thereof above the
then-current principal amount or extends the
maturity thereof beyond the original scheduled
maturity date.
Floor Plan As set forth on Exhibit B annexed hereto and made
a part hereof.
Floor Space The space within the exterior faces of the walls
encompassing any premises within the Building or,
if such premises is enclosed by a wall or
partition between space available for occupancy
for two or more separate tenants or occupants, the
space within such exterior faces and the center of
such wall or partition. in computing floor space,
space located below the Adams street parking level
garage - as shown on the Preliminary plans and
Specifications (excepting, however, the lower
Hotel Portion lobby on Adams Street, the office
portion lobby, and the Garage Portion) shall be
excluded. In computing the
7
<PAGE>
Floor Space of a full floor, no deduction or
exclusion shall be made from Floor Space otherwise
computed by reason of Common Areas, including,
without limitation, stairs, elevators, escalators,
mechanical space, interior construction or
equipment. Floor Space of areas common to both the
Office Portion and the Hotel Portion shall be
allocated, based on the Prel1minary Plans and
Specifications, 63.445% to the Office Portion and
36.555% to the Hotel Portion, which allocation may
be adjusted upon substantial completion of the
Building on the basis of as-built plans and
specifications indicating the respective Floor
Space of the respective portions of the Building.
Floor Space for the Office Portion only, as
otherwise computed in accordance with this
definition, shall also include a sixteen and
one-half (16.5) percent add-on factor to reflect
an agreed-upon allocation of the Office Portion
lobby and mechanical space (Exclusive of
mechanical space located on floors leased to
tenants). The parties agree that floor space for
each of the floors included in the premises shall
be deemed to be 33,285 square feet for floors 23
through 26 inclusive, 32,170 square feet for
floors 27 through 29 inclusive, 30,020 square feet
for the 30th floor and 26,840 for the 31st floor,
8
<PAGE>
provided the Premises are built in accordance with
the Preliminary Plans and Specifications. If the
Premises are not built in accordance with the
Preliminary Plans and Specifications, the Premises
shall be remeasured and recomputed, provided, that
in no event shall the Floor Space of floors 23
through 31 of the Premises exceed 286,510 square
feet. Floor Space for the Garage Portion only
shall be calculated as the product obtained by
multiplying (x) the "floor Space for the Garage
Portion only, as otherwise computed in accordance
with this definition, by (y) 25%.
Garage Portion The Garage Unit (as defined in the Condominium
Documents), as more particularly described in the
Preliminary Plans and Specifications.
General Common Elements As defined in the Condominium Documents.
Governmental Authority The United States of America, the state of New
York, New York City and any agency, department,
commission, board, bureau, instrumentality or
political subdivision of any of the foregoing, now
existing or hereafter created, acting solely in
its governmental capacity, and having jurisdiction
over the premises or any portion thereof or any
street, road, avenue or sidewalk comprising a part
9
<PAGE>
of, or in front of, the Premises, or any vault in
or under the Premises.
Governmental Requirements Any law, ordinance, code, order, rule or
regulation of any Governmental Authority.
Gross Leasable Area of the Shall mean the Floor Space of the Office Portion.
Office Portion As of the date hereof, the Gross Leasable Area of
the Office Portion shall be deemed to be 8099,280
square feet. If the Office Portion is not built in
accordance with the Preliminary Plans and
Specifications, Gross Leasable Area of the Office
Portion shall be remeasured and recomputed. Gross
Leasable Area of the Office Portion may be
adjusted from time to time, in accordance with the
terms and provisions of this Lease.
Ground Lease That certain Severed, Amended and Restated
Agreement of Lease (Office Unit 2) between The
City of New York And Brooklyn Renaissance Plaza
LLC (as assignee of MWR), as the same may be
amended from time to time.
Ground Lessee The lessee from time to time under the Ground
Lease.
Ground Lessor The lessor from time to time under the Ground
Lease.
Hotel LLC Brooklyn Renaissance Hotel LLC, a New York limited
liability company.
10
<PAGE>
Hotel Portion The Hotel Unit (as defined in the Condominium
Documents), as more particularly described in the
Preliminary Plans and Specifications.
Institutional Lender Any entity qualifying as an Institutional Lender
pursuant to the first sentence of the definition
of that term set forth in the Ground Lease.
Land The land described in Exhibit C annexed hereto and
made a part hereof.
Late Rate As defined in Section 3.4.
Lease This Agreement of Lease and all exhibits hereto
and all amendments, modifications and supplements
hereof.
Lease Year The twelve (12) month period beginning on the
commencement date and each succeeding twelve (12)
month period during the term.
Limited Common Elements As defined in the Condominium Documents.
Mortgage Any mortgage now or hereafter secured by (i) any
interest in the ground lease, and/or (ii)
landlord's interest under the lease and/or the
sandwich lease, and/or (iii) sublandlord's
interest under the lease or the sandwich lease,
and all renewals, replacements, amendments,
modifications, consolidations and extensions
thereof.
11
<PAGE>
Mortgagee The holder of a Mortgage and any other party for
the benefit of which a Mortgage is held including,
without limitation, the Indenture Trustee of
the Empire Notes.
MWR MWR Associates, L.P., a New York limited
partnership
Non-Arbitrable Dispute As defined in Section 15.2A.
Non-Privileged Alterations As defined in Section 7.2C.
Nuisance As defined in Section 7.2H.
Office Portion Collectively, Office Unit 1, Office Unit 2 and the
Office/Retail Unit (each as described in the
Condominium Documents) each as more particularly
described in the Preliminary Plans and
Specifications.
Office Portion Allocable As defined in Section 3.3A(vi).
Operating Expenses
Office Portion Operating As defined in Section 3.3A (iii).
Expenses
Office Unit 2 As defined in the Condominium Documents
Person A natural person, firm, partnership, limited
liabi1ity company, association or corporation,
as the case may be.
PILOT As defined in section 3.4 Of the ground lease.
Possession Rent As defined in Section 3.1B (i).
Preliminary Plans and As set forth in exhibit D annexed hereto and made
Specifications a
12
<PAGE>
part hereof.
Premises The twenty-third (23rd) through thirty-first
(31st) floors, inclusive, of the Office Portion,
each as shown on Exhibit B (inclusive of Common
Areas located within the Premises).
Prime Rare The prime lending rate charged from time to time
by The Chase Manhattan Bank, N.A. or its
successor.
Privileged Alterations As defined in Section 7.2C.
Prior Landlord As defined in Section 13.2A(1).
Purchaser As defined in Section 13.2A.
Renewal Period As defined in Section lO.lA.
Rent Base Annual Rent and all additional rent and
charges payable by Tenant pursuant to this Lease,
whether denominated as Possession Rent, Services
Rent or otherwise.
Rules and Regulations The rules and regulations set forth in Exhibit E
annexed hereto and made part hereof, as same may
be modified by Landlord from time to time.
Sandwich Lease As defined in the recitals hereto.
Services Rent As defined in section 3.1B(i).
Size of the Premises 286,510 square feet.
13
<PAGE>
Standard Building As set forth on Exhibit F annexed hereto and made
Hours and Days a part hereof.
Substantial Completion As defined in Sections 2.2B and C.
Substantial Completion As defined in Section 2.2B.
Deadlines
Substantial Completion As defined in Section 2.2D.
Notice
Taxes As defined in Section 3.3A(i).
Tax Year As defined in Section 3.3A(ii).
Tenant Unless otherwise specified, includes any person
holding under Tenant.
Tenant's Architect The New York State - licensed architect to be
engaged -by Tenant in connection with the design
and implementation of Tenant's Work Plan.
Tenant's Extra Work As defined in Section 2.lB.
Tenant's Improvement Fund As defined in Section 2.0.
Tenant's Plan As defined in Section 2.l.
Tenant's Pro-Rata Share As defined in section 3.3A(iv).
Tenant's Tax Reimbursement As defined in section 3.3B(i).
Tenant's Rejection Notice As defined in Section 2.2D
Tenant's Work Allowance As defined in Section 2.1(H)
Tentative Monthly As defined in section 3.3c(i)(b).
Operating Expense Charge
Term As defined in the demising clause of this Lease.
14
<PAGE>
Title Matters The exceptions set forth in Exhibit G annexed
hereto and made a Part hereof.
Unavoidable Delays As defined in Section 14.9.
Underlying Lease(s) Any ground or underlying lease (including
without limitation the Ground Lease) that now
exists or may hereafter be placed on Office Unit 2
or any part thereof and any renewals, amendments,
and/or modifications thereof.
Unit As defined in the Condominium Documents
ARTICLE 2
ARTICLE 2
LANDLORD'S wORK - TENANT'S PLAN - CONSTRUCTION
----------------------------------------------
Section, 2.0 Tenant's Improvement Fund.
-------------------------
A. NOT LATER THAN THIRTY (30) DAYS AFTER THE DATE OF execution of this
Lease by all parties, Landlord shall establish an interest-bearing escrow
account AT A BANK OR OTHER FINANCIAL institution approved by Tenant.
B. Landlord shall cause to be DEPOSITED IN SAID ESCROW account
(which account and the contents thereof are hereinafter
15
<PAGE>
referred to as "Tenant's Improvement Fund") an amount equal to the sum of vi)
the mortgage recording taxes payable on the mortgages executed and delivered
simultaneously with the closing hereof (the "Project Mortgages"), but which will
be exempt from payment by reason of the Project Mortgages being recorded by the
New York City Industrial Development Agency (the "Agency") (the "MRT Benefits")
and which have been received by Landlord or Sublandlord in any capacity and (ii)
those amounts paid by or on behalf of Landlord to the New York City Economic
Development Corporation ("NYCEDC") pursuant to a Sales and Compensating Use Tax
Agreement among The City of New York, MWR Associates, L.P., Landlord and Tenant
dated as of June 27, 1996 (the "Sales Tax Agreement") to the extent such
amounts are available to Tenant under that agreement, all as further described
in Exhibit I hereto (COLLECTIVELY, THE "CITY OF New York Benefits"). Landlord
shall cooperate fully with Tenant in obtaining the City of New York Benefits at
no additional cost or expense to Landlord.
C. In addition to the funding described in subparagraph B above,
landlord shall cause the Tenant's work allowance (hereinafter defined) portion
of Tenant's improvement fund to be funded on a progress basis as and in the
manner prescribed in Section 2.1E. LANDLORD SHALL CAUSE THE PROCEEDS OF TENANT'S
Improvement Fund, and the interest on the principal thereof (at a rate
equivalent to that on short-term U.S. TREASURY OBLIGATIONS), to be applied to
the payment of the costs of Tenant's Work Plan
16
<PAGE>
pursuant to Section 2.1(E) as and in the manner provided therein, and shall
otherwise disburse any balance of Tenant's Improvement Fund as further provided
in said Section.
Section 2.1 Tenant's Work Plan.
------------------
A. Landlord shall notify Tenant in writing of Commencement of
Construction within five () Business Days thereof, and the date of such notice
shall be deemed the "Construction Commencement Date". No later than October 15,
1997, Tenant shall cause to be prepared and completed and submitted to Landlord
at Tenant's sole cost and expense detailed drawings, plans and specifications
prepared by a New York State licensed architect or engineer of Tenant's choice
(Herein collectively referred to as "tenant's work plan") setting forth, without
limitation, the layouts of partitions (including openings), reflected ceilings,
lights, mechanical plans and specifications for installation of air conditioning
system and duct work, heating, electrical, sprinkler, communications and
computer networking and such other layouts and systems as may be necessary to
complete the premises for occupancy in accordance with tenant's requirements.
Tenant's work plan shall be fully detailed, shall show complete dimensions,
shall not be in conflict with the preliminary plans and specifications, the base
Building, shall not require any changes in the structure of the Building, shall
Not be in violation of any governmental requirements, shall not require landlord
to take any action that would constitute a
17
<PAGE>
default under this Lease, any Mortgage, or Underlying Lease, or affect any
portion of the Building other than the Premises. Notwithstanding the foregoing,
Tenant agrees to advise Landlord of any non-standard structural requirements of
Tenant's Work Plan within a reasonable time from the date hereof. Further
notwithstanding the foregoing, if Tenant sha21 decide to construct employee
cafeteria within the Premises, Tenant shall so notify Landlord and shall
furnish Landlord with proposed plans and specifications for same as a part of
Tenant's Work Plan. In the event that the inclusion of Tenant's cafeteria or of
other nonstandard structural requirements of Tenant's Work Plan shall cause a
modification in the Base Building (which Tenant shall use best efforts to
avoid), Tenant shall reimburse Landlord for all of Landlord's actual costs and
expenses in connection WITH SUCH modification and with any construction delay
occasioned solely thereby within thirty (30) days of receipt of Landlord's
Detailed statement thereof.
B. Within five (5) business days after submission to landlord of
tenant's work plan, landlord shall either approve same, which approval landlord
agrees shall not be unreasonably withheld, or shall set forth in writing the
particulars in which landlord does not approve same in which latter case tenant
shall, within fifteen (15) business days after landlord's notification, return
to landlord appropriate corrections thereto. Such corrections shall be
consistent with the requirements of section 2.1(A) above, and
18
<PAGE>
subject to Landlord's reasonable approval. The foregoing process shall repeat
itself until Tenant's Plan has been approved by Landlord, as set forth above,
and Tenant shall not commence the improvements contained in Tenant's Work Plan
until such approval shall have been given.
C. In respect of all work performed by Tenant under this Section 2.l,
(i) neither Tenant, nor its agents or employees shall interfere with work being
done by the Landlord or its agents and employees in any part of the Building or
the Premises, (ii) neither Tenant nor its agents or employees shall cause a
disruption in the labor harmony of the Building or the Premises, (iii) Tenant
shall comply with any reasonable work schedule, rules and regulations proposed
by Landlord, its agents or employees, (iv) subject to Landlord's procuring
wraparound insurance for the Building, in which case Tenant shall participate
Therein on mutually agreeable terms, tenant shall procure and deliver to
landlord worker's compensation insurance in statutory limits, (v) tenant shall
indemnify, defend and hold landlord and sublandlord harmless (including
reasonable attorneys fees and expenses) from and against any and all claims,
actions, judgments, liabilities and expenses arising from or in connection with
any act or omission of tenant or its agents, contractors, invitees or employees,
(vi) tenant shall comply with all governmental requirements, and (vii) all the
terms, provisions and agreements of this lease shall apply to said occupancy
(including the payment of Possession Rent when
19
<PAGE>
due), except for the obligation to pay Services Rent.
D. In the event that prior to the Commencement Date the Preliminary
Plan and Specifications are modified by Landlord so as to alter the Size of the
Premises or the Floor Space of the Building (or any portion thereof), then the
Premises and the Building (or any portion thereof), as the case may be, shall be
remeasured by Landlord to reflect such change and Rent shall be adjusted
accordingly; provided, however, that so long as all or a portion of the Empire
Notes shall remain outstanding, any reduction in rent which may result shall be
applied only, in the full aggregate amount of such rent reduction, against the
services rent payable hereunder (but not against possession rent), and the
amount and timing of the periodic payments of possession rent shall remain
unchanged notwithstanding a reduction in rent. However, notwithstanding any such
remeasurement, the dollar amount of tenant's work allowance to be provided to
tenant shall be computed using the greater of 256,510 square feet or the
remeasured square footage. Tenant shall have the right to verify for itself any
such remeasurement by the Landlord. In the event of a dispute in connection with
such remeasurement, same shall be determined by expedited dispute resolution in
accordance with section 15.2 Hereof, it being understood that pending resolution
of such dispute all payments of rent shall be paid by tenant as billed by
landlord, subject to reimbursement or credit after such determination.
20
<PAGE>
E. Tenant shall receive the benefit of a cash contribution ("tenant's
work allowance") to be paid into tenant's improvement fund (on a progress basis,
as provided below) in an amount equal to the product of (i) 330.00 And (ii)
286,510 or such greater (but not lesser) remeasured square footage as may result
from a modification of the preliminary plans and specifications pursuant to
section 2.1C. Tenant may elect to have the benefit of the total of tenant's
improvement fund applied to the improvement of as few as 197,480 square feet
of the premises (floors 23 through 28). Landlord shall make disbursements from
tenant's improvement fund in accordance with the provisions of this article 2
(i) to tenant's general contractor in respect of construction matters and (ii)
to tenant's architect in respect of other miscellaneous matters (not more than
once per month) on a progress basis and within ten (10) days of tenant's
presentation of its contractors' requisition(s) to landlord's managing agent
(with the certification, except in the case of advances or deposits, of tenant's
architect that the requisitioned work is complete) in the face amount of such
requisitions, until the principal and interest of tenant's improvement fund
shall have been exhausted. Tenant shall give landlord written notice not later
than thirty (30) days prior to the submission of tenant's first requisition,
which notice shall set forth the estimated total dollar amount of such first
requisition. Upon the presentation of each requisition of tenant's contractor(s)
to landlord, and not more than three (3) days following landlord's receipt
thereof, landlord shall deposit, on
21
<PAGE>
account of Tenant's Work Allowance, a sum equal to one-half (l/2) of the face
amount of such requisition into Tenant's Improvement Fund and shall deduct said
amount from the balance of Tenant Work Allowance. Each requisition of Tenant's
contractor shall be paid one-half (1/2) from Tenants Work Allowance, as
provided in the preceding sentence, and one-half (1/2) from The City of New York
Benefits portion of Tenant's Improvement Fund. To the extent that, with respect
to a given requisition, the City of New York Benefits portion of tenant's
improvement fund may contain less than one-half (1/2) of the amount of such
requisition, landlord shall pay the balance of such requisition from tenant's
work allowance, but in no event shall landlord's obligation in respect of
tenant's work allowance exceed the product of $30.00 X 286,150 or greater
remeasured square footage. In the event that there shall be a balance remaining
in tenant's improvement fund and/or in respect of tenant's work allowance after
tenant's architect shall have given notice to landlord that the improvements
described in tenant's work plan are completed, landlord, at tenant's election,
shall (i) pay the balance of tenant's improvement fund and/or tenant's work
allowance as tenant shall direct in writing, or (ii) apply the same as -a credit
against services- rent (but not against possession rent). In the event that the
cost of the improvements described in tenant's work plan shall exceed the sum of
(i) tenant's work allowance and (ii) the City of New York benefits available in
tenant's Improvement Fund, then tenant shall pay such excess amount to tenant's
contractors.
22
<PAGE>
F. Tenant shall be responsible (subject in all events to the terms of
this Lease) for filing all building alteration applications and plans (which all
shall be in compliance with Governmental Requirements), handling the paper work
associated with such filings, and obtaining all permits, approvals and
certificates required by any governmental or quasi-governmental bodies and
regulatory agencies having jurisdiction thereof with respect to Tenant's Work
Plan, provided, however, that Landlord shall not unreasonably withhold or delay
its execution of any such application, permit or filing requiring its
signature(s). Tenant shall have the option of employing the services of
Landlord's expeditor at Tenant's expense.
G. All installations, alterations, additions, improvements, fixtures
and other property which are now or at any time hereafter attached to the
Premises or any part thereof (whether or not made, installed or paid for by or
for the benefit of landlord or tenant) including, but not limited to, all pipes,
ducts, conduits, wiring, paneling, sheetrock partitions (and built-in
inclusions), railings and the like, hall be, and remain the property of
landlord or ground lessor and shall remain upon and be surrendered with the
premises as a part thereof at the expiration or sooner termination of the term.
None of the foregoing shall be deemed to include any of tenant's furniture,
personal property or trade fixtures which shall remain the property of tenant;
provided, however, that tenant, at tenant's sole cost and expense, shall remove
same from
23
<PAGE>
the Premises prior to the expiration or sooner termination of the Term and shall
repair any damage to the Premises caused by such removal.
Section 2.2 Construction
------------
A. Landlord shall enter into a construction contract that requires
that Substantial Completion 'as hereinafter defined) of the Premises be achieved
on or before the dates of Substantial Completion Deadlines I, II and III (as
defined in subparagraph (B) inclusive. Landlord shall achieve Substantial
Completion of and deliver to Tenant the entire Premises (or applicable portion
thereof) and the Completion Date (as hereinafter defined) shall occur, not later
- -than the date of the applicable Substantial Completion Deadline. Unavoidable
Delay, as defined in Section 14.9, shall not excuse Landlord's failure to meet
any Substantial CompletioN deadline. Landlord shall construct the building
pursuant to- building permits or partial building permits or equivalent, copies
of which shall be provided to tenant prior to commencement of construction.
Tenant shall have, as its exclusive remedies in the event that substantial
completion of the premises shall not have been achieved and the completion date
shall not have occurred on or before the applicable substantial completion
deadlines, such remedies as are set forth hereinafter and in the date certain
agreement between landlord and tenant of even date herewith (the "date certain
agreement"). In no event shall such
24
<PAGE>
failure to achieve Substantial Completion as to all or any portion of the
Premises by any Substantial Completion Deadline affect Tenants obligation to
pay Possession Rent and or Bond Support Payments (both as hereinafter defined)
commencing on the Commencement Date and for the remainder of the Term.
B. There shall be three (3) Substantial Completion Deadlines
("Substantial Completion Deadline I", "Substantial Completion Deadline II" and
Substantial Completion Deadline III) as set forth below, and Substantial
Completion shall be defined separately as to each Substantial Completion
Deadline further as set forth below.
(1) Substantial Completion Deadline I shall be February 11, 1998.
Substantial completion for purposes of substantial completion deadline
I means that all of the following base building elements and other
conditions shall have been completed and met with respect to each of
tenant's first six floors, floors twenty-three (23) through
twenty-eight (28) inclusive ("initial floors"): the slab of each
initial floor and of the floor above poured and cured with shoring and
bracing (except shoring and bracing underneath floor 23) removed;
access by hoist or elevator sufficient to permit the orderly flow of
personnel and materials provided and caused to be made available for
tenant's use on a
25
<PAGE>
reasonable and nondiscriminatory basis with the other contractors in
the Building; temporary utilities (electricity and water, sufficient
to permit the orderly performance of Tenant's improvements) made
available, the use of which shall be at Tenant's expense; exterior
building enclosure (exclusive of standard "leave outs" or "comeback
areas" for exterior hoist and tower cranes) with installation of
curtainwall and interior core walls ready to receive finish. The
foregoing conditions will be met with respect to floors 29, 30 and 31
("Tenants Non-Occupancy Floors") not later than February 18, 25 and
March 4 1998, respectively.
(2) Substantial Completion Deadline II shall be April 11, 1998. Substantial
Completion for purposes of substantial completion deadline ii means
that the following conditions shall have been substantially completed
and met with respect to each of the initial floors: column enclosures,
perimeter piping complete with enclosure", sprinkler loop, core
partitions, electric and telephone closets, mechanical room including
equipment and ducted to core- wall, all vertical and horizontal
stacks, piping, and electric substantially completed.
26
<PAGE>
During the 60-day period between Substantial Completion Deadlines I
and II, Landlord's access to the Initial Floors shall remain unimpeded
for the purposes of performing Substantial Completion Deadline II
work. The foregoing conditions shall have been met with respect to
Tenant's Non-Occupancy Floors not later than April 18, 25 and May 2,
1998 respectively.
(3) Substantial Completion Deadline III shall be September 11, 1998.
Substantial Completion for purposes of Substantial Completion Deadline
III means that, with respect to all of Tenant's floors, floors
twenty-three (23) through thirty-one (31) inclusive, all of the Base
Building requirements shall have been substantially completed
including, without limitation, lobby, life-safety systems, permanent
high-rise elevators serving the premises, partial balancing of the
building HVAC systems and other Building-wide systems necessary to
obtain a temporary certificate of occupancy for those areas of the
building so that tenant may lawfully occupy the premises.
Tenant shall coordinate, or cause its contractor and
subcontractors to coordinate, the performance of the improvements
27
<PAGE>
Described in tenant's work plan with the base building work being performed by
or on behalf of landlord so as not to interfere with the performance and timely
completion of the base building for the premises and/or the building. Tenant
agrees to permit Morse Diesel International, Inc., In addition to such other
general contractors as tenant may select, to submit bids or proposals for the
performance of tenant's work plan, provided, however, that tenant shall not be
required to accept the lowest bid submitted, and tenant may negotiate and
contract with the bidder of tenant's choosing. Landlord shall coordinate, or
cause its general contractor responsible for the base building and any other of
its contractors and their subcontractors to coordinate, the performance of the
base building work being performed on behalf of landlord with the work being
performed by tenant pursuant to tenant's work plan so as not to interfere with
the latter's timely and orderly completion. Landlord shall have the right to
approve the selection of tenant's general contractor, which approval landlord
agrees not to unreasonably withhold or delay. Tenant agrees to cause its
contract with the general contractor responsible for the performance of the
improvements described in tenant's work plan to include a provision
requiring said general contractor to consult with landlord and to take such
commercially reasonable steps as landlord, or landlord's general contractor, may
determine, and tenant's general contractor shall have agreed, are desirable in
order to accelerate the performance of tenants work plan ("mitigating work") for
the purpose of mitigating any amounts
28
<PAGE>
likely to become payable to Tenant as liquidated damages under this Lease and
the Date Certain Agreement, provided however that any such Mitigating Work shall
be undertaken at the sole cost and expense of MWR Associates or another entity
beneficially owned or controlled by Joshua L. Muss.
For purposes of this lease, the date certain agreement and
the construction contract with the general contractor responsible for the base
building (which contract landlord shall cause to incorporate, in general
substance, the provisions of this section 2.2(B)), landlord shall pay, or cause
to be paid, to tenant, with respect to tenant's initial floors, as liquidated
damages and not as a penalty, the sum of eight thousand six hundred sixty-four
($8,664.00) Dollars for each day for which substantial completion deadline I, or
substantial completion deadline II, inclusive, shall not have been met by
landlord, its general contractor and/or subcontractors. Notwithstanding the
foregoing, and provided that landlord shall have otherwise met substantial
completion deadline I or substantial completion deadline II, as the case may be,
and shall have delivered not less than five (5) of tenant's initial floors
pursuant thereto, then, with respect to the one (1) tenant's initial floor
remaining, landlord shall pay to tenant, as liquidated damages and not as a
penalty, the sum of one thousand four hundred forty four ($1,444.00) Dollars
(rather than the $8,664.00 Set forth above) for each day for which substantial
completion deadline I or II, as the case may be, is not met with
29
<PAGE>
respect to said one (1) floor. All payments due, if any, with respect to
Landlord's failure to meet a Substantial Completion Deadlines I and II shall
cease to accrue as of the date of the next Substantial Completion Deadline to
occur. For each day up to and including the sixtieth (60th) day for which
Substantial Completion Deadline III shall not have been met, Landlord shall pay
to Tenant, as liquidated damages and not as a penalty, the sum of Six THOUSAND
Five Hundred ($6,500) Dollar , and for each day after the sixtieth (60th) day
for which Substantial Completion Deadline III shall not have been met, Landlord
shal pay to Tenant, as liquidated damages and not as a penalty, the sum of
Fourteen Thousand Ninety-Seven ($14,097) Dollars. Tenant's receipt or
non-receipt of any of the payments described in this subparagraph shall not
affect Tenant's obligation timely- to make Bond Support Payments or payments of
Possession Rent as required under this Lease.
C. Landlord acknowledges that its failure to achieve
substantial completion within the applicable substantial completion deadline
will result in extreme hardship to tenant and will irreparably interfere with
tenant's business, and the parties agree that it would be extremely difficult
and impracticable to ascertain and fix the actual damages which tenant would
incur as a result of landlord's delay in achieving substantial completion as
required above. Landlord and tenant acknowledge their intent that tenant shall
be compensated for any bond support payments which tenant may be required to
make under this lease. Accordingly, the damages for
30
<PAGE>
such delay, and only for such delay, are liquidated and agreed to in the amounts
set forth in subparagraph B above. Any amounts required to be paid to Tenant
pursuant to subparagraph B above shall be paid to Tenant without offset or
counterclaim not later than the fifteenth (15th) day of each month for which
Tenant shall be obligated to pay Bond Support Payment pursuant to this Lease.
If, following the Completion Date (hereinafter defined), Tenant shall have
received total payments pursuant to ;his Lease and the Date Certain Agreement in
excess of the total amount of any Bond Support Payments (hereinafter defined)
which Tenant shall have paid or become obligated to pay, Tenant shall refund
any such excess amount to Landlord not later than thirty (30) days after the
date on which Landlord shall make demand therefor.
D. Upon achieving Substantial Completion of the Premises, with respect
to each of Substantial Deadlines I, II and III) respectively, Landlord shall
deliver to Tenant written notice to that effect (the "Substantial Completion
Notice"), and tenant shall respond by giving landlord either a notice accepting
substantial completion of the premises pursuant to the applicable substantial
completion deadline or a tenants rejection notice, described below, within five
(5) business days of receipt of landlord's substantial completion notice,
failing which tenant shall be deemed to have accepted substantial completion.
Tenants rejection notice shall be prepared by tenant's architect and shall
include a detailed list of reasons that substantial completion has not been
31
<PAGE>
achieved, and Landlord shall correct the deficiencies described in Tenants
Rejection Notice and thereafter shall issue a new Substantial Completion notice
to which Tenant shall have three (,) Business Days to respond otherwise as
provided above. The foregoing procedure shall be repeated until the date on
which Tenant shall accept, or shall have been deemed to accept, as provided
above, Substantial Completion, which date shall be the "Completion Date",
provided, however, that the Completion Date for purposes of the initial Tenant's
Operating Expense Payment pursuant to Sect_on 3.3.(C) shall be the earlier of
the date of Tenant's acceptance or date of deemed acceptance of Substantial
Completion as defined in Section 2.2(B)(3) with respect to Substantial
Completion Deadline III.
E. At any time prior to Tenant's acceptance pursuant to any
Substantial completion deadline pursuant to section 2.2(D), landlord or tenant
may, by written notice to the other, in good faith cause -any genuine issue in
respect of (i) substantial completion by landlord or (ii) tenants failure to
comply with tenant's obligations under this article 2 or tenant's or its general
contractor's direct interference with the ability of landlord or its general
contractor to fulfil landlord's obligations under this article 2, to be
submitted to non-binding compulsory mediation with jam-endispute or with any
reputable private dispute resolution service consisting of former judicial
officers (or such other person or persons as the parties may mutually select).
The
32
<PAGE>
mediation will commence with 72 hours of either party's notice, or as soon
thereafter as can be arranged, and costs will be shared equally by both parties
Neither the statements of the parties nor the findings of the mediator shall be
utilized or communicated, and the mediation shall be without prejudice to either
party, in any subsequent proceed1ng. Should the mediation fail to result in an
agreement to the contrary between the parties, all payments due to Tenant
pursuant to Sect on 2.2(B) hereof AND THE DATE CERTAIN Agreement shall be made
without set off or counterclaim and within the time period specified. in Section
2.2(C), but without prejudice to either party's right to contest such matters at
a later date. Thereafter, if Landlord shall dispute such payments, Landlord may
submit such dispute to arbitration pursuant to Section 15.1.
F. Tenant shall have the option, in its sole discretion, to occupy the
premises for business use on a floor by floor basis as the same shall be
completed and ready for occupancy, in which event the completion date shall be
separately determined for each such floor in all other respects pursuant to the
provisions of this section 2.2.
G. Tenant has been advised of the importance to landlord of completing
the building and the premises as quickly as possible and the great financial
loss to landlord resulting from a delay in such completion. Accordingly, tenant
(as tenant under this lease) covenants and agrees that tenant will not interfere
with landlord's
33
<PAGE>
access to the Premises nor obstruct Landlord's contractors so as to cause any
significant delays for Landlord in completing Landlord's Work.
H. Notwithstanding anything contained in the foregoing to the
contrary, if Tenant shall occupy the Premises, or any portion thereof, prior to
the certification or deemed certification of Substantial Completion as provided
in subparagraph D above, then the Completion Date shall be the day Tenant or
anyone claiming under or through Tenant first occupies the Premises or any
portion thereof (but only with respect to said portion) for business.
Section 2.3 Building Under Construction
---------------------------
A. The parties hereby acknowledge and agree that the Premises are a
Part of a building which is to be constructed by or on behalf of landlord
substantially in accordance with the preliminary plans and specifications and
that such building is comprised of the hotel portion, the office portion and the
garage portion, each of which is shown on the preliminary plans and
specifications, it being understood that any such portion may be subdivided
further by or on behalf of landlord into one or more leasehold condominium units
in connection with the submission by landlord of the building to a condominium
regime. Tenant hereby acknowledges and agrees that the preliminary plans and
specifications shall be subject to such changes as landlord in its
34
<PAGE>
sole discretion shall determine are necessary or desirable. In no event,
however, shall any such change: (i) cause the Office Portion to violate any
Governmental Requirements; or (ii) materially alter the Size of the Premises;
(iii) eliminate the Hotel Portion or reduce the number of rooms below 200 rooms
or the public spaces of the Hotel Portion as currently shown on the Preliminary
Plans and Specifications; or (iv) cause the loss of PLOT, New York State or
City funding agreements, or other public benefits as may be committed to the
Building. Any such impermissible change shall be deemed a material anticipatory
breach of this Lease by Landlord, but shall in no event affect the obligations
of Tenant to pay Bond Support Payments or Possession Rent to Sublandlord.
Section 2.4 Section 223(a) of real property law. Tenant waives
--------------------------------------
any right to rescind this lease under section 223(a) of the real property law of
the state of New York, and, except as otherwise provided in the date certain
agreement, further waives any damages which may result from any delay in the
substantial completion of tenant's work or delivery of possession of the
premises.
35
<PAGE>
ARTICLE 3
RENT
Section 3.1 Payment.
-------
A. Tenant hereby agrees to pay all Rent in lawful money of the United
States which shall be legal tender in payment of all debts and dues, public and
private, at the time of payment, at the address of Landlord and Sublandlord set
forth in this Lease or at such other place a_ Landlord (with respect to Services
Rent) or Sublandlord (with respect to Possession Rent) in writing may designate,
without abatement, offset, counterclaim or defense whatsoever (except as may be
otherwise herein expressly provided with respect to Services Rent but in no
event against Possession Rent or, if the Empire Notes shall no longer be
outstanding, Rent), and without any prior demand therefor.
B. (i) "possession rent" as used herein shall mean, collectively, (a)
the base annual rent, (b) tenant's tax reimbursement and (c) a portion of
tenant's operating expense payment in an amount equal to the "base rent" payable
under the ground lease, together with any late charges due upon any of the
foregoing pursuant to section 3.4; Provided that notwithstanding anything to the
contrary contained in this lease, any possession rent accruing in respect of the
premises (or any portion thereof) from and after the commencement date until two
months following the
36
<PAGE>
Completion Date of the Premises (or any portion thereof) shall be referred to
herein as "Bond Support Payments". Said two month period following the
Completion Date shall be referred to herein as the "Concession Period".
"Services Rent" as used herein shall mean any and all Rent payable under the
Lease other than Possession Rent and Bond Support Payments.
(ii) Notwithstanding any provisions of this Lease or of
applicable law to the contrary, Tenant shall commence making payments to
Sublandlord of Possession Rent or Bond Support Payments, as the case may be,
with and for the month beginning on November 1, 1998 (the "Commencement Date"),
without abatement, offset, counterclaim or defense. Tenant's obligation to pay
Possession Rent or Bond Support Payments, as the case may be, to Sublandlord
from and after the Commencement Date AND FOR THE remainder of the Term shall be
Absolute and unconditional, whether or not the completion date with respect to
all or any portion of the premises or any individual office floor shall have
theretofore occurred. If the completion date with respect to the premises or any
portion thereof shall have failed to occur in accordance with section 2.2 Of the
lease on or before the commencement date, then Tenant's obligation to make
payments of possession rent or bond support payments, as the case may be, shall
nevertheless commence and continue without abatement, deduction, offset,
counterclaim or defense.
37
<PAGE>
c. Sublandlord hereby covenants and agrees, during the term of
the Empire Notes, to cause any Possession Rent and Bond Support Payment received
by Sublandlord to be delivered to the Bond Trustee to be applied to the payment
of the Empire Notes, Taxes and the "Base Rent" payable under the Ground Lease.
Section 3.2 Base Annual Rent. Tenant shall pay the Base Annual Rent in
----------------
equal monthly installments on or before the last business day of each calendar
month during the Term, in accordance with Section 3.1A. So long as all or a
portion of the Empire Notes shall be outstanding, such payments shall be made by
Tenant to Sublandlord without any abatement, offset, counterclaim or defense
whatsoever; following the payment in full of the Empire Notes, such payments
shall be without abatement, offset, counterclaim or defense except as may be
otherwise expressly provided herein.
Section 3.3 Adjustment to Base Annual Rent.
------------------------------
A. Definitions:
(i) "Taxes" shall mean the aggregate amount of real estate taxes
and assessments (exclusive of penalties, interest and discount thereon) imposed
upon office unit 2 and payable during any tax year, including, without
limitation, any special assessments levied on office unit 2 after the date of
this lease for public benefits to land or building which assessments, if
building which assessments, if
38
<PAGE>
payable in installments, shall be deemed payable in the maximum number of
permissible installments (Tenant's responsibility with respect thereto being
limited to installments due and payable for periods within the Term) in the
manner in which such taxes and assessments are imposed as of the date hereof;
provided, that if because of any change in the taxation of real estate, any
other tax or assessments (including, without limitation, any occupancy, gross
receipts or rental tax) is imposed upon Landlord, Sublandlord or the owner of
the Land and/or Building, or upon or with respect to Office Unit 2 or occupancy,
rents or income therefrom, in substitution for, or in addition to any of the
foregoing Taxes, such other tax, assessment or fee shall be deemed part of
Taxes, subject in all events to the next sentence. Taxes for any Tax Year shall
include PILOT (or a proportionate share thereof, as THE CASE MAY BE) AS is
payable under the Ground Lease. The term "TAXES" shall not include Municipal,
State or federal income, franchise, capital gain, inheritance, estate,
succession, transfer, or gift taxes of landlord, sublandlord or any corporate
successor of such party; provided, however, that if any tax, assessment, levy
(including but not limited to, any municipal, state or federal levy), imposition
or charge, or any part thereof, shall be measured by or be based in whole or in
part upon office unit 2 and shall be imposed upon landlord or sublandlord, then
all such taxes, assessments, levies, impositions or charges, or the part
thereof, to the extent that the same are so measured or based, shall be deemed
to be included within the term taxes.
39
<PAGE>
(ii) "Tax Year" shall mean The City of New York fiscal year, July 1
through June 30 (or such other fiscal year as hereafter may be duly adopted by
{he City of flew York as the fiscal year for real estate tax purposes), all or a
portion of which falls within Term.
(iii) "Office Portion Operating Expenses" shall mean the sum of
(X) office portion allocable operating expenses (as hereafter defined), and (y)
the following costs and expenses, without duplication (and all taxes thereon, if
any), reasonably paid or incurred in any calendar year during the term by
landlord or on behalf of landlord (including, without limitation, by the board
of managers on behalf or for the account of landlord) and directly attributable
to the operation, cleaning (of the common areas), repair, safety, management,
security and maintenance of the office portion, and which under generally
applied real estate practice in the City of New York for comparable building
are properly chargeable as operating expenses: (a) all reasonable compensation
paid to the following categories of employees performing services required in
connection with the actual operation, repair and maintenance of the office
portion, including common areas: (1) the building manager and staff who work
full time in the office portion, or if less than full time, whose time is
prorated for the time spent on matters directly related to the office portion;
and (2) all persons engaged in the actual operation, repair and maintenance of
any part of the office portion
40
<PAGE>
And building systems, including, without limitation, engineers, mechanics,
electricians, plumbers, porters and janitors who work full time in the office
portion, or if less than full time, whose time is prorated for the time spent on
matters directly related to the office portion (collectively, "employees"): (b)
the cost of all hospitalization, medical, surgical, union (or other contractual)
and general welfare benefits (including group life insurance) and any pension,
retirement or life insurance plan and other benefit or similar expense relating
to some or all of the employees; (c) social security, unemployment and other
payroll taxes paid in respect of some or all of the employees; (d) the cost of
providing disability and worker's compensation coverage imposed by any legal
requirements, union contract or otherwise with respect to the employees; (e) the
cost of casualty, liability and fidelity insurance that a prudent owner of a
building comparable to the office portion would maintain or which may be
required pursuant to the terms and provisions of the ground lease or any
mortgage (subject to allocation of cost if premiums for any of the foregoing
insurance covers any properties in addition to the land and the improvements
thereon); (f) the cost of maintenance, painting and repairs, that, under
generally accepted accounting principles, consistently applied, are not
capitalized; (g) the cost or rental of all cleaning supplies, tools, materials
and equipment that, under generally accepted accounting principles consistently
applied, would not be capitalized; (h) the cost or rental of uniforms, work
clothes, laundering and dry cleaning for employees:
41
<PAGE>
(i) the cost of window cleaning, landscaping, guard, watchman or other security
services or systems, if any; (j) charges of independent contractors or
consultants performing work which, if performed by employees, would be included
within this definition of office portion operating expenses: (k) legal fees,
costs and disbursements paid to outside counsel, but excluding those (1) related
to disputes with tenants, based upon landlords negligence or other tortious
conduct, (2) relating to enforcing any leases except for enforcing lease
provisions for the benefit of the building tenants generally, (3) relating to
the defense of landlord's title to, or interest in, the building or the land, or
(4) to the extent reimbursed directly to landlord by other tenants (but not as a
part of office portion operating expenses), (l) accounting, engineering,
architectural and other professional fees and disbursements; (m) water costs,
water rates, sewer rents, frontage charges and sales taxes, for the portions of
the office portion not leasable to other tenants; (n) other costs reasonably
necessary to operate, repair, manage and maintain the office portion in a first
class manner and condition; (o) reasonable management fees, whether the office
portion is or is not managed by landlord or an affiliate of landlord; and (p)
the cost of all charges for energy (including costs for energy generated by a
power plant operated by or on behalf of landlord in the building, provided same
(including any construction cost component thereof), shall not exceed the lowest
rate available to landlord from a public utility company servicing the office
portion), including,
42
<PAGE>
without limitation, gas, oil, steam, electricity (for the portions of the Office
Portion not leasable to other tenants), heat, ventilation, air conditioning,
water and other utilities for the portions of the Office Portion not leasable to
other tenants (together with any taxes or impositions with respect to such
utilities and together with all costs and expenses incurred in maintaining,
repairing and servicing the, equipment providing same that, under generally
accepted accounting principles, consistently applied, would not be capitalized);
provided, however, that any such amounts shall not exceed that which is
customarily paid to unaffiliated third persons in arms length transactions in
New York City for comparable items or services in a business operation of a size
and nature as that being operated by Landlord in the Office Portion.
The foregoing costs and expenses shall exclude or have deducted
from them the following items, as the case may be. In addition, in no event
shall "Office Portion Operating Expenses" under clause (y) above include costs
that are otherwise either (i) included in office portion allocable operating
expenses or (ii) directly passed through to tenant under this lease, including,
without limitation, pursuant to article 5, it being understood and agreed that
there shall be no duplication of charges to tenant. (1) Executive's salaries
above the grade of building manager at the building; (2) expenditures for
replacements, alterations or other capital improvements in accordance with
generally accepted
43
<PAGE>
accounting principles (other than those which under generally applied real
estate practice are expenses or regarded a deferred expenses), exclusive of
capital improvements made by Landlord after the Building is substantially
completed (i) which have the effect of reducing expenses which would otherwise
be included in Office Portion Operating Expenses, but only to the extent of such
savings, or (ii) which are made in compliance with Governmental Requirements
enacted after the Building is substantially completed (as, for example, New York
City Local Law No. 5), in each case amortized over the useful life of the
improvement with a reasonable salvage value on a straight-line basis (together
with interest thereon incurred by Landlord at the prevailing rates) which SHALL
be included in Office Portion Operating Expenses for the Comparison Years (as
hereafter defined) during which such amortization occurs. If landlord shall
lease any item of capital equipment designed to result in savings or reductions
in expenses which would otherwise be included in office portion operating
expenses, then the rentals and other costs paid in connection therewith shall be
included in office portion operating expenses for the comparison year in which
they are incurred, but only to the extent of such savings; (3) cost of repairs
or replacements incurred by reason of fire or other casualty or condemnation to
the extent landlord is compensated therefor through insurance; (4) depreciation,
except as provided above; (5) taxes (as defined in subparagraph (a)(i) above);
(6) the cost of any item or service such as electricity, furnished to pace
leasable or leased to tenants (including tenant) in the building
44
<PAGE>
and billed for and paid for separately or billable separately for such space by
such tenants; (7) financing and refinancing costs and debt service (including
amortization) payable under any Mortgage or any other debt for borrowed money;
(8) Landlord's franchise- or income taxes; (9) leasing commissions, costs,
disbursements and other expenses including architectural and legal fees incurred
for leasing, renovating! or improving space for tenants, including Tenant; (10)
costs (including permit, license and inspection fees) incurred in renovating,
improving, decorating, painting or redecorating, vacant space or space for
tenants; (11) costs of a capital nature, including capital improvements, capital
repairs, capital equipment, and capital tools, as determined under generally
accepted accounting principles consistently applied, except that the annual
Amortization of these costs shall be included to the extent expressly permitted
in (2) above and subparagraph (p) of this subparagraph 3.3(A)(iii); (12)
overhead and profit paid to affiliates for services on or to the office portion
or for supplies or other materials, but only to the extent that the costs of the
services, supplies, or materials including overhead and profit exceed the
competitive costs of the services, supplies or materials were they not provided
by an affiliate;(13) compensation paid to clerks, attendants or other persons in
commercial concessions operated by landlord; (14) rentals and other related
expenses incurred in leasing air conditioning systems, elevators, or other
equipment ordinarily considered to be of a capital nature, except equipment used
in providing janitorial services that is not affixed
45
<PAGE>
to the Office Portion, or except as otherwise expressly permitted under
subparagraph (2) above; (15) items and services for which Tenant reimburses
Landlord or pays third parties or that Landlord provides selectively to one or
more tenants of the Office Portion other than Tenant with or without
reimbursement; (16) advertising and promotional expenditures; (17; costs
incurred in operating the Garage Portion or the Hotel Portion other than as
provided hereinbelow; (18) during the firs.: five years of the Term,
nonrecurring costs incurred to remedy structural defects in original
construction materials or installation; (19) any fines or penalties incurred
because Landlord violated any governmental rule or authority, including late
payment of water and sewer rents, except if same is due to Tenant's fault; and
(20) costs of any repairs made by Landlord to remedy damage caused by or
resulting from the negligence of Landlord, its agents, servants or employees.
(iv) "Tenant's Pro Rata Share" shall mean the percentage arrived at
as of the commencement of each CALENDAR YEAR by dividing the Size of the
Premises by the Gross Leasable Area of the Office Portion. The parties agree
that as of the date hereof, Tenant's Pro Rata Share is 34.428%.
(V) "office portion allocable operating expenses" shall mean
sixty-four and four-tenths (63.445) Percent of the "operating expenses" (as
hereafter defined) incurred in any calendar year during the term in respect of
(a) the common elements
46
<PAGE>
And (b) those limited common elements which are appurtenant both to the Office
Portion and either the hotel portion or the garage portion. Such percentages
shall be subject to review from time to time on an item by item basis upon the
request of either party and may be adjusted based on actual experience. In no
event shall "office portion allocable operating expenses 't include costs that
are otherwise either (i) included in "office portion operating expenses" or
(ii) directly passed through to tenant under this lease, including, without
limitation, pursuant to article 5 hereof, it being understood and agreed that
there shall be no duplication of charges to tenant. In the event of a dispute,
the same shall be determined by arbitration in accordance with section 15.1 Of
the lease. For the purposes of this subparagraph (v), "operating expenses" shall
mean all reasonable costs and expenses (and all taxes thereon, if any) paid or
incurred by or on behalf of landlord or by the board of managers with respect to
the operation, cleaning, repair, safety, management, security and maintenance of
the common elements and of those limited common elements appurtenant both to the
office portion and either the hotel portion or the garage portion, as the case
may be, exclusive of (a) those categories of expenses excluded from office
portion allocable operating expenses as items 1-20 in subparagraph (a)(iii)
above or (b) attributable exclusively to any one of the office portion (or any
unit therein), the hotel portion or the garage portion or to both the hotel
portion and the garage portion (but not the office portion). Landlord agrees
that the consumption of all utilities,
47
<PAGE>
including water, electricity, heating, air-conditioning and gas, used
respectively at the Office Portion, the retail tenancies in the Office Portion,
if any, the Hotel Portion and the Garage Portion, as applicable, shall be
metered separately, unless same is prohibited by law or not feasible.
B. Taxes
(i) tenant shall pay to sublandlord, or as sublandlord shall
otherwise direct, from time to time within thirty (30) days after written demand
therefor (which demand shall not be made earlier than forty (40) days prior to
the due date for payment of such taxes), an amount or sum ("tenants tax
reimbursement") equal to taxes. If such payment is not made by tenant in a
timely fashion so as to avoid the imposition of any interest or penalties for
late payment of taxes, then tenant shall be responsible for any and all such
interest, penalties and other late charges that may be imposed and same shall be
payable by tenant upon demand as additional rent and shall be deemed to be a
part of tenant's tax reimbursement. The real estate taxes involved in this
subparagraph shall be initially computed on the basis of the assessed valuations
in effect at the time the demand is sent (as such assessed valuations may have
been settled or finally adjudicated prior to such time) regardless of any then
pending applications, proceedings or appeal respecting the reduction of any such
assessed valuations, but shall be subject to subsequent adjustment as provided
in
48
<PAGE>
subparagraph (ii) below.
(ii) In the event that, after a demand has been sent to Tenant, an
assessed valuation which had been utilized in computing the Taxes for such Tax
Year is reduced (as a result of settlement, final determination of legal
proceedings or otherwise), and as a result thereof a refund of Taxes is actually
received by or on behalf of Landlord, then, Tenant shall be entitled to
receive a credit in the amount of its Pro Rata share thereof.
(iii) provided that tenant shall have made all payments of
tenant's tax reimbursement when due, tenant hall have the right, but not the
obligation, to contest the separately assessed valuation of office unit 2 by any
and all legal means, at tenant's sole cost and expense in the event that
landlord shall fail to institute tax certiorari proceedings with respect to any
such tax year. In no event shall landlord compromise or settle with respect to
the assessed valuation of office unit 2 for a tax year during the term without
the consent of tenant which shall not be unreasonably withheld or delayed.
(iv) tenant hall be entitled to any and all credits against
payment of pilot attributable to office unit 2 as may be available to tenant or
which may have been otherwise negotiated with the city of New York, provided
that tenant hall remain obligated to make all payments of taxes assessed
against
49
<PAGE>
Office Unit 2 as the same shall appear on the tax rolls. In no event shall
Tenant be liable for payment of the "Deferred Obligations" as the same are
defined in that certain Assignment and Assumption of Severance Ground Lease of
even date herewith between MWR and Landlord.
C. Office Portion Operating Expenses
(i) a) commencing on the completion date and continuing during
each full or partial calendar year thereafter during the term, tenant shall pay
in the manner and at the times herein set forth, tenant's pro rata share of
office portion operating expenses ("tenants operating expense payment") for
such full or partial calendar year as follows: (y) to sublandlord, or as
sublandlord shall otherwise direct, a portion of tenant's operating expense
payment in an amount equal to the "base rent" payable from time to time under
the ground lease and (z) to landlord in an amount equal to the balance of
tenant's operating expense payment (i.e., The total amount of tenant's operating
expense payment less the amount of tenant'- payment to sublandlord on account of
ground lease "base rent"); provided, however, that during the concession
period, one-half of tenant's operating expense payment hall be abated, as
provided in- subparagraph (b) below, provided, further that in no event shall
any such abatement reduce the possession rent payable by tenant. During the
concession period and the first and second lease years, tenant's
50
<PAGE>
Operating Expense Payment 1n respect of each such Concession Period or Lease
Year shall be deemed to be the aggregate payments of the Tentative Monthly
Operating Expense Charge for such Concession Period or Lease Year, as the case
may be.
b) together with tenant's monthly payment: to sublandlord of base
annual rent, each month during the term (and on the last day of any month during
the concession period), tenant shall pay to landlord, as additional rent on
account of tenant's operating expense payment a sum equal to the tentative
monthly operating expense charge (as hereinafter defined), which shall be
prorated for any partial month during the term. As used in this subparagraph
(c), the term "tentative monthly operating expense charge" shall mean, (a)
during the concession period, a sum (as abated) equal to one-twelfth (1/12) of
the product of (x) the size of the premises (proportionate if tenant has
accepted delivery of less than all of the premises) and (y) $2.50; (B) in the
case of the first lease year, a sum equal to one-twelfth (1/12) of the product
of (x) the size of the premises (proportionate if tenant is occupying less than
all of the premises), and (y) $5.00; (C) in the case of the second lease year, a
sum equal to one-twelfth (1/12) of the product of (m) the size of the premises
(proportionate if tenant is occupying less than all of the premises), and (n)
$6.00; And (d) in the case of the third lease year and each successive lease
year, a sum equal to 105` of the tentative monthly operating expense charge
applicable to the
51
<PAGE>
last month of the immediately preceding Lease Year. Commencing with the third
Lease Year, at such time as the Actual Office Portion Operating Expenses (as
hereinafter defined) for the preceding calendar year are determined, the
Tentative Monthly Operating Expense Charge shall be recalculated based upon the
Actual Office Portion Operating Expenses for such calendar year. Upon such
recalculation, tenant shall pay to Landlord, within sixty (60) days after
Tenant's receipt of Landlord's statement (as described in subparagraph (c)
below), the difference between (x) the recalculated Tentative Monthly Operating
Expense Charge that should have been paid to date for the current Lease Year and
(y) the amounts actually paid to date on account of the Tentative Monthly
Operating Expense Charge for the current Lease Year and shall commence monthly
payments of the recalculated Tentative Monthly Operating Expense Charge with the
monthly payment next due.
c) Within one hundred fifty (150) days after the expiration of the
Calendar year in which the third lease year-commences, and after the expiration
of each calendar year thereafter during the term (but not more often than once
in any calendar year), landlord will end to tenant a statement certified by a
financial officer of landlord setting forth the actual office portion operating
expenses for the immediately preceding calendar year (or, in the calendar year
in which the third lease year commences, the portion of such calendar year
occurring after the commencement of the third lease year) (the
52
<PAGE>
"Actual office portion operating expenses") and crediting tenant with the
amounts, if any, collected by landlord from tenant pursuant to subparagraph
b(ii) of this section during and on account of such preceding calendar year (or,
in the calendar year in which the third lease year commences, the portion of
such calendar year occurring after the commencement of the third lease year).
Landlord shall attempt to provide the foregoing statement to tenant within one
hundred twenty (120) days after the expiration of each calendar year. If such
statement reflects an amount due to landlord for such calendar year, tenant
shall pay such amount to landlord as additional rent within ninety (90) days
after receipt of such statement. Should tenant fail to pay landlord timely, as
aforesaid, any sums due pursuant to this subparagraph c, then tenant shall pay
interest on such unpaid amounts at the late rate, calculated from the date of
landlord's statement until the date tenant's payment is received. If landlord's
statement reflects that the amounts theretofore collected by landlord from
tenant on account of any such calendar year exceed the amount actually due from
tenant for such calendar year, the excess shall be credited against the services
rent (and not the possession rent) next becoming due from tenant.
D) any delay or failure of landlord in computing or billing for
the rent adjustments hereinabove provided shall not constitute a waiver of or in
any way impair the continuing obligation of tenant to pay such rent adjustments
53
<PAGE>
hereunder.
e) Notwithstanding any expiration or termination of this Lease
prior to the Lease expiration date , Tenant's obligation to pay rent as adjusted
under this Paragraph shall continue and shall cover all periods up to the Lease
expiration or termination date, and shall survive any expiration or termination
of this Lease, provided that in no event will this Lease be cancelled or
terminated, nor Tenant's obligation to pay Posession Rent and/or Bond Support
Payments be affected, modified or compromised in any way, so long as any of the
Empire Notes shall remain outstanding.
D. General
(i) any demand for taxes or statement of operating expenses sent to
tenant shall be conclusively binding upon tenant unless, within one hundred
twenty (120) days after such statement is sent, tenant shall send a written
notice to landlord objecting to such statement and specifying the respects in
which such statement is claimed to be incorrect. If such notice is sent and the
parties are unable to settle the matter between themselves within thirty (30)
days thereafter, either party may refer the matter to arbitration in accordance
with article 15.1 Hereof. Notwithstanding any objection sent by tenant disputing
any comparative statement, tenant shall at all times be obligated to
54
<PAGE>
make the payments to Landlord required pursuant to this Section 3.3 while the
resolution of such dispute is pending.
(ii) The expiration or termination of this Lease during any Tax
Year or any Lease Year for any part or all of which there is an increase in Base
Annual rent under this section 3.3 Shall not affect the rights or obligations of
the parties hereto respecting such increase, and any statement relating to such
increase shall be sent to tenant subsequent to, and all such rights and
obligations shall survive, on a pro rata basis, any such expiration or
termination. Any payments due under such statement shall be payable within
thirty (30) days after such statement is sent to tenant, failing which tenant
shall pay landlord or sublandlord, as the case may be, interest at the late rate
on such unpaid amounts, calculated from the date tenant receives any such
statement until the date tenant's payment is received.
(iii) the payments, if any, required to be made to landlord or
sublandlord, as the case may be by tenant pursuant to any of the provisions of
this section 3.3 Shall be deemed payments of additional rent, the nonpayment of
which shall entitle landlord and sublandlord to any and all of the remedies
available to such party under this lease and applicable law for the nonpayment
of rent.
55
<PAGE>
(iv) Tenant and its authorized representative, upon reasonable notice
to Landlord and at reasonable times, shall have the right to examine any and all
records of Landlord then currently in Landlord's possession at Landlord's
offices as required under the rules and regulations promulgated by the Internal
Revenue Service for record retertion (collectively, the "Retained Records"),
pertinent to Office Portion Operating Expenses or Taxes for the purpose of
verifying the accuracy of any statement furnished by Landlord to Tenant for the
period for which Landlord has, in its possession, such Retained Records. Subject
to the requirements of any applicable law, rule or regulation of governmental
authorities or court of competent jurisdiction, Tenant will maintain the
confidentiality of Landlord's non-public records.
(v) Notwithstanding anything to the contrary contained in this Lease,
In no event shall tenant be obligated to pay tenant's operating expense payment
in respect of any portion of the premises for any period prior to the completion
date of such portion; provided however, that tenant shall be obligated to make
such payment to the extent the same constitutes possession rent hereunder.
Section 3.4 Late charges. If, during the term of this lease, tenant
------------
shall fail to pay any payment of rent within ten (10) days after same is first
due or payable, tenant agrees to pay to landlord or sublandlord, as the case may
be (i.e., The party to
56
<PAGE>
whom the applicable payment is payable) as and for agreed upon late charges (and
not a penalty) on account of the additional administrative, accounting and
overhead costs attributable to Tenant's delinquency, an amount (the "Late
Rate") equal to the lower of: (i) the rate of interest payable under the Empire
Notes plus two (2%) percent or (ii) the highest rate permitted by law, on the
amount not paid when due, from the due date until the date of payment. All
amounts payable to Landlord or Sublandlord pursuant to this Section 3.4 shall
be considered additional rent. Nothing contained in this Section 3.4 or
otherwise is intended to grant Tenant any extension of time in respect of the
due dates for any payments of Rent under this Lease, nor shall same be construed
to be in limitation of or in substitution for any other rights, remedies or
privileges available to Landlord or Sublandlord under this Lease, at law, in
equity or otherwise.
ARTICLE 4
COMMON AREAS
SECTION 4. Common Areas.
------------
A. Landlord, at its sole cost and expense, shall cause the building to
contain a separate lobby and entrance located on the east side of the office
portion (the "east lobby") solely for the use of tenant with respect to the
floors of the premises and for the use of tenants of the floors above the
premises with respect to
57
<PAGE>
said floors. In the event that Governmental Requirements require connecting
doors between the East Lobby and any other Office Portion lobby, said connecting
doors will be for emergency use only. The size of the East Lobby shall be
substantially proportionate (taking into account the physical constraints and
dimensions as reflected in the Preliminary Plans and Specifications) to the
total square footage of Tenant's floors and the floors above tenant's floors
versus the total square footage of the remainder of the Office Portion floors.
The design of the East Lobby will be subject to Landlords and Tenant's
reasonable mutual review and approval prior to the construction thereof which
shall conform to the agreed upon design.
B. The public hallways, elevators, shafts, office portion main lobbies,
loading docks, mechanical spaces and shafts, electric and telephone closets,
bathrooms, and such other public areas or common conveniences within the office
portion identified or shown in the condominium documents as limited common
elements appurtenant to the office portion and/or such other spaces designated
as such from time to time by landlord for the common use of the office portion
are collectively referred to a. "Common areas." Common areas located outside the
premises may thereafter be excluded therefrom when designated by landlord for
non-common use, and any portion thereof not initially included within common
areas may be included when so designated by landlord for common use, without
tenant's consent. If landlord desires to make any material change
58
<PAGE>
to the Common Areas located wholly within the Premises or to the West Lobby,
Landlord shall first obtain Tenant's prior written approval, which approval
shall not be unreasonably withheld or delayed. If Tenant has not responded to
Landlord within thirty (30) days after Landlord's written notice requesting such
approval, Tenant's approval shall be deemed given. If Landlord must make any
such changes due to an emergency or prior to Tenant's initial occupancy,
Tenant's approval need not be obtained. Disputes between Landlord and Tenant
under this Section 4.1 shall be resolved as provided in the expedited dispute
resolution mechanism set forth in Section 15.2 hereof.
C. Except as otherwise provided in this lease, no schedule, exhibit,
sketch, plan, drawing, rendering, brochure, flyer, or the like shall be deemed
to create a warranty, representation or agreement on the part of landlord that
the office portion and/or the common areas or any portions thereof will be or
will continue to be exactly as indicated thereon, and landlord reserves the
right at its sole and absolute discretion to (i) increase, reduce, change or
(with respect to common areas only) eliminate the number, type, size, location,
elevation, nature and use of any or all of the same, (ii) make changes,
additions, alterations, or improvements in or to any or all of the same, and
(iii) convert from time to time common areas into space available for leasing to
tenants and/or reconvert any such space, or convert any other space in the
office portion, into common areas. Any such alterations, restorations,
59
<PAGE>
renovations or other such work in the Office Portion may result in certain
inconveniences or disturbances to Tenant. Landlord shall use reasonable efforts
to minimize the interference of such work with Tenant's operation of its
business but nothing contained herein or otherwise shall require Landlord to
take extraordinary measures or incur additional (or overtime) costs or expenses
to complete such work, and Tenant agrees that the performance of any such work
shall not constitute or be deemed to be a constructive eviction or be grounds
for a termination of this Lease or the term hereof, nor shall the same in any
way affect the obligation to pay the Rent herein reserved, it being understood
that Tenant shall have the right to claim damages from Landlord or Landlord's
agent(s) or contractor(s) (but not from Sublandlord) or to seek equitable relief
from a court of competent jurisdiction.
D. Except as otherwise expressly provided in this lease, tenant, its
agents, employees and invitees shall have free use of any of the common areas
outside the premises subject to the rules and regulations which shall be
applied in a uniform and consistent manner.
E. Landlord reserves the right to close, if necessary, all or any
portion of the common areas outside the premises for the minimum length of time
as may, in the reasonable opinion of landlord's counsel, be legally sufficient
to prevent a dedication thereof or the accrual of the right of the public
therein.
60
<PAGE>
Landlord hereby notifies Tenant, and Tenant acknowledges such notice, that
Landlord does not in any manner permit or authorize usage by the public that
might create a legally sufficient dedication or accrual of any rights therein by
the public.
F. Tenant shall have no right to affix any sign, banner or other item
of any nature whatsoever to the exterior of the premises or its windows, or to
any part of the common areas or the office portion or which may be visible to
the public through the windows or common areas, unless and until the sign,
banner or other item has been approved by landlord in its sole discretion. In
the event tenant affixes same in violation of the provisions hereof, then in
addition to the remedies available to landlord under this lease and applicable
law, landlord shall have the right to remove same and charge tenant, as
additional rent, for the costs of such removal and for restoring the area from
which the sign, banner or other items was removed. On all floors of the
premises, tenant, in tenant's sole discretion, shall have the right to affix, or
permit its designees to affix, any and all signs provided that the same shall be
in good taste and consistent with a first class office/hotel building. Banners
and other items of any nature whatsoever shall not be affixed without notice to
and the consent of landlord, which consent shall not be unreasonably withheld or
delayed.
61
<PAGE>
ARTICLE 5
UTILITIES - SERVICES
Section 5.0 Sublandlord. Landlord and Tenant each acknowledge and -----------
agree that Sublandlord shall not be responsible for providing any of the
utilities or services described in this Article and each hereby expresly waives
and releases Sublandlord, but not Landlord, from any responsibility or
obligation with respect thereto.
Section 5.1 Electricity
-----------
A. Landlord shall furnish or shall cause to have furnished, at Landlord's
sole cost and expense, the mains, conduits, pipes and wiring necessary to bring
the electric current described in the Base Building up to each floor of the
Premises. Tenant shall be responsible at Tenant's sole cost and expense for the
distribution of electric service throughout the Premises.
(i) Tenant covenants and agrees to contract for and pay directly to
the public utility company servicing the premises all charges for electricity
consumed by tenant in respect of the premises (including, but not limited to,
electricity for operating that portion of the HVAC system (such as air handlers)
located within the premises as measured
62
<PAGE>
by Tenant's meter. Landlord shall, at Tenant's sole cost and expense and prior
to Tenant's opening for business, install a direct meter or meters to measure
the electric consumption by Tenant at the Premises and shall separate said
meter(s) from Landlord's and other tenants' meters. As soon as practicable, such
meter(s) shall be transferred to the account of Tenant and shall be maintained
by Tenant during the Term. Landlord shall not be responsible for any charges for
electricity consumed at the Premises by Tenant. Tenant may, without the further
consent of Landlord, at Tenant's sole cost and expense, install separate meters
for each floor of the Premises to the extent permitted by the utility company.
(ii) to the extent applicable, tenant shall pay all sales, use and
other taxes imposed by any governmental authority upon the manufacture, sale,
use, transmission, distribution or other process necessary or incidental to the
furnishing of electric energy to the premises. If landlord has paid said taxes,
tenant shall reimburse landlord for the full amount thereof on presentation of
proof of payment.
(iii) tenant's use of the electric current in the premises shall not
at any time exceed the electrical capacity of the office portion as set forth in
the base building specifications, without landlords prior written
63
<PAGE>
approval. The granting of Landlord's approval may be conditioned upon Tenant's
payment to Landlord, as additional rent, for any increased capital or operating
costs required to provide or resulting from such increase in electrical
capacity.
(iv) Landlord shall not be liable for any failure or defect in the
supply of electric energy furnished to the Premises by reason of any
requirement, act or omission of the public utility providing the Office Portion
with electricity.
(v) Tenant agrees that Landlord, in its sole discretion, may install
or cause to have installed in the building a self-generating electric and/or
thermal HVAC facility prior to or during the term. In such event, tenant shall
utilize the energy generated by or otherwise distributed through such
facilities, provided the cost thereof shall not exceed the lowest applicable
rate that would have been payable by tenant to Consolidated Edison or other
applicable lower private utility rate; however, tenant may, in its discretion,
agree to pay a higher rate if- it determines that it in in tenant's best
interest to do so
Section 5.2 Access. Landlord shall afford Tenant access to the Premises on
------
a 24 hour per day seven (7) days per week basis. With respect to access to and
egress from the Premises
64
<PAGE>
during other than Standard Building Hours and Days, Tenant shall comply with the
Rules and Regulations and with any other reasonable arrangements made by
Landlord specifically there for.
Section 5.3 Elevator Service.
----------------
A. During the Term, Landlord, at Landlord's expense, shall furnish to
the Premises during Standard Building Hours & Days not less than six express
elevator cars serving the Lobby of the Office Portion and floors 7 and 20-31 of
the Office Portion. During other than Standard Building Hours and Days, there
shall be at least one car available, and a second car may be made available upon
Tenant's request, if necessary in Tenant's reasonable judgment.
B. Landlord will designate one or more service elevators in the Office
Portion for use for shipping and delivery and Tenant agrees that Tenant will use
(and shall cause any persons claiming through or under tenant to use) only the
elevator or elevators so designated for all shipments and deliveries in
accordance with Building Rules and Regulations and only by pre-arrangement and
confirmation with the Building management, such confirmation not to be
unreasonably withheld or delayed. Tenant agrees that Tenant will not ship or
deliver, or permit the shipping or delivery of, any furniture or equipment into
or
65
<PAGE>
out of the Office Portion or between floors within the Premises and that Tenant
will not make and receive, and permit the making and receiving of, any other
shipments or deliveries of furniture or equipment except (i) during the hours
between 10:00 a.m. and 11:30 a.m. and between 2:30 p.m. and 4:00 p.m. (ii) after
business hours, or (iii) in accordance with the Rules and Regulations.
Section 5.4 Heat. Landlord, at Landlord's expense, shall furnish heat
----
to the Premises during Standard Building Hours and Days in accordance with the
specifications of the Base Building. Tenant agrees to use best efforts to cause
any operable windows, if any, in the Premises to be closed at all times during
heating season.
Section 5.5 Air-Conditioning. Landlord, at Landlord's expense, shall
----------------
furnish and distribute to the Premises during Standard Building Hours and Days
conditioned air at temperatures and degrees of humidity in accordance with the
specifications of the Base Building (subject, in all events, to applicable
Governmental Requirements).
Notwithstanding the foregoing PROVISIONS OF SECTIONS 5.4 and
5.5 hereof, Landlord shall not be responsible if the normal operation of the
Building air conditioning or heating systems shall fail to provide heat or
conditioned air at
66
<PAGE>
reasonable temperatures, pressures or degrees of humidity in any portions of the
Premises or ventilated air: (a) if any machinery or equipment installed by or on
behalf of Tenant, or any Person claiming through or under Tenant, shall have an
electrical load in excess of the electric load per square foot of Floor Space of
the Premises permitted in the Base Building, or by reason of a human occupancy
factor in excess of one person per 100 square feet of Floor Space; (b) because
of any rearrangement of partitioning or other alterations made or performed by
or on behalf of Tenant or any person claiming through or under Tenant; or (c) as
a result of the improper installation by Tenant or its contractors of duct work
or any other work. Tenant shall cooperate fully with Landlord at all times and
abide by all rules, regulations and requirements which Landlord may reasonably
prescribe for the proper functioning and protection of the ventilation, air
conditioning and heating systems.
Section 5.6 Water. Landlord shall furnish tenant with hot and cold
-----
water for ordinary lavatory, sanitary and drinking purposes on all floors of the
premises, but if tenant uses or consumes water for any other purposes, landlord
may install one or more water meters at tenant's expense and thereby measure all
or any part of tenant's consumption of water in the office portion. Tenant shall
pay to landlord the coat of any such meters (including installation) within
twenty (20) days after
67
<PAGE>
demand, and Tenant shall keep any such meters and any such installation
equipment in good working order and repair, at Tenant's cost and expense. Tenant
agrees to pay directly to the utility or the Landlord as the case may be, for
water consumed as shown on said meters and sewer charges and taxes thereon,
within twenty (20) days after bills are rendered. For the purposes of
determining the amount required to be paid by Tenant under this Section, all hot
and cold water consumed during any period when said meters are not in good
working order (it being understood that a finding by any Governmental Authority
that such meters are not in good working order shall be determinative as between
Landlord and Tenant) shall be deemed to have been consumed at the rate of
consumption of such water during the most comparable period when such meters
were in good working order.
Section 5.7 Directory. Tenant shall be entitled to, at landlord's
---------
expense, a separate directory in the office portion lobby, subject to landlord's
reasonable approval as to size, location and style so as to conform generally
with any other office portion directory. Landlord hereby agrees that tenant
shall have an opportunity to consider the size, design and location of the
office portion directory provided that such consideration shall be exercised in
a reasonably prudent and expeditious manner. Tenant hereby agrees that subject
to its approval (which will not be unreasonably withheld or delayed),
68
<PAGE>
Office Portion directories may be electronic. Landlord agrees to add or delete
all entries in such directories within thirty (30) days after Tenant's request
therefor.
Section 5.8 Cleaning.
--------
(1) Landlord, at tenant's cost and expense, shall cause the premises
(excluding any portions of the premises used for the storage, preparation,
service or consumption of food or beverages other than in limited kitchenettes
which may contain a microwave, sink, refrigerator and lunch tables) to be
cleaned and shall cause tenant's ordinary office refuse to be removed, all at
regular intervals, in accordance with the cleaning specifications. Tenant shall
pay as additional rent within twenty (20) days after written demand from
landlord for the removal of any other tenant refuse or rubbish other than
ordinary refuse and for any other special cleaning services requested by tenant
including areas within a kitchenette- or lounge. If segregation or separation of
any rubbish is required by governmental performed by occupants of the office
portion, same shall be performed by tenant within the premises at tenant's sole
cost and expense. Tenant may elect to enter into a cleaning contract for the
premises with a contractor other than landlord, in which event tenant will not
be charged for cleaning services by landlord in respect of the premises.
69
<PAGE>
(2) Landlord shall cause the windows of the Premises to be
cleaned (interior and exterior) two (2) times in each calendar year during the
Term unless Tenant shall have contracted for its own cleaning services for the
Premises, and such contract shall include window cleaning.
Section 5.9 Extra Services. The Base Annual Rent does not reflect or
---------------
include any charge to Tenant for the furnishing or distributing of heat,
air-conditioned air or mechanical ventilation to the Premises, or other Building
services (other than access), during other than Standard Building Hours and
Days. Accordingly, if Tenant requests Landlord to furnish any such services
during other hours or days, Tenant shall pay as additional rent, within thirty
(30) days of being billed for such services, $40 per hour for each whole or
partial floor, subject in all instances to periodic increases (not more than
once per Lease Year) to reflect actual percentage increases payable by Landlord
for providing such extra services. In the event of a dispute between Landlord
and Tenant as to the increased rates for any such extra services, the same shall
be resolved by arbitration conducted in accordance with the terms and provisions
of Section 15.1 hereof, but pending such resolution, Tenant shall pay to
Landlord all amounts as and when billed by Landlord. Landlord shall not be
required to furnish any such services during such other periods, unless Landlord
has received reasonable notice from tenant requesting such
70
<PAGE>
services and Landlord is able to provide same.
Section 5.10 Parking. So long as this Lease shall be in full force and
-------
effect, Tenant shall be entitled to, and Landlord shall cause the operator of
the Garage Portion to provide to Tenant, throughout the Term, valet or self-park
parking spaces in the Garage Portion in the initial minimum number of 90 spaces
and upon the terms and conditions as provided in that certain Parking Agreement
of even date herewith between and among Landlord, Tenant and Renaissance
Property Managers LLC, intended to be recorded herewith.
Section 5.11 Interruption of Services.
------------------------
A. Landlord reserves the right to temporarily stop any service or facility in
the building when necessary by reason of construction in other parts of the
building, accident or emergency, or for repairs, alterations, replacements or
improvements, which, in the judgment of landlord are desirable or necessary, or
required to be made by landlord or tenant pursuant to this lease, until said
repairs, alteration9, replacements or improvements shall have been completed.
Landlord shall attempt to notify tenant in advance of any planned interruption
of services to the premises, it being understood that no advance notification
need be given in case of accident or emergency. The exercise of such right by
71
<PAGE>
Landlord shall not constitute an actual or constructive eviction, in whole or in
part, or entitle Tenant to any abatement or diminution of Rent, except as
provided in Paragraph (B) of this Section, or relieve Tenant from any of its
obligations under this Lease, or impose any liability upon Landlord or its
agents by reason of inconvenience or annoyance to Tenant, or injury to or
interruption of Tenant's business, or otherwise. Landlord agrees that it shall
prosecute such work during normal hours for construction with continuity,
diligence and dispatch and shall not, considering the nature and extent of the
work, unreasonably interfere with Tenant's use of or access to the Premises.
B. Notwithstanding anything in this Section 5.11 or otherwise in this
Lease to the contrary, in the event that Landlord, within fifteen (15) days
after its receipt of notice from Tenant, does not cure a default by Landlord in
providing any service required to be provided by Landlord to Tenant pursuant to
Article 5 of this lease and identified in such tenant's notice (or in
distributing to the premises any service which is actually being provided by a
utility), and such default is not caused by the failure of a utility company to
provide services it was otherwise providing or by the acts or negligence of
Tenant, its agents or employees, and provided further that as a direct and
proximate cause of such default, Tenant is unable to occupy the Premises (or a
portion thereof
72
<PAGE>
for the purposes set forth in Section 7.1(A)), then, as Tenant's sole remedy,
effective upon Landlord's receipt of a second notice from Tenant given not
earlier than the expiration of the fifteen (15) days grace period referred to
above and stating that such default by Landlord is continuing, Rent shall abate
(proportionately if only a portion of the Premises is so affected), subject to
the last sentence of this Section, for the period commencing from Landlord's
receipt of Tenant's second notice and continuing until the earlier of the date
such default is cured or the date Tenant is able to re-occupy the Premises for
the purposes permitted under Section 7.1(A). In the event of a dispute between
Landlord and Tenant respecting any matter referred to in this Section 5.11(B),
the same shall be resolved by arbitration conducted in accordance with the terms
and provisions of Section 15.1 hereof, provided that pending the resolution of
such dispute Tenant shall continue to pay all of the Rent due hereunder in
accordance with the terms and provisions of this Lease subject to receiving the
appropriate credit or refund by Landlord upon the resolution of such dispute
(together with interest on the amount of any refund at the Late Rate, from the
date paid to and collected by Landlord to the date repaid). Notwithstanding
anything to the contrary set forth herein, so long as any of the empire notes
shall remain outstanding, Tenant shall continue to pay the full amount of
Possession Rent due from time to time hereunder notwithstanding any abatement of
Rent provided in this Section
73
<PAGE>
5.11B, and such abatement may be recovered only from the Services Rent accruing
from time to time hereunder.
Section 5.12 Miscellaneous. Except as elsewhere expressly provided in
-------------
this Lease, Landlord's obligation to furnish the services required to be
provided by Landlord pursuant to this Article 5 to the Premises or to an
individual Office Floor, as the case may be, shall commence on the Commencement
Date or such earlier or later date or dates that Tenant shall take possession of
the Premises or an individual Office Floor, as the case may be, in accordance
with the terms of this Lease.
ARTICLE 6
LANDLORD'S ADDITIONAL COVENANTS
Section 6.0 Sublandlord. Landlord and tenant each acknowledge and agree
-----------
that sublandlord shall not be responsible for performing any of the covenants or
agreements contained in this article, and each hereby expressly waives and
releases sublandlord, but not landlord, from any responsibility or obligation
with respect thereto.
74
<PAGE>
Section 6.1 Repairs by Landlord.
-------------------
A. Landlord, at its sole cost and expense, shall make or cause to be
made all structural repairs and replacements to keep in good order and repair,
consistent with other first class office buildings in the downtown Brooklyn
area, the land and the exterior of the office portion (including the roof,
exterior walls or curtain wall covering the extension of the building, windows,
sidewalks and foundation), the plumbing, electrical, heating, air conditioning
and ventilating systems of the office portion and the load-bearing walls and
columns, if any, within the building and the common areas, provided that
landlord shall not be obligated to do any work or perform any repairs arising
from any act, misuse, omission or negligence of tenant or its agents, employees
or invitees or that are required to be made by tenant a provided in section
7.1(C). Tenant hereby agrees to give written notice to landlord of the need for
any such repair, except in the case of an emergency, when such notice may be
oral. In any event, landlord shall be afforded a reasonable time in which to
commence such repair. Notwithstanding anything in this lease to the contrary,
tenant shall reimburse landlord for any and all repairs made by landlord
pursuant to this section 6.1 Which are not covered by landlord's insurance and
which are caused by any act, misuse, omission or negligence of tenant or its
invitees or licensees, their repective officers, agents, employees or visitors,
75
<PAGE>
within sixty (60) days after Landlord shall furnish a statement to Tenant of the
cost thereof, together with reasonable supporting documentation.
B. In the event hat Landlord fails to fulfill its obligations pursuant
to this Section 6.1, Tenant may, in addition to its other remedies against
Landlord (which may not, under any circumstances be exercised against
Sublandlord or in any way affect Possession Rent), give written notice to
Landlord specifying the repairs that Landlord has failed to perform and Landlord
shal7 commence performance of such work within ten (10) days after the giving of
such notice or within two (2) days in the case of emergency, and diligently
proceed to complete said work. Subject to Unavoidable Delays, if Landlord fails
so to commence or complete said work after said written notice, then Tenant, in
addition to any other remedy it may have against Landlord (which may not, under
any circumstances be exercised against Sublandlord or in any way affect
Possession Rent), may perform the same and deduct the reasonable cost thereof
from any services rent (or, if the Empire Notes shall no longer be outstanding,
any Rent) due or that may become due and payable under this Lease.
C. Anything to the contrary herein notwithstanding, in the event the
repairs which Landlord is required hereunder to perform are required to correct
a hazardous condition or to end
76
<PAGE>
an emergency which renders the Premises unsuitable, in whole or in part, for the
use contemplated by this Lease, Tenant shall give Landlord immediate notice of
such fact and Landlord shall within twenty-four (24) hours of receipt of said
notice, commence the repairs and diligently proceed with continuity to complete
.said work. If Landlord fails to commence and complete such repairs in a
diligent fashion after said notice, Tenant may (i) perform same and deduct the
cost thereof from any Services Rent, but not any Possession Rent (provided, that
if the Empire Notes shall no longer be outstanding, Tenant may apply said
deductions against any Rent), due or that may become due and payable under this
Lease or (ii) may withhold Services Rent, but not any Possession Rent (provided,
that if the Empire Notes shall no longer be outstanding, Tenant MAY WITHHOLD ANY
Rent), due and owing to Landlord in proportion to the portion of the Premises
rendered unsuitable for its use until Landlord performs such repairs.
Section 6.2 Quiet enjoyment. Landlord covenants that tenant, on paying
---------------
the rent and performing tenant's obligations under this lease, shall peacefully
and quietly have, hold and enjoy the premises and the appurtenances throughout
the term without hindrance, ejection or molestation by any person lawfully
claiming under landlord subject to the other terms and provisions of this lease
and to all mortgages, the ground lease, the condominium documents and underlying
leases of
77
<PAGE>
record to which this Lease may be or become subject and subordinate.
Section 6.3 Landlord's and Sublandlord's Title. Landlord represents
-----------------------------------
that it is the owner and holder of the tenants estate under the Ground Lease,
and that it has full power and authority to enter into the Sandwich Lease with
Sublandlord and this Lease with Tenant. Landlord represents that as of the date
hereof there exists no Event of Default under the Ground Lease or the Sandwich
Lese and that each such Lease is currently in full force and effect.
Sublandlord represents that it is the owner and holder of the tenant's estate
under the Sandwich Lease, and that it has full power and authority to enter into
this Lease with Tenant. Sublandlord represents that as of the date hereof there
exists no event of default under the Sandwich Lease and that the Sandwich Lease
is currently in full force and effect.
Section 6.4 Landlord's Liability.
--------------------
A. In the event of a sale or transfer of all or any part of office
unit 2 or any undivided interest therein, or in the event of the making of a
lease of all or substantially all of office unit 2 (other than the sandwich
lease) or in the event of a sale or transfer of the landlord's or sublandlord's
leasehold estate, the grantor, transferor or lessor, as the
78
<PAGE>
Case may be (subject to the terms and conditions of the sandwich lease), shall
thereafter be entirely relieved of all terms, covenants and obligations
thereafter to be performed by landlord or sublandlord, as the case may be, under
this lease to the extent of the interest or portion so sold, transferred or
leased, provided that (i) the interest: of the grantor, transferor or lessor, as
landlord or sublandlord, as the case may be, in any funds then in the hands of
landlord or sublandlord or the then grantor, transferor or lessor in which
tenant has an interest, shall be turned over, subject to such interest, to the
then grantee, transferee or lessee; (ii) notice of such sale, transfer or lease
shall be delivered to tenant; and (iii) such grantee, transferee or lessee shall
have assumed in a signed writing furnished to tenant all of the obligations of
landlord and sublandlord to tenant under this lease accruing from and after the
date of transfer, it being understood that landlord shall remain obligated to
tenant for any obligations of landlord to tenant accruing up to the date of
transfer and then unpaid or unperformed. In no event shall this lease be
terminated as a result of such sale, transfer or lease.
B. Tenant agrees that it shall look solely to (i) the estate and
property of Landlord in the Office Portion and the Land; (ii) the rents, issues,
profits (other than Possession Rent or Bond Support Payments), and proceeds of
insurance
79
<PAGE>
attributable thereto and (iii) the rights and interests assigned or pledged, or
required to be assigned or pledged, to Tenant pursuant to the Date Certain
Agreement, and the proceeds thereof, for the collection of any judgment (or
other judicial process) requiring the payment of money by Landlord in the event
of any default or breach by Landlord with respect to any of the terms, covenants
and conditions of this Lease to be observed or performed by Landlord; and no
other assets of Landlord or any person having any interest in Landlord shall be
subject to levy, execution or other procedures for the satisfaction of Tenant's
remedies: it being intended that such exculpation from personal liability of
Landlord and any person having an interest in Landlord as set forth in this
subparagraph (B) shall be absolute, unconditional and WITHOUT exception of any
kind.
C. Tenant and landlord hereby acknowledge and agree that neither party
shall have any claim or recourse against sublandlord for any matter whatsoever.
Without limiting the generality of the foregoing, tenant agrees to look solely
to landlord for the provision of any services, the performance of any and all
obligations and the payment of any and all other liabilities of the lessor under
the lease. Tenant further acknowledges and agrees that tenant shall not exercise
any of its remedies under the lease (including, without limitation, any offset
right or right to indemnification) against
80
<PAGE>
Sublandlord or the Possession Rent or the Bond Support Payments, and shall not
name Sublandlord in any action to enforce the obligations of Landlord under this
Lease. Tenant's obligation to pay such Possession Rent and Bond Support Payments
shall be absolute and unconditional under all circumstances. The provisions of
this subsection shall not be deemed to limit the obligation of Sublandlord to
cause the payment of the Possesion Rent and Bond Support Payments received by
Sublandlord to the Bond Trustee to be applied to the payment of the Empire
Notes, Taxes and "Base Rent" under the Ground Lease pursuant to the applicable
provisions hereof.
Section 6.5 Taxes. Assessments. Water Rates. Sewer Rents.
--------------------------------------------
Subject to landlord's right to contest, and tenant's obligation to pay
tenant's tax reimbursement under section 3.3L hereof, sublandlord shall cause
tenant's tax reimbursement to be applied to pay all taxes levied against office
unit 2 or that may be liens thereon. If sublandlord, after a final
non-appealable decision by a court or agency of competent jurisdiction, fails to
cause said taxes to be paid, then tenant, in addition to any and all other
remedies it may have against landlord (which may not, under any circumstances,
be exercised against sublandlord or in any way affect possession rent) may,
after thirty (30) days notice to landlord, and to any mortgagee and any superior
lessor, apply any services rent,
81
<PAGE>
but not any Possession Rent (provided that, upon payment in full of all amounts
outstanding under the Empire Notes, Tenant may apply any Rent), due or that may
become due and payable under this Lease to the payment of said Taxes and so long
as any of such items are unpaid, and provided Tenant pays such Services Rent or
other Rent on account of said Taxes, no action or proceeding may be maintained
by Landlord or Sublandlord against Tenant for nonpayment of Rent If Landlord,
any Mortgagee or superior lessor gives Tenant notice that such party has made
such payment (such notice shall include a receipted bill, if available), then
Tenant's rights under this Section 6.5 shall not apply to the payment in
question.
Section 6.6 Legal Fees. Landlord shall pay on demand Tenant's
-----------
expenses, including reasonable attorneys' fees and disbursements (at rates
comparable to those charged by Landlord's attorneys) incurred by Tenant in
enforcing any obligation of Landlord under this Lease, in curing any default by
landlord under this lease, or in connection with any action or proceeding
brought by or against landlord and arising out of, or pursuant to, this lease,
provided that tenant has obtained a final non-appealable judgment in its favor
(or earlier, if landlord fails to appeal prior to the expiration of the last
date that landlord can appeal as of right).
82
<PAGE>
Section 6.7 Insurance. Landlord shall, at all times while any of the
---------
Empire Notes shall remain outstanding, maintain or cause to be maintained in
effect (i) insurance with respect to the Building against any peril included
within the classification "All Risks of Physical Loss" with extended coverage
("Casualty Insurance") in an amount not less than the actual replacement cost of
the Building (without regard to any depreciation, and exclusive of Tenants
improvements and any excavations, footings and foundations, landscaping and
paving) as reasonably determined by Landlord and/or Sublandlord, and in any
event sufficient to avoid any co-insurance penalty and (ii) "loss of rental
value" insurance ("Loss of Rents Insurance") in a form reviewed and approved by
Tenant and in an amount sufficient to provIde proceeds for a period not less
than two years of loss, and in no event less than the total Rent payable under
this Lease for such period. All insurance required by this Section 6.7 shall be
in such form and shall be issued by such insurance companies as are required
pursuant to Section 7.2(c) of the Ground Lease.
Section 6.8 Funding of Tenant Improvements. Landlord shall cause
-------------------------------
the tenant improvement fund to be fully funded a. And in the manner provided in
sections 2.0, 2.1H and exhibit k hereto, and a failure to do 90 will constitute
a material breach of this lease, provided that tenant acknowledges and agrees
that tenant shall not exercise any rights or remedies
83
<PAGE>
(including without limitation any offset rights) against Sublandlord or
Possession Rent or Bond Support Payments.
Section 6.9 Landlord's Indemnification of Tenant. To the fullest
--------------------------------------
extent permitted by law, Landlord shall indemnify and hold harmless Tenant from
and against any and all claims, actions, judgments, damages, liabilities and
expenses, including, without limitation, reasonable attorneys fees
(collectively, the "Liabilities") as the same may be incurred by Tenant as a
result of Tenant's indemnifying, and holding harmless Sublandlord pursuant to
Sections 7.3 and 7.4 of this Lease to the extent that any such Liabilities are
not in connection with damage to property or injury or death to persons or any
other matters, (A) arising in or about the Premises, the Building or the Land
and occasioned in whole or in part by Tenant's acts or omissions or the acts or
omission of its representatives, servants or employees or (B) arising in the
Premises and occasioned in whole or in part by the acts or omissions of guests
present at the Premises by Tenants license and/or permission, express or
implied.
If tenant shall be made a party to any litigation commenced against
landlord, which is covered by the foregoing indemnification, then landlord shall
protect and hold tenant forever harmless and shall pay all costs and expenses,
including without limitation, reasonable attorneys fees and
84
<PAGE>
disbursements, incurred or paid on behalf of Tenant in connection with such
litigation. It is understood and agreed that Landlord shall have the right. to
designate counsel to defend Tenant, at Landlord's sole cost and expense. The
provisions of this subparagraph shall survive the expiration or other
termination of this Lease.
ARTICLE 7
TENANT'S ADDITIONAL COVENANTS
Section 7.1 Affirmative Covenants. Tenant covenants and agrees, at
---------------------
its own cost and expense, at all times during the term of this Lease:
A. To use the Premises only for executive and general offices and for
no other purposes; in all events, however, consistent with a first-class office
building incorporating a first-class hotel and convention center.
B. To deliver to landlord within thirty (30) days after demand (but
not more often than- once in any lease year) a schedule of subleases affecting
the premises containing the information required under section 10.4(B) of the
ground lease and to otherwise comply with section 10.4(B) of the ground lease.
85
<PAGE>
C. To take good care of the Premises, fixtures, equipment and
improvements therein and all appurtenances serving same and, at tenant's sole
cost and expense, to make all improvements, repairs and replacements, structural
and otherwise as and when needed to preserve in good working order and condition
(a) the improvements in the premises constructed pursuant to landlord's work or
tenant's work plan and (b) base building components within the premises, to the
extent repairs are needed as a result of damage caused by tenant. Subject to the
provisions of section 2.1(F) hereof, and provided the repairs and replacements
hereinafter described are not caused by landlord's negligence or paid for by
landlord's insurance, tenant, at tenant's sole cost and expense, shall also (i)
make all replacements, as and when necessary, to the lamps, tubes, ballasts, and
starters in the lighting fixtures, at any time located in the premises, which
tenant may request landlord to do at tenant's sole cost and expense, (ii)
perform all maintenance and make all repairs and replacements, as and when
necessary, to any air conditioning equipment, plumbing, electrical, heating,
ventilating and/or other mechanical systems in the premises that were installed
by or on behalf of tenant, and (iii) make all repairs relating to landlord's
work and/or tenant's work plan. The provisions of the foregoing sentence shall
not be deemed to give tenant any right to install air conditioning equipment,
mechanical systems or similar equipment except in accordance with the terms and
86
<PAGE>
provisions of this Lease. All repairs and replacements made by or on behalf of
Tenant or any Person claiming through or under Tenant shall be at least equal in
quality to the original work or installation with specifications for any
substitution to be approved by Landlord, such approval not to be unreasonably
withheld or delayed.
D. To comply with all requirements, rules, laws, regulations and orders
(including, without limitation, those relating to Hazardous Materials (as
defined in Section 7.4) and substances and the environment) of Federal, State
and local authorities and of any board of fire underwriters having jurisdiction
over the Premises, the Building or the Land, during the Term hereof or any
renewal term, and to remove all violations which may be placed against the
Premises, the Building or the Land, to the extent such violations are caused by
Tenant or its agents, employees or guests; to make all repairs, alterations,
changes, additions or replacements to the premises, including appurtenances,
equipment, facilities and fixtures therein, arising out of tenant's particular
use or occupancy of the premises or as are necessary to satisfy any governmental
requirements as relate to tenant's particular use; to keep the premises equipped
with all safety appliances so required because of such use or occupancy, and
otherwise to comply with any governmental requirements. In any case where tenant
is required to make repairs or perform any work pursuant
87
<PAGE>
to subparagraphs C and D hereof, Tenant may, at its option, request that
Landlord make such repairs or perform such work for and on behalf of Tenant, but
at Tenant's sole cost and expense. In such event, Tenant shall reimburse
Landlord as additional rent for the cost of such repairs and/or work within
thirty (30) days after Landlord shall furnish a statement to Tenant of the
amount thereof.
E. To keep the Premises, the Office Portion, the Building and the Land
at all times, free of liens for labor and materials contracted for, or arising
from work performed on behalf of, Tenant; to procure all Governmental Approvals
before undertaking any work in or with respect to the Premises; to do all such
work in a good and workmanlike manner, employing materials of good quality; to
perform such work in such manner as to insure proper maintenance of good and
harmonious labor relationships with other contractors employed by Landlord at
the Building; and to comply with any Governmental Requirements relating thereto.
F. To the fullest extent permitted by law, landlord and tenant shall
each indemnify and hold the other harmless from and against any and all claims,
actions, judgments, damages, liabilities and expenses, including, without
limitation, reasonable attorneys' fees and disbursements, in connection with
damage to property or injury or death to persons, or any
88
<PAGE>
other matters, arising on or about the Premises, the Building or the Land
occasioned in whole or in part by such indemnitor's acts or omissions or the
acts or omissions of its representatives, servants, employees and guests present
by its license and/or permission, expess or implied, except that neither
indemnitee shall be so indemnified and saved harmless to the extent the
liabilities, etc. are caused by the negligent or other tortious acts or
omissions of such indemnitee. If Landlord or Tenant, respectively, shall be made
a party to any litigation commenced against the other and covered by the
foregoing indemnity, then the indemnitor shall protect and hold the indemnitee
forever harmless and shall pay all costs and expenses, including, without
limitation, reasonable attorneys' fees and disbursements, incurred or paid on
behalf of the indemnitee in connection with such litigation. It is understood
and agreed that the indemnitor shall have the right to designate counsel to
defend the indemnitee at indemnitor's sole cost and expense. The provisions of
this subparagraph shall survive the expiration or other termination of this
lease.
Tenant shall, at its sole cost and expense, carry and maintain
insurance in force throughout the term as follows:
(I) the tenant improvements shall be insured against "all risks" of
physical damage in an amount
89
<PAGE>
which at the time such insurance is placed is not less than the reasonable
estimated "full replacement cost" of such Tenant improvements. "Full
replacement cost" is defined as the cost of replacing such Tenant improvements
without deduction for physical depreciation thereof; and
(ii) comprehensive public liability, insurance on an "occurrence
basis" against all claims for bodily injury, death, property damage, including
personal injury aid contractual liability for claims occurring on, in or about
the Premises in an amount not less than $5,000,000 per occurrence and $5,000,000
aggregate for any policy year (subject to Landlord's right to demand increased
policy limits in Landlord's reasonable discretion) naming Landlord and Tenant
as the insureds and naming the lessors under any ground or underlying leases,
Ground Lessor, Sublandlord, the Board of Managers and all Mortgagees as
additional insureds.
(iii) during the performance of tenant's work plan, tenant shall cause
its general contractor or construction manager and all "uncontractors to
maintain worker's compensation and employers liability insurance to the extent
required by applicable governmental requirements. The general contractor engaged
by tenant shall provide and require that its subcontractors of any tier carry
comprehensive public liability insurance (included completed operations) at
least to
90
<PAGE>
the extent described in clause (ii) above.
All insurance required to be maintained by tenant shall be carried with a
company or companies reasonably acceptable to landlord, rated "A-10" or better
by best insurance guide and licensed to do business in the state of New York and
shall be written for terms of not less than one year. Tenant shall furnish
landlord (and any other parties required to be designated as additional
insureds under all insurance policies required to be maintained by tenant) with
certificates evidencing: (a) the maintenance of insurance as aforesaid; (b) the
payment of the premiums therefor; and (c) the renewals thereof at least sixty
(60) days prior to the expiration of any such policy. Such policy or policies
shall also provide that it or they shall not be cancelled or altered without
giving landlord, sublandlord and any mortgagee at least sixty (60) days prior
written notice thereof which shall be sent to landlord by certified mail at the
address to which notices are required to be sent to landlord or sublandlord
hereunder or to such mortgagee under the applicable mortgage. In the event of
tenant's default in obtaining or delivering any such policy, policies or
certificates or tenant's failure to pay the premiums there for, landlord may
(but shall not be obligated to) secure or pay the premium for any such policy or
policies and charge tenant, as additional rent, for the cost of such premiums,
plus interest at the late rate.
91
<PAGE>
G. To pay on demand any increase in premiums that may be charged on
insurance carried by or on behalf of Landlord resulting from Tenant's particular
use or occupancy of the Premises, whether or not Landlord has consented to the
same. If, due to Tenant's (i) occupancy, or (ii) abandonment, or (iii) failure
to occupy the Premises as herein provided, any such insurance shall be cancelled
by the insurance carrier, then, in any of such events, Tenant shall indemnify
and hold Landlord Sublandlord, the Board of Managers and any Mortgagee harmless
against any loss which would have been covered by such insurance. If Landlord
receives notice of any of the foregoing events from its insurance carrier,
Landlord shall so notify Tenant and, to the extent permitted by such carrier,
Tenant may attempt to correct such condition(s). Tenant shall also pay any
increase in premiums on such insurance as may be carried by or on behalf of
Landlord for its protection against loss through fire or other casualty, if such
increase shall result from any of the foregoing events.
H. None of landlord, sublandlord nor their agents and employees shall
be liable for, and tenant acknowledges that it shall have no right to terminate
the lease as a result of and waives all claims for, loss or damage to tenant's
business or damage to persons or property sustained by tenant resulting from any
accident or occurrence in or upon the premises or the building, including, but
not limited to, claims for damage
92
<PAGE>
resulting from: (i) any equipment or appurtenances becoming out of repair; (ii)
injury done or occasioned by wind; (iii) any defect in or failure of plumbing,
heating or air conditioning or ventilation equipment, electric wiring or
installation thereof, gas, water, steam or other pipes, stairs, porches,
railings or walks; (iv) broken glass; (v) the backing up of any pipe or
downspout; (vi) the bursting, leaking or running of any tank, tub, washstand,
water closet, waste pipe, drain or any other pipe or tank in, upon or about the
building or the premises; (vii) the escape of steam or hot water; (viii) water,
snow or ice being upon or coming through the roof, skylight, trapdoor, stairs,
doorways, show windows, walks or any other place upon or near the building or
the premises or otherwise; (ix) the falling of any fixture, plaster, concrete,
glass, metal, tile or stucco; (x) any act, omission or negligence of other
tenants, licensees or of any other persons or occupants of the building; and
(xi) the presence of hazardous substances or materials in, on, under, around or
about the land or the building, whether now existing or hereafter discovered or
occurring. Nothing herein is intended to reduce or eliminate landlord's
obligation to use due care in the management of the land, the building and the
premises and to that extent landlord shall remain liable, and tenant shall
retain its right to proceed against landlord as a result of any damage or injury
arising from landlord's negligence. The provisions of this subparagraph shall
survive the expiration or other termination
93
<PAGE>
of this Lease.
I. To permit Landlord, Sublandlord, each Mortgagee and their agents,
as appropriate, to have access in and about the Premises including, without
limitation, the right (i) to enter the Premises at all times to examine the
Premises or for any of the purposes set forth in this paragraph or for the
purpose of performing any obligation of Landlord under this Lease or exercising
any right or remedy reserved to Landlord in this Lease, and if Tenant shall not
be present or shall not open and permit any entry into the Premises at any time
when such entry shall be necessary or permissible, to use a master key or, in
the event of emergency, to forcibly enter the Premises; (ii) with notice, to
erect, install, use and maintain pipes, ducts and conduits in and through the
Premises, provided such work will not materially reduce the useable space of the
Premises or materially and adversely affect Tenant's access to or use of the
Premises; (iii) in connection with a sale or refinancing of the Office Portion
or the premises, and/or during the final twelve (12) months of the term, upon
reasonable notice, to exhibit the premises to others; (iv) to make necessary
repairs, alterations, improvements or additions, or to perform such maintenance,
including, but not limited to, the maintenance of all base building heating,
ventilation, airconditioning, elevator, plumbing, electrical and other
mechanical facilities, provided such work will not materially reduce the useable
space
94
<PAGE>
of the premises or materially and adversely affect tenant's access to or use of
the premises; (v) to take all materials into and upon the premises that may be
required in connection with any such repairs, alterations, improvements,
additions or maintenance, provided such materials will not materially reduce the
useable space of the premises or materially and adversely affect tenant's access
to or use of the premises; and (vi) to alter, renovate and decorate the premises
at any time during the term of this lease of tenant shall have removed all or
substantially all of tenant's property from the premises. Upon notice to tenant,
landlord and/or sublandlord shall have the right, from time to time, to change
the name, number or designation by which the building and/or office portion are
commonly known. Subject to the provisions of article 2 and article 4, landlord
and/or sublandlord also reserves the right at any time to change the arrangement
or location of entrances, passageways, doors, doorways, corridors, elevators,
stairs, toilets and -other public parts of the building and/or common areas,
provided any such change does not materially and adversely obstruct tenant's
access to or operations in connection with the premises. Landlord, sublandlord
and either such party's agents shall have the right to permit access to the
premises, whether or not tenant shall be present, to any receiver, trustee,
assignee for the benefit of creditors, sheriff, marshal or court officer
entitled to, or reasonably purporting to be entitled to, such access for the
purpose of
95
<PAGE>
taking possession of, or removing, any property of tenant or any other occupant
of the premises, or for any other lawful purpose, or by any representative of
any governmental authority. Neither anything contained in, nor any action taken
by landlord or sublandlord under, this subparagraph (i) shall be deemed to
constitute recognition by landlord or sublandlord that any Person; other than
tenant has any right to an interest in this lease or the premises. The
reasonable exercise by landlord or sublandlord or either such party's agents of
any right reserved to landlord or sublandlord in this subparagraph shall not
constitute an actual or constructive eviction, in whole or in part, or entitle
tenant to any abatement or diminution of rent, or relieve tenant from -any of
its obligations under this lease or impose any liability upon landlord,
sublandlord or either such party's agents, or upon any lessor under any ground
or underlying lease (including, without limitation, the ground lease) by reason
of inconvenience or annoyance to tenant, or injury to or interruption of
tenant's business, or otherwise.
J. To pay on demand landlord's and/or sublandlord's expenses,
including reasonable attorneys' fees and disbursements, incurred in enforcing
any obligation of tenant under this lease; in curing any default by tenant under
this lease; or in connection with any action or proceeding brought by or against
tenant and arising out of, or pursuant to, this
96
<PAGE>
Lease, provided that Landlord or Sublandlord, as the case may be, has obtained a
final non-appealable judgment in its favor (or earlier, if Tenant fails to
appeal prior to the expiration of the last date that Tenant can appeal as of
right). The provisions of this subparagraph shall survive the expiration or
other termination of this Lease.
K. Within thirty (30) days of the filing thereof, to cause to be
discharged of record by payment, bonding or otherwise, any mechanic's lien at
any time filed against the premises or the building for any work, labor,
services or materials claimed to have been performed at, or furnished to the
premises, for or on behalf of tenant, or anyone holding the premises through or
under tenant, other than for tenant's work performed by landlord or for which
landlord is required to compensate tenant's contractors pursuant to article 2
hereinabove. Nothing in this lease contained shall be construed as a consent on
the part of landlord or sublandlord to subject such party's estate in the
premises to any lien or liability under applicable law. The provisions of this
subparagraph shall survive the expiration or other termination of this lease.
L. Upon the expiration or other termination of the Term, to quit and
surrender the Premises to Sublandlord in "as is" condition, broom clean, in good
order and condition except for
97
<PAGE>
damage by fire or by other casualty which is not the result of Tenant's
negligence, or by condemnation, and at Tenant's expense to remove all personal
property of Tenant. Tenant may, but shall not be required to, (i) remove any
alteration, addition or improvement made by Tenant with or without Landlord's or
Sublandlord's consent, but in the event of removal, Tenant shall repair any
damages to the Premises caused by such removal; and/or (ii) restore the Premises
to the condition in which they were prior to the installation of the articles so
removed. Except as expressly provided above, neither Tenant, nor any other
person occupying the Premises, or parts thereof, shall be required to restore or
repair the same at the expiration or sooner termination of the term. Any
property, improvements or installations which are not so removed shall be deemed
to have been abandoned by Tenant and may be retained or disposed of by
Sublandlord, as Sublandlord shall desire.
M. In the event tenant remains in possession of the premises after the
expiration or earlier termination of the term of this lease and without the
execution and delivery of a new lease by both parties, tenant, at the option of
sublandlord, shall be deemed to be occupying the premises as a tenant from month
to month, at a monthly rental equal to the greater of (i) 100% of the market
value base rent of the premises as determined in accordance with section l0.1(C)
98
<PAGE>
hereof, or (ii) a sum equal to the monthly installment of Base Annual Rent
payable during the 1ast month of the Term Pleas, in either event: (w) the
monthly payment Reimbursement payable pursuant to Section 3.3(B) for the last
year of the Term, (x) the monthly payment of Tenant's Operating Expense Payment
payable pursuant to Section 3.3(C), (y) the monthly cleaning cost charges
payable pursuant to Section 5.8 hereof for the last year of the Term; and (z)
the monthly parking charge payable by Tenant pursuant to Section 5.10 hereof for
the last year of the Term, subject to all the other terms and conditions of this
Lease. In no event shall any provision hereof be construed as permitting Tenant
to hold over in possession of the Premises after expiration or earlier
termination of the term of this Lease. Tenants obligations under this
subparagraph (M) shall survive the expiration or other termination of this
Lease.
N. To comply with the rules and regulations, provided same are
non-discriminatory.
O. To comply with the provisions of the ground lease as and to the
extent the same shall be applicable to tenants of the ground lessee.
P. Tenant shall in all events promptly cooperate with the reasonable
requests of landlord, sublandlord and each
99
<PAGE>
party's Institutional Lender(s) obtaining of financing.
Q. That at all times the Possession Rent, and/or Bond Support
Payments, as the case may be, shall be sufficient to pay the principal and
interest on the Empire Notes, pilot and base rent under the Ground Lease as the
same shall become due and payable.
Section 7.2 Negative Covenants. Tenant covenants and agrees that at
-------------------
all times during the Term Tenant shall not:
A. Use or occupy, or permit the use or occupancy of the Premises or
any part thereof, for any purpose other than as permitted in Section 7.1(A)
hereof.
B. Injure, overload, deface or otherwise harm the Premises or any part
thereof or any equipment or installation therein.
C. Make or permit the making or performance of, any alterations,
subdivisions, installations, improvements, additions or other physical changes
in or about the Premises (referred to collectively in this subparagraph as
"alterations"), except as herein provided. All alterations shall be made and
performed at Tenant's sole cost and expense and in accordance with Rules and
Regulations that Landlord may adopt from time to time; no alterations shall
affect any part of the Building other than the Premises or adversely affect any
service required to be furnished by Landlord to Tenant or to any other tenant or
occupant of the Building or impair the
100
<PAGE>
value of the Building; no alteration shall affect the outside appearance of the
building or the color or style of any window covering; all business machines and
mechanical equipment shall be placed and maintained by Tenant in settings
sufficient, in Landlord's reasonable judgment, to absorb and prevent vibration,
noise and annoyance to other tenants or occupants of the Building. Tenant may
install partitions and fixtures in, and make nonstructural alterations to the
Premises, without Landlord's consent ("Privileged Alterations") provided that
the same do not adversely affect the proper functioning of the Building Systems
(hereinafter defined). Privileged Alterations shall include without limitation
all non-structural alterations with an estimated cost of $100,000 or less per
floor. Not later than fourteen (14) days prior to commencing any Privileged
Alterations, Tenant shall submit plans and specifications or a schematic
drawing, diagram or sketch in sufficient detail (a) to identify the work being
performed by Tenant, and to enable Landlord to determine that such work is a
privileged alteration and (b) to enable landlord to amend the building plans, if
required, at tenant's sole cost to reflect such privileged alterations. if
Landlord shall give notice to Tenant that Landlord, exercising its reasonable
judgment, deems the work to be performed by tenant not to be a privileged
Alteration, then such work shall be treated as a Non-Privileged Alteration
(hereinafter defined). As defined in this Lease, the term "Building Systems"
shall mean all operating systems,
101
<PAGE>
including, but not limited to, machinery, engines, dynamos, boilers, elevators,
air conditioning machinery, ducts, units and equipment, heating, ventilating and
hot water systems, pipes, plumbing, wiring, gas, steam, water and electrical
fittings attached to or used in connection with the Building.
If Tenant desires to perform alterations to the Premises other
than privileged alterations ("non-privileged alterations"), then tenant shall
obtain landlord's written consent, which consent shall not be unreasonably
withheld or delayed, prior to commencing such alterations. Tenant shall submit
detailed plans and specifications therefor to landlord for landlord's approval
as to compliance with the provisions of this subparagraph (c) not later than
fourteen (14) days prior to the anticipated commencement of such alteration. If
landlord does not grant its consent to any non-privileged alteration, which
consent shall not be unreasonably withheld or delayed, or to the plans and
specifications therefor, landlord shall specify with reasonable detail its
reasons for failing to grant such consent. In no event shall landlord be
required to consent to any non-privileged alteration which would adversely
affect any part of the building outside of the premises or would in landlord's
reasonable judgment adversely affect the proper functioning of any of the
building system-. If any dispute shall arise between landlord and tenant in
connection with this subparagraph (c), such dispute shall be submitted to
102
<PAGE>
arbitration pursuant to Section 15.2 hereof. Prior to the commencement of each
proposed alteration, Tenant or its contractors shall furnish to Landlord: (i)
duplicate original policies evidencing worker is compensation insurance covering
all persons to be employed in connection with such alteration, including those
to be employed by all contractors and subcontractors, and of comprehensive
public liability insurance (including property damage coverage) in which
Landlord, its agents and any lessor under any ground or underlying lease
(including, without limitation, the Ground Lessor), Sublandlord and the Board of
Managers shall be named as parties insured, which policies shall be issued by
companies, and shall be in form and amounts reasonably satisfactory to Landlord
and shall be maintained by Tenant until the completion of such alterations; and
(ii) all permits, approvals and certificates required by all Governmental
Authorities. Notwithstanding landlord's approval of plans and specifications for
any alteration: alterations shall be made and performed in full compliance with
all governmental requirements; alterations shall be made and performed in
accordance with the rules and regulations; all materials and equipment to be
incorporated into the premises as a result of all alterations shall be new or of
first quality; and, no such materials or equipment shall be subject to any lien,
encumbrance, chattel mortgage or title retention or security agreement.
103
<PAGE>
D. Remove rubbish or garbage, perform window cleaning, janitorial or
maintenance services in or about the Premises, except in each such case, if any,
by a Person, reasonably approved by Landlord.
E. Take or permit any action which would violate Landlord's union
contract, if any, affecting the Building nor create any foreseeable work
stoppage, picketing, labor disruption or dispute, or any interference with the
business of the Landlord or any other tenant or occupant in the Building or of
the rights and privileges of any person(s) lawfully in the Building.
F. Use any of the Common Areas located outside the Premises except in
accordance with the Rules and Regulations. No awnings or other projections shall
be attached to the outside walls or windows of the Building. No curtains,
blinds, shades, or screens shall be attached to or hung in, or used in
connection with, any window or door except as otherwise permitted by landlord in
conformity with the window treatments for the office portion, as determined by
landlord pursuant to the preliminary plans and specifications and/or rules and
regulations. No showcases or other articles shall be put in front of or affixed
to any part of the exterior of the building, nor placed in the common areas. The
water and wash closets and other plumbing fixtures shall not be used for any
104
<PAGE>
Purposes other than those for which they are constructed, and no sweepings,
rubbish, rags or other substances shall be thrown therein. Tenant shall not
bring or keep or permit to be brought or kept, any hazardous, toxic,
inflammable, combustible or explosive fluid, material, chemical or substance in
or about he premises, except in compliance with hazardous materials Laws and
other applicable laws. The premises shall not be used for any illegal purpose or
in contravention of governmental regulations. Tenant shall not cause or permit
any unusual or objectionable odor to emanate from the premises nor shall tenant
cause or permit any cooking in or about the premises except (i) by means of
microwave oven or (ii) within the area to be designated as tenant's cafeteria
space. Tenant shall not make, or permit to be made, noises which disturb or
interfere with other tenants or occupants of the building or neighboring
buildings or premises whether by the use of any musical instrument, radio,
television set or other audio or visual device, unmusical noise, or in any other
way. Nothing shall be thrown out of any doors or window-. Tenant shall, upon the
termination or expiration of its tenancy, restore to landlord all keys of
offices and toilet rooms, either furnished to, or otherwise procured by tenant.
All removals from the building, or the carrying in or out of the building or the
premise. Of any freight, furniture or bulky matter of any description must take
place at such time and in such manner as landlord or its agents may determine,
from time to time and in accordance with
105
<PAGE>
the rules and regulations. Subject to tenant's reasonable security requirements,
landlord reserves the right to inspect all freight to be brought into the
building and to exclude from the building all freight which violates any of the
rules and regulations. Landlord shall not have the right to prohibit any
advertising by tenant or any occupant of the premises, which advertising relate
to the premises, the office portion or the building except that which, in
landlord's reasonable opinion, tends to impair the reputation of landlord, the
premises, the office portion and/or the building, and upon notice from
landlord, tenant or such occupant shall refrain from or discontinue such
advertising. Landlord reserves the right to exclude from the building, during
other than standard building hours and days, all persons who do not present a
duly authorized pass to the building. Tenant shall be responsible for all
persons for whom it requests such passes and shall be liable to landlord for all
acts of such persons. Tenant, before closing and leaving the premises shall see
that all entrance doors are locked and all windows closed. Tenant shall not
clean any window of the building from the outside.
G. Subject to the provisions of section 7.1(A), cause, allow, suffer
or permit any activity in the premises or any equipment or installations therein
(whether or not expressly permitted to be installed therein by any of the
provisions of this lease) to unreasonably interfere with the comfort and
106
<PAGE>
enjoyment of the Building by Landlord and other tenants or occupants thereof
(such interference being herein referred to as a "Nuisance"), with Tenant being
fully cognizant of the existence of a first class hotel within the Building. Use
or allow the Premises to be used or occupied for any unlawful purposes or in
violation of any certificate of occupancy or certificate of compliance covering
or affecting the use of the Premises.
If a nuisance shall occur, Landlord shall give notice thereof to
tenant and tenant shall thereupon immediately take such action as shall be
necessary to prevent the further occurrence of the activities or conduct causing
the same. If such actions shall fail to cure and/or correct the nuisance within
five (5) business days after the giving of such notice by landlord, tenant shall
either immediately and permanently cease the activity or temporarily cease such
activity or conduct and forthwith take such remedial actions (as, for example,
relocating equipment within the premises, installing sound-proofing and/or noise
resistant materials and/or building sound studios), to the reasonable
satisfaction of landlord so that landlord and other tenants shall not be
affected by the activity, conduct or equipment creating the nuisance. At such
time as landlord is reasonably satisfied that the nuisance has been abated
and/or been rectified, tenant shall be permitted to resume such activities (and
only then if such activities are
107
<PAGE>
otherwise permitted hereby). Tenant's failure to comply with the foregoing
requirements shall constitute a material breach of this Lease.
H. Pay any sums of Rent for more than one (1) month in advance.
I. Do anything or cause any action to be taken that would constitute
a breach of Section 41.16 of the Ground Lease.
J. Claim any New York State or New York City sales tax exemption
solely by virtue of the ownership of the Building by the City of New York except
as provided in that certain Project Agreement and that certain Lease Agreement,
both of even date herewith, by and between New York City Industrial Development
Agency and Empire Insurance Group.
Section 7.3 Indemnification of Sublandlord.
------------------------------
(a) to the fullest extent permitted by law, and subject to the
exclusions set forth in section 7.3(C), landlord, for itself and its successors
and assigns, covenants and agrees that it shall be liable for and shall pay, and
shall indemnify, hold harmless and defend sublandlord, the board of managers,
the agency and -any mortgagee, and their respective shareholders, members,
directors, officers, employees, and
108
<PAGE>
agents (each, an "indemnitee" and, collectively, the "indemnitees"), from and
----------
against any and all claims, actions, judgments, damages, liabilities,
obligations, losses, demands, penalties, fines, settlements and expenses
(including, without limitation, reasonable legal fees and expenses and costs of
investigation. Remediation or other response action) of every kind and nature
and however caused, whether known or unknown, contingent or otherwise (each, a
"claim" and collectively, the "claims") arising from or in connection with or in
-----
any way relating to (i) the occurrence or existence of this lease or the
performance or non-performance or enforcement or violation of any of the terms
hereof by landlord, the tenant or any other person; (ii) the manufacture, design
construction, purchase, ownership, delivery, lease, sublease, possession, use,
operation, management, maintenance, condition, or repair of the premises, the
building or the land (or any portion thereof); (iii) any accident, injury to or
death of persons or loss of property occurring in, on or about the premises, the
building or the land, or any part thereof, or the adjoining sidewalks, curbs,
vaults and vault space, if any, streets or ways; (iv) performance of any labor
or services or the furnishing of any materials or other property in respect of
the premises, the building or the land, or any part thereof; or (v) any act or
omission of landlord and/or tenant or any of its and/or their servants, agents,
contractors, employees, licensees or invitees.
109
<PAGE>
(b) To the fullest extent permitted by law, and subject to the
exclusions set forth in section 7.3(C), tenant, for itself and its successors
and assigns, covenants and agrees that it shall be liable for and shall pay, and
shall indemnify, hold harmless and defend sublandlord, the board of managers,
the agency and any mortgagee, and their respective shareholders, members,
directors. Officers, employees, and agents (each, an "indemnitee" and,
collectively, the "indemnitees"), from and against any and all claims, actions,
judgments, damages, liabilities, obligations, losses, demands, penalties, fines,
settlements and expenses (including, without limitation, reasonable legal fees
and expenses and costs of investigation, remediation or other response action)
of every kind and nature and however caused, whether known or unknown,
contingent or otherwise (each, a "claim" and collectively, the "claims") arising
from or in connection with or in any way relating to (i) the occurrence or
existence of this lease or the performance or non-performance or enforcement or
violation of any of the terms hereof by landlord, the tenant or any other
person; (ii) the manufacture, design construction, purchase, ownership,
delivery, lease, sublease, possession, use, operation, management, maintenance,
condition, or repair of the premises, the building or the land (or any portion
thereof); (iii) any accident, injury to or death of persons or loss of property
occurring in, on or about the premises, the building or the land, or any part
thereof, or the adjoining sidewalks,
110
<PAGE>
curbs, vaults and vault space, if any, streets or ways; (iv) performance of any
labor or services or the furnishing of any materials or other property in
respect of the Premises, the Building or the Land, or any part thereof; or (v)
any act or omission of Landlord and/or Tenant or any of its and/or their
servants, agents, contractors, employees, licensees or invitees.
(c) Subject to the following sentence, the indemnifications provided
for in Section 7.3(a) shall be terminated and be of no further force or effect
from and after the date upon which all of the Empire Notes shall have been paid
in full (the "Indemnity Termination Date"). Notwithstanding the occurrence of
the Indemnity Termination Date, the indemnification obligation set forth in
Section 7.3(a) shall not terminate as to (x) any Claim asserted against, imposed
upon or suffered by an Indemnitee prior to the Indemnity Termination Date or (y)
any matter which as of the indemnity termination date is the subject of a
dispute, claim or litigation, whether or not then asserted against an
indemnitee.
(d) Notwithstanding the provisions of SECTION 7.3(a), with respect to
a Claim, Landlord and Tenant shall not be liable for, nor shall either be
obligated to, pay or indemnify, hold harmless or defend an Indemnitee from and
against such
111
<PAGE>
Claim to (and only to) the extent such Claim, (x) results from the willful
misconduct or gross negligence of such Indemnitee, or any agent or employee of
such Indemnitee or (y) results from the breach by Sublandlord of, or failure of
Sublandlord to comply with, its representations, warranties, obligations or the
provisions of its organizational documents. Notwithstanding the foregoing, the
negligence, including gross negligence or willful misconduct, of one Indemnitee
shall not abrogate the indemnities set forth in this Section with respect to any
other non-negligent Indemnitee.
(e) The indemnities set forth in this Section 7.3 are independent,
direct and unconditional obligations of Landlord and Tenant to each Indemnitee
and the Indemnitees, as applicable, and are not dependent upon the enforcement
of, or enforceability of, the indemnification by Landlord of Tenant under
Section 6.9 and/or the indemnifications of Landlord and Tenant to each other
hereunder or under any other provision of this Lease. Nothing in this Section
7.3 shall abrogate, vitiate or otherwise affect the indemnities between landlord
and tenant set forth in sections 6.9 And 7.1F of this lease, all of which
remain in full force and effect upon the terms thereof.
(f) The provisions of this Section 7.3 shall survive the expiration or
termination of this Lease.
112
<PAGE>
Section 7.4 Environmental Indemnity.
-----------------------
(a) Landlord, for itse2f, its successors and assigns, covenants and
agrees that it shall be liable for and shall pay, indemnify, defend and hold
harmless Tenant, Sublandlord, the Agency and any Mortgagee and their respective
shareholders, members, directors, officers, employees and agents, from and
against any Claims (including, without limitation, reasonable engineer and
consultant fees, investigation and laboratory fees) of whatever kind or nature,
known or unknown, contingent or otherwise, with respect to the Land, Building
and/or Premises, or portions thereof, arising out of, or in any way related to,
(w) the presence, use, handling, management, storage, transportation, disposal,
release, or threatened release of any Hazardous Materials (as hereinafter
defined) on, in, from, under, at, or in connection with the Land, Building
and/or Premises or any portion thereof; (x) any personal in3ury (including
wrongful death) or property damage (real or personal) arising out of or related
to such Hazardous Materials or Environmental Laws (as hereinafter defined); (y)
any lawsuit brought or threatened, settlement reached, or government order or
investigation relating to such Hazardous Materials, and/or (z) any violation of,
or liability under, any environmenta1 law. The provisions of this paragraph
shall be in addition to any and all other obligations and liabilities Landlord
may have to any Indemnitee at common law, and shall survive the
113
<PAGE>
termination of this Lease.
(b) Tenant, for itself, its successors and assigns, covenants and
agrees that it shall be liable for and shall pay, indemnify, defend and hold
harmless Sublandlord, the Agency and any Mortgagee and their respective
shareholders, members, directors, officers, employees and agents, from and
against any Claims (including, without limitation, reasonable engineer and
consultant fees, investigation and laboratory fees) of whatever kind or nature,
known or unknown, contingent or otterwise, with respect to the Land, Building
and/or Premises, or portions thereof, arising out of, or in any way related to,
(w) the presence, use, handling, management, storage, transportation, disposal,
release, or threatened release of any Hazardous Materials (as hereinafter
defined) on, in, from, under, at, or in connection with the Land, Building
and/or Premises or any portion thereof; (x) any personal injury (including
wrongful death) or property damage (real or personal) arising out of or related
to such Hazardous MAterials or environmental laws (as hereinafter defined); (y)
any lawsuit brought or threatened, settlement reached, or government order or
investigation relating to such hazardous materials, and/or (z) any violation of,
or liability under, any Environmental Law. The provision of this paragraph
shall be in addition to any and all other obligations and liabilities Tenant may
have to any Indemnitee at common law, and shall survive the termination of this
Lease.
114
<PAGE>
(c) The indemnities set forth in this Section 7.4 are independent,
direct and unconditional obligations of Landlord and Tenant to each Indemnitee
and the Indemnitees, and are not dependent upon the enforcement of, or
enforceability of, the indemnification by Landlord of Tenant under Section 6.9
and/or "he indemnifications of Landlord and Tenant to each other set forth.
herein or elsewhere in this Lease, or between Ground Lessee and Ground Lessor
under Section 20.2 of the Ground Lease. Nothing in this Section 7.4 shall
abrogate, vitiate or otherwise affect the mutual indemnities between Ground
Lessee and Ground Lessor set forth in Section 20.2 of the Ground Lease, all of
which remain in full force and effect upon the terms thereof.
(d) As used herein, the term "Hazardous Materials" shall mean any and
all pollutants, contaminants, wastes, chemicals or toxic, radioactive,
ignitable, corrosive, reactive or otherwise hazardous substances, wastes and
materials regulated by environmental laws, including, without limitation, any
flammable explosives, radioactive materials, hazardous materials, hazardous
wastes, hazardous or toxic substances, or related material defined in the
comprehensive environmenta1 response, compensation, and liability act of 1980,
as amended (42 U.S.C. Sections 6901, et seq.), And in the regulations adopted
and publications promulgated pursuant thereto. The term "environmental laws"
shall mean any and all federal, state
ll5
<PAGE>
or local law, regulation, judicial decision, rule, order, decree, injunction,
permit or governmental restriction, whether now or hereafter in effect, relating
to the environment, the effect of the environment on human health or pollutants,
wastes, contaminants or hazardous substances or materials.
(d) The provisions of this Section 7.4 shall survive the expiration or
termination of this Lease.
ARTICLE 8
DESTRUCTION, CONDEMNATION
Section 8.1 Destruction. Fire and Other Casualty.
------------------------------------
A. If the Premises or any part thereof shall be damaged by fire or
other casualty, Tenant shall give immediate notice thereof to Landlord and this
Lease shall continue in full force and effect except as hereinafter set forth.
B. If the premises are partially damaged and rendered partially
unusable by fire or other casualty, the damages thereto including landlord's
work (but not to the property, equipment or improvements belonging to or made by
or on behalf of tenant located therein or forming a part thereof) shall be
repaired by and at the expense of landlord and the rent, until the earlier of
(x) ninety (90) days after the substantial
116
<PAGE>
Completion of the repair of the base building components within the premises, or
(y) the date tenant takes occupancy of the damaged portion of the premises for
the conduct of its business, shall be abated and apportioned (according to the
part of the premises which is usable), subject to and in accordance with the
following sentence, from the date of the casualty. While any of the empire notes
shall remain outstanding, notwithstanding the occurrence of such a casualty,
neither possession rent nor bond support payments, as applicable, shall abate
and tenant shall continue to pay the entire possession rent and/or bond support
payments as the same become due and payable hereunder. Landlord and sublandlord
each hereby irrevocably assigns and sets over to tenant, to the extent of any
payments of the possession rent and/or bond support payments made by tenant in
respect of the portion of the premises rendered unusable during the period same
shall be unusable (such payments, the "compensable Post-Casualty payments"),
landlord's and sublandlord's right to receive the proceeds of loss of rents
insurance. Landlord and sublandlord each hereby appoints tenant as such party's
attorney-in-fact, coupled with an interest, to execute any and all documents and
instruments necessary or desirable to collect such proceeds. If the proceeds of
loss of rents insurance shall, in the aggregate, be less than the compensable
post-casualty payments, then tenant may offset any such deficiency against the
services rent (but not, while any of the empire notes shall remain
117
<PAGE>
outstanding, the Possession Rent) and if the aggregate Services Rent shall be
insufficient to satisfy such deficiency, the same shall otherwise be reimbursed
by Landlord.
C. If the Premises are damaged and rendered wholly unusable by fire or
other casualty, then (i) except as otherwise expressly permitted under Section
8.lD, Landlord shall repair and restore the Premises as required by the Ground
Lease and (ii) the Rent shall be proportionately paid up to the time of the
casualty and thenceforth shall cease, subject to the provisions of the following
sentence, until the earlier of (x) ninety (90) days after the substantial
completion of the Base Building components within the Premises, or '(y) the date
Tenant takes occupancy of the damaged portion of the Premises for the conduct of
its business. While any of the Empire Notes shall remain outstanding,
notwithstanding the occurrence of such a casualty, neither Possession Rent nor
Bond support payments, as applicable, shall abate and tenant shall continue to
pay the entire possession rent and/or bond support payments as the same become
due and payable hereunder. Landlord and sublandlord each hereby irrevocably
assigns and sets over to tenant, to the extent of any compensable post-casualty
payments, landlord's and sublandlord's right to receive the proceeds of loss of
rents insurance. Landlord and sublandlord each hereby appoints tenant as such
partys attorney-in-fact, coupled with an interest, to execute any and all
documents and
118
<PAGE>
instruments necessary or desirable to collect such proceeds. If the proceeds of
Loss of Rents Insurance shall, in the aggregate, be less than the Compensable
Post-Casualty Payments, then Tenant may offset any such deficiency against the
aggregate Services Rent, and if the aggregate Services Rent shall be
insufficient. to satisfy such deficiency, the same shall otherwise be reimbursed
by Landlord. In no event may Tenant offset such deficiency against the
Possession Rent or otherwise claim such deficiency against Sublandlord.
D. If the Premises are rendered wholly unusable (whether or not the
Premises are damaged in whole or in part) or if the Building, the Garage
Portion, the Hotel Portion, or the Office Portion shall be so damaged that
Landlord and/or Sublandlord shall decide to demolish all of them or to rebuild
them (and provided the Ground Lease shall so permit), then, in any of such
events, Sublandlord may elect to terminate this Lease by written notice to
Tenant, provided that all outstanding obligations under the empire notes shall
have theretofore been paid in full; or, if (i) within six (6) months of such
casualty, subject to Unavoidable Delay, Landlord and/or Sublandlord has not
commenced repair of the Premises or notified Tenant that sublandlord has elected
to terminate the Lease, or (ii) such casualty occurs during the last two (2)
years of the term and, in the event of either (i) or (ii), all outstanding
obligations under the Empire Notes shall have been
119
<PAGE>
Paid in full, then tenant may elect to terminate this lease by written notice to
landlord and sublandlord. Notwithstanding anything to the contrary contained
herein, any such termination right of sublandlord or tenant may only be
exercised if all amounts outstanding under the empire notes shall have been paid
in full. If landlord and/or subland2ord shall have received casualty insurance
proceeds in respect of office unit 2 in an amount sufficient to pay in full all
outstanding obligations under the empire notes, and tenant would otherwise have
the right to, and desires to, terminate this lease in accordance with clauses
(i) or (ii) of the second preceding sentence except for sublandlord's failure to
pay the empire notes, then upon notice from tenant, and provided that landlord
is permitted under the ground lease not to restore or rebuild the damaged
portion of the building, sublandlord shall apply such proceeds to the payment in
full of the empire notes. In either case such notice of termination shall be
given within sixty (60) days after such six month period or such fire or
casualty, as the case may be, specifying a date for the expiration of the lease,
which date shall not be more than sixty (60) days after the giving of such
notice, and upon the date specified in such notice the term of this lease shall
expire as fully and completely as if such date were the date set forth above for
the expiration of the term, and tenant shall forthwith quit, surrender and
vacate the premises without prejudice, however, to tenant's obligations under
the lease (as it existed prior to
120
<PAGE>
such termination), and any Rent and additional rent owing shall be paid up to
the date of the casualty and any payments of Rent or additional rent made by
Tenant which were on account of a period subsequent to such date shall be
returned to Tenant. Unless Sublandlord shall serve a termination notice as
provided in this subparagraph (D), Landlord shall make the repairs and
restorations under the conditions of subparagraph (C) of this Section 8.1 and
substantially complete such repairs 1nd restorations as expeditiously as
possible under the circumstances. After any such casualty, Tenant shall
cooperate with Landlord's and/or Sublandlords restoration by removing from the
Premises as promptly as reasonably possible, all of Tenant's salvageable
property. Nothing contained herein shall relieve Tenant from liability that may
exist as a result of damage from fire or other casualty.
E. Tenant hereby waives the provisions of Section 227 of the Real
Property Law of the State of New York and agrees that the provisions of this
Article shall govern and control in lieu thereof.
Section 8.2 Eminent Domain.
--------------
A. If all or substantially all of the Premises or the means of access
thereto shall be acquired or condemned by eminent domain for any public or
quasi-public use or purpose,
121
<PAGE>
this Lease shall continue in full force and effect, and Tenant shall continue to
pay the entire Possession Rent and/or any Bond Support Payments as the same
become due and payable hereunder until such time as all outstanding amounts then
due under the Empire Notes shall have been paid in full. Tenant shall have no
claim for the value of any unexpired term of this Lease and assigns to
Sublandlord Tenant's entire interest in any such award; provided however, that
(i) the award to Landlord and/or Sublandlord shall first be applied to pay any
and all amounts outstanding under the Empire Notes (and Landlord and/or
Sublandlord shall irrevocably direct payment of such award to the Bond Trustee
to be so applied), and thereafter Landlord and/or Sublandlord shall pay to
Tenant an amount, up to the balance of any such award, equal to the Possession
Rent and/or Bond Support Payments, if any, paid by Tenant from and after the
date of the vesting of title in the condemning authority and (ii) to the extent
same will not result in any reduction in the award to Landlord and/or
sublandlord, tenant shall be entitled to claim, prove and receive an award for:
(a) tenant's moving expenses, (b) the value of tenant's leasehold improvements
at the time of the condemnation, and (c) any personal property of Tenant that is
taken.
122
<PAGE>
If less than all or substantially all of the Premises shall be so
taken, Tenant's Pro Rata Share shall be adjusted to reflect such taking. Subject
to the further provisions of this Section 8.2A, Tenant shall nevertheless
continue to pay the entire Possession Rent and/or any Bond Support Payments as
the same become due and payable hereunder. The proceeds of any award for partial
taking shall be applied by Landlord and/or Sublandlord first, to reduce the
outstanding principal amount of the Empire Notes in an amount that will reduce
the periodic payments required to be made by Sublandlord thereunder by an amount
equal to the Rent Reduction (hereinafter defined), in which event (and only in
which event) Tenant shall be entitled to a dollar-for-dollar reduction in the
Possession Rent or the Bond Support Payments, as the case may be, for any such
reduction in Sublandlord's periodic payments. As used herein, the term "Rent
Reduction" shall mean the product of (x) the percentage reduction in the number
of square feet of floor space in the premises resulting from such taking and (y)
the base annual rent. If the award shall exceed the amount necessary to reduce
sublandlord's periodic payments by an amount equal to the rent reduction, then
such excess shall be applied by landlord to the repair, restoration or
replacement of the remaining premises. If the excess award shall be insufficient
to cover the repair, restoration or replacement of the remaining premises,
Landlord shall pay any deficiency between the award and the cost of such repair,
restoration or
123
<PAGE>
replacement. Such repair, restoration or replacement of the remaining Premises
shall be substantially completed within twelve (12) months after the aforesaid
taking in condemnation and approval by Tenant of the plans and specifications
for repair and restoration, which approval shall not be unreasonably withheld or
delayed, in accordance with such approved plans and specifications. If the award
shall be insufficient to reduce Sublandlord's periodic payment by the entire
amount of the Rent Reduction, Tenant shall not be entitled to a reduction or
offset against the Possession Rent and/or Bond Support Payments for any portion
of the Rent Reduction which exceeds the reduction in Sublandlord's periodic
payments under the Empire Notes, but in such event Tenant shall be entitled to a
credit against the Services Rent payable from time to time in an amount equal to
such balance of Rent Reduction, and if the aggregate Services Rent shall be
insufficient to satisfy such balance of Rent Reduction, the same shall otherwise
reimbursed by Landlord. As used herein, the term "all or substantially all of
the premises" shall mean such portion of the premises as shall entitle the
landlord and/or sublandlord to compensation equal to the full value of the
Premises.
B. If all or any part of the premises shall be temporarily taken by
eminent domain for any public or quasi public use or purpose, the term of this
lease and tenant's
124
<PAGE>
obligations hereunder (including, without limitation, the obligations to pay
Rent and additional rent) shall be unaffected but Tenant shall be entitled to
the portion of the award for such temporary taking that is allocable to the
period of such taking occurring within the Term and the balance of such =war]
shall be paid to Landlord.
ARTICLE 9
DEFAULTS AND REMEDIES
Section 9.1 Default. The occurrence AT ANY TIME DURING the Term
-------
of any one or more of the following events shall be deemed an "Event of
Default"::
A. If Tenant shall default in the payment when due of any installment
of Base Annual Rent or in the payment when due of any additional rent or charge,
and such default shall continue for a period of ten (10) days after notice by
Landlord or Sublandlord to Tenant of such default; or
B. If Tenant shall default in the observance or performance of any
term, covenant OR CONDITION OF THIS LEASE ON Tenant's part to be observed or
performed (OTHER THAN THE covenants for the payment of Base Annual Rent and
ADDITIONAL RENT OR CHARGES) AND TENANT SHALL FAIL AFTER NOTICE BY LANDLORD
125
<PAGE>
or Sublandlord of such default to remedy such default within thirty (30) days or
if said default is not capable of being cured within said thirty (30 day period
or such longer period as shall be reasonably necessary and Tenant shall not
commence the cure within said period or shall not thereafter diligently
prosecute to completion all steps necessary to remedy such default; or
C. If Tenant shall assign this Lease or sublet the Premises or a
portion thereof other than in conformance with the provisions of Article ll
hereof.
D. If Tenant shall file a voluntary petition under any applicable
section of the United States Code, or if such petition shall be filed against
Tenant and an order for relief shall be entered, or if Tenant shall file a
petition or an answer seeking, consenting to or acquiescing in any
reorganization, arrangement, composition, readjustment, liquidation, dissolution
or similar relief under the present or any future federal bankruptcy code or any
other present or future applicable federal, state or other bankruptcy or
insolvency statute or law, or shall seek, or consent to, in writing, the
appointment of any trustee, receiver, custodian, assignee, sequestrator,
liquidator or other similar official of tenant or of all or any substantial part
of its properties, or of the Premises or any interest of Tenant therein; or
126
<PAGE>
E. If within ninety (90) days after the commencement of a proceeding
against Tenant seeking any reorganization, arrangement, composition,
readjustment, liquidation, dissolution or similar relief under the present or
any future Federal Bankruptcy Code or any other present or future applicable
Federal, State or other bankruptcy or insolvency statute or law, such proceeding
shall not be dismissed, or if, within ninety (90) days after the appointment,
without the consent or acquiescence of Tenant (it being agreed that mere failure
to oppose a request or appointment shall riot constitute consent or
acquiescence), of any trustee, receiver, custodian, assignee, sequestrator,
liquidator or other similar official of Tenant, or of all or any substantial
part of its properties, or the Premises or any interest of Tenant therein, such
appointment shall not be vacated or stayed on appeal or otherwise, or if, within
ninety (90) days after the expiration of any such stay, such appointment shall
not be vacated; or
F. Upon the occurrence at any time of any one or more such events of
default, (i) sublandlord, if such events of default are with respect to the
matters set forth in subparagraphs (A) or (B) above, at any time thereafter, at
sublandlord's option, may give to tenant a thirty (30) days' notice of
termination of this lease and, in the event such notice is given, or, (ii) in
the event of the occurrence of any of the matters set forth in subparagraphs
(C), (D) or (E), this
127
<PAGE>
Lease and the Term shall come to an end and expire (whether or not the Term
shall have commenced) upon the expiration of said thirty (30) days or upon the
occurrence of such matters set forth in subparagraphs (D) or (E) with the same
effect as if the date of expiration of said thirty (30) days or the date of cue!
occurrence were the expiration date, but Tenant shall remain liable for damages
as provided herein. Any monies received from or on behalf of Tenant during the
pendency of any proceeding of the types referred to in the said subparagraphs
(D) or (E) shall be deemed paid as compensation for the use and occupation of
the Premises and the acceptance of any such compensation shall not be deemed a
waiver on the part of Landlord or Sublandlord of any rights under this Lease.
Notwithstanding any contrary provision herein contained, in the event Tenant
seeks relief under the Federal Bankruptcy Codes as provided in subparagraph (D)
ABOVE, THE SAME SHALL NOT BE deemed an Event of Default, so long as all Rent i9
paid to landlord in accordance with the terms of this lease.
Section 9.2 Remedies.
--------
A. If this lease shall have been terminated, or if tenant has
defaulted, after the expiration of any applicable grace period, in the payment
of rent or in observing any other term, condition or covenant and such default
i9 continuing, then, in any of such events, sublandlord may without notice,
128
<PAGE>
institute summary proceedings and dispossess Tenant and the legal representative
of Tenant or other occupants of the Premises, and remove their effects and hold
the Premises as if this Lease had not been made. Tenant hereby waives the
service of notice of intention to re-enter or to institute legal proceedings to
that end.
B. In case of any such default, re-entry, expiration and/or dispossess
by summary proceedings or otherwise, in addition to any other remedy now or
hereafter available to Landlord or Sublandlord under this Lease or applicable
laws: (i) the Rent shall become due thereupon and be paid up to the time of such
re-entry, dispossess and/or expiration; (ii) Sublandlord may relet the Premises
or any part or parts thereof, either in the name of Sublandlord or otherwise,
for a term which may at Sublandlord's option be less than or exceed the period
which would otherwise have constituted the balance of the Term, and may grant
concessions of free rent, if dictated by current market conditions; and (iii)
Tenant or the legal representative of tenant hall also pay sublandlord and/or
landlord, as applicable, a damages for the failure of tenant to observe and
perform said tenant's covenants herein contained, for each month of the period
which would otherwise have constituted the balance of the term, any deficiency
between (x) the sum of (a) one monthly installment of base annual rent, (b)
Taxes that would have been payable for the
129
<PAGE>
month in question but for such re-entry or termination, and (c) the current
monthly tenant's operating expense reimbursement, and (y) the net amount, if
any, of the rents collected on account of the lease or leases of the premises
for each month of the period which would otherwise have constituted the balance
of the term. The failure of sublandlord to relet the premises or any part of
parts thereof shall not release or affect tenant's liability for damages. In
computing such damages there shall be added to the said deficiency such
reasonable expenses as sublandlord may incur in connection with reletting,
including, but not limited to, court costs, reasonable attorneys' fees and
disbursements, brokerage and expenses to put and keep the premises in good order
or for preparing the same for reletting as hereinafter provided. Any such
damages shall be paid in monthly installments by tenant on the rent day
specified in this lease and any suit brought to collect the amount of the
deficiency for any month shall not prejudice in any way the rights of landlord
and/or sublandlord to collect the deficiencies for any subsequent or prior month
by a similar proceeding. Sublandlord, at its option, may make such alterations,
repairs, replacements and/or decorations in the premises as sublandlord, in its
sole judgment, considers advisable and necessary for the purpose of reletting
the premises, and the making of such alterations and/or decorations shall not
operate- or be construed to release tenant from liability hereunder as
aforesaid. Sublandlord shall in no
130
<PAGE>
event be liable in any way whatsoever for failure to relet the Premises, or in
any event that the Premises are relet, for failure to collect the rent thereof
under such reletting.
C. In the event of a breach by Tenant of any of the covenants or
provisions hereof, Landlord or Sublandlord, as the case may be, shall have the
right to initiate an action for injunction without notice of default being
served upon Tenant, and shall have the right to invoke any remedy allowed at law
or in equity as if re-entry, summary proceedings and other remedies were not
herein provided for. Mention in this Lease of any particular remedy shall not
preclude Landlord or Sublandlord from any other remedy under this Lease or
applicable laws.
Section 9.3 Trial by jury: counterclaim. Landlord, sublandlord and
----------------------------
tenant shall and they hereby do waive trial by jury in any action, proceeding or
counterclaim brought by any of the parties hereto against another on any matters
not relating to personal injury or property damage, but otherwise arising out of
or in any way connected with this lease, the relationship of landlord,
sublandlord and tenant, tenants use or occupancy of the premises, and any
emergency statutory or any other statutory remedy. Tenant further agrees that it
shall not interpose any counterclaim or counterclaims in a summary proceeding or
in any action based on non-payment of rent or any
131
<PAGE>
other payment required of Tenant hereunder other than any claim Tenant may have
against the Services Rent (or following the payment in full of all amounts
outstanding under the Empire Notes, the Rent) under this Lease.
Section 9.4 Landlord's and Sublandlord's Right to Cure Defaults.
-------------------------------------------------------
Landlord or Sublandlord may cure, after notice of default is served and any
applicable grace period has expired, any default by Tenant under this Lease; and
whenever Landlord or Sublandlord so elects, all reasonable costs and expenses
incurred by Landlord or Sublandlord, as the case may be, in curing a default,
including without limitation, reasonable attorneys' fees and disbursements,
together with interest on the amount of costs and expenses so incurred at the
Late Rate, shall be paid by Tenant to Landlord or Sublandlord, as the case may
be, on demand, and shall be recoverable as additional rent.
Section 9.5 Waiver of default. No consent or waiver, express or
------------------
implied, by landlord, sublandlord or tenant to or of any breach of any covenant,
condition or duty of any other party hereto shall be construed as a consent or
waiver to or of any other breach of the same or any other covenant, condition or
duty of another, unless in a writing signed by the party against whom waiver is
sought.
132
<PAGE>
ARTICLE 10
TENANT'S OPTION TO EXTEND TERM
Section 10.1 Option to Extend.
----------------
A. Tenant shall have the option but not the obligation to renew and
extend this Lease for one additional period of ten (10) years (such period being
hereinafter referred to as the "Renewal Period"). No earlier than forty (40)
months, but not less than thirty (30) months before the expiration of the Term,
Landlord shall notify Tenant of the months remaining in the Term and Landlord's
proposed Market Value Base Rent (as defined in Paragraph (C) below) establishing
the Rent to be paid by Tenant during the Renewal Period, and Tenant shall be
entitled to exercise its option to renew at any time within the ensuing twelve
(12) months by written notice to Landlord, time being of the essence; provided,
---- ----- -- --- -------
however, that if Landlord's notice i9 delivered to Tenant less than thirty (30)
months before the expiration of the Term, Tenant's time to exercise its option,
and the Term, shall each be extended by a period equal to the time elapsed
between thirty (30) months before the expiration of the term and the actual date
of landlord's notice to tenant. Notwithstanding the foregoing, tenant shall not
be entitled to exercise its option with respect to the renewal period unless, at
he time so exercised, this lease shall be in full force and effect. If tenant
shall fail to give any such notice within
133
<PAGE>
the aforesaid time limitation, Tenant's rights to exercise its option shall be
deemed waived and of no further force and effect.
B. The Renewal Period shall be governed by the same terms, covenants and
conditions in this Lease contained except that (i) Tenant shall have no further
right or option to extend the Term pursuant to this Article 10, and (ii) the
Base Annual Rent for the Renewal Period shall be equal to 95` of the Market
Value Base Rent as defined in subparagraph (C) below but in no event shall the
Rent for the Renewal Period be less than (x) the Rent in the twentieth (20th)
Lease Year per Lease Year for each of the twenty-first (21st) through
twenty-third (23rd) Lease Years, (y) the product obtained by multiplying (i) THE
Rent in the twenty-third (23rd) Lease Year by (ii) one hundred nine (109)
percent per Lease Year for each of the twenty-fourth (24th) through twenty-sixth
(26th) Lease Years, and (z) the product obtained by multiplying (i) the Rent in
the twenty-sixth lease year by (ii) one hundred twelve (112`j percent per lease
year for each of the twenty-seventh (27th) through thirtieth (30th) lease
years, in all such years subject to increase to reflect any additional space
tenant may have leased during the term and to which said renewal applies. In
either event, during the renewal period the tenant will pay, in addition, the
monthly payments of taxes and operating expenses pursuant to section 3.3, The
monthly cleaning cost charge and
134
<PAGE>
the monthly parking charge. Subject to the provisions hereof, if Tenant
exercises the option, the Term shall be deemed to include the Renewal Period.
C. (i) The term "Market Value 3ase Rent" set forth in subparagraph (B)
above shall mean the per square foot annual fair market rental value of the
Premises as of the commencement date of the Renewal Period.
(ii) the initia1 determination of market value base rent shall be
made by landlord. Landlord shall give notice to tenant of the proposed market
value base rent at the time of landlord's notice to tenant pursuant to section
10.1(A) hereof. If landlord and tenant shall fail to agree upon the market value
base rent proposed by landlord within thirty (30) days thereafter, then tenant
shall have the right to refer to arbitration the determination of market value
base rent, which shall be made in accordance with the terms and provisions of
section 10.1 and the real estate valuation arbitration rules of the American
Arbitration Association as may be in effect from time to time. It is
specifically understood and agreed that nothing in this subsection (ii) shall be
deemed to toll, modify or extend the time periods for tenant to exercise its
option to renew and extend this lease as provided in paragraph (a) above.
Subject in all events to paragraph B above, the determination by such
arbitrators shall be binding on the parties. Arbitrators shall be binding on the
135
<PAGE>
(iii) If for any reason the Market Value Base Rent shall not
have been determined prior to the commencement of the Renewal Period, and if
Tenant shall have elected to renew notwithstanding same, then until the Market
Value Base Rent shall have been fully determined, the Rent payable subsequent to
the commencement date of the Renewal Period shall be equal to the then current
Base Annual Rent, plus escalations for Taxes, Office Portion Operating Expenses,
cleaning costs, and parking charges then payable pursuant to the Lease. Upon a
final determination, an appropriate adjustment shall be made reflecting such
final determination, and Landlord and/or Sublandlord, or Tenant, as the case may
be, shall pay the other any overpayment or deficiency, as the case may be, from
the commencement of the Renewal Period to the date of such final determination.
D. The provisions of this Article l0 shall not be deemed to grant
Tenant any further option to renew or extend THIS Lease at the expiration of the
Renewal Period.
136
<PAGE>
ARTICLE 11
ASSIGNMENT AND SUBLETTING
Section 1l.l
A. Subject to the terms of subparagraphs B and C below, Tenant shall
have the right to freely assign, sell, mortgage, pledge or transfer this Lease
or sublet the Premises or parts thereof to, or permit occupancy thereof by, any
Person upon such terms and conditions as Tenant, within its sole discretion,
shall agree, and without consent of Landlord or Sublandlord. The proceeds of
such demise shall accrue solely to Tenant; neither Landlord nor Sublandlord
shall have any right of recapture in the event of such demise during the term of
the Lease or any extensions thereof; and neither Landlord nor its managing agent
nor Sublandlord shall be entitled to any brokerage or other fees in connection
with such demise.
B. Subject to the terms of subparagraph c below, the foregoing rights
of tenant shall be limited only to the extent that (i) any assignee or
subtenant of tenant shall be of a character, be engaged in a business, and shall
propose to use and continue to use the premises (or a portion thereof) in a
manner, in keeping with the character and quality of the office portion; (ii)
tenant shall not be in default beyond any applicable cure period hereunder at
the time when the
137
<PAGE>
assignment or subletting is to be consummated; (iii) solely with respect to the
floors of the Premises intended initially to be occupied by Tenant itself (i.e.,
floors 23-28), and only if Landlord shall perform Landlord's Work therein,
Tenant will not assign or sublet until after Substantial Completion of the Base
Building and landlord's Work. Tenant will provide Landlord, Sublandlord and
Standard & Poor's with reasonable prior notice of Tenant's intent to assign or
sublet, together with a description of the proposed assignee or subtenant.
Tenant will furnish co Landlord and Sublandlord copies of all executed subleases
or assignments.
C. Notwithstanding any assignment of this lease or subletting of all
or a portion of the premises, the tenant herein named, and each immediate or
remote successor in interest of the tenant herein named, shall remain liable,
jointly and severally (with respect to tenant, as primary obligor), with its
assignee (including, without limitation landlord if landlord is its assignee),
subtenant (including, without limitation, landlord if landlord is its
subtenant), and all subsequent assignees or subtenants, for the performance of
tenant's obligations hereunder (including, without limitation, the obligation to
pay possession rent, which shall survive each such assignment or sublet) and,
without limiting the generality of the foregoing, shall remain fully and
directly responsible and liable to landlord and sublandlord for all acts and
138
<PAGE>
omissions on the part of any assignee or subtenant in violation or breach of any
of tenant's obligations under this lease. Without limiting the generality of the
foregoing, tenant acknowledges and agrees that it shall not be released from any
of its obligations under this lease including, without limitation, its
obligation to pay Possession rent hereunder, upon any assignment or sublease
hereunder, except, following the payment in full of the empire notes, in the
event of an assignment to an assignee acceptable to the institutional lender(s)
and with the agreement of said lender(s) to substitute such assignee in tenant's
place and stead, in which case tenant shall be released from all of its
obligations under this lease.
ARTICLE 12
AMENDMENT OF LEASE
At any time or times prior to or after the commencement date, tenant
agrees to execute, within thirty (30) days after demand therefor, one or more
amendments to this lease as may be reasonably requested by a mortgagee so long
as such amendment (a) does not increase the base annual rent or additional rent,
(b) does not reduce the term, (c) does not increase tenant's pro rata share
(except in accordance with the provisions of this lease), (d) does not
materially and adversely diminish tenant's rights having substantial value or
139
<PAGE>
materially and adversely increase Tenant's obligations under this Lease, and (e)
does not materially and adversely diminish Tenant's rights in respect of the
Office Portion, Garage Portion, or the Common Areas. Notwithstanding the
foregoing, the parties shall not modify, supplement or amend this Lease in any
manner unless the parties shall first have obtained written confirmation from
Standard & Poor's that any such proposed modification or amendment will not
result in a downgrade, withdrawal or qualification of the current rating
assigned to of the Empire Notes. Any amendment, supplement and/or modification
of this Lease in violation of the foregoing requirements shall be null and void.
ARTICLE 13
SUBORDINATION AND ATTORNMENT
Section 13.1 Subordination.
-------------
A. This lease is and all of tenant's rights hereunder are subject and
subordinate to (i) any ground or underlying leases that now exist or may
hereafter be placed on the land, building and/or office portion or any part
thereof (including, without limitation, the sandwich lease) and any renewals,
amendments and/or modifications thereof, (ii) any mortgage and to any and all
advances to be made thereunder, and to the interest thereon, and all renewals,
replacements, amendments,
140
<PAGE>
modifications, consolidations and extensions thereof and (iii) the Condominium
documents (subject, however to article 37 of the declaration of easements).
Tenant covenants and agrees that if any mortgagee or the holder of any
underlying lease succeeds to sublandlord's interest under this lease, tenant
will attorn to such mortgagee or the holder of any such underlying lease and
will recognize such mortgagee or such holder as the lessor under this lease. At
the option of sublandlord or any successor landlord hereunder, tenant agrees
that neither the cancellation nor termination of any underlying lease to which
this lease is now or may hereafter become subject or subordinate, nor any
foreclosure of a mortgage or assignment in lieu of foreclosure, nor the
institution of any suit, action, or other summary proceedings by sublandlord or
any successor landlord thereof, or any foreclosure proceeding brought by any
mortgagee to recover possession of the leased property, shall by operation of
law or otherwise result in the cancellation or termination of this lease or the
obligations of the tenant hereunder, and tenant covenants and agrees to attorn
to any successor to sublandlords interest in the premise-. Tenant agrees not to
pay more than one month's rent in advance without first obtaining the written
approval of the holders of all underlying leases and all mortgagees. Tenant
shall execute and deliver in recordable form, whatever instruments may be
reasonably required to acknowledge or further effectuate the provisions of this
article 13, and in the event tenant fails so
141
<PAGE>
to do within lO days after demand in writing, Tenant does hereby make,
constitute and irrevocably appoint Sublandlord as its attorney-in-fact, coupled
with an interest, and in its name, place and stead so to do.
B. The subordination of this Lease and Tenant's covenant to attorn as
hereinabove provided is subject to the express condition that upon written
demand therefor (x) all Mortgagees shall execute and deliver to Tenant a
subordination, nondisturbance and attornment agreement in a form reasonably
acceptable to Mortgagee and Tenant, it being understood that forms of
subordination, non-disturbance and attornment agreements then prevailing among
Institutional Lenders shall be acceptable to Tenant, provided same does not
materially increase Tenant's obligations or materially and adversely affect
Tenant's rights having substantial value under thin Lease, and (y) the lessor
under any Underlying Lease shall execute and deliver to Tenant an agreement to
the effect that if such Underlying Lease is terminated, said lessor shall
142
<PAGE>
recognize tenant as the direct tenant of the lessor on the same terms and
conditions as contained in this lease, provided that no default shall have
occurred under this lease and remained uncured within the time period, if any,
for curing such default. Any such agreement, or any agreement of similar import,
from the mortgagee and/or lessor shall be in such form as is reasonably
acceptable to tenant and such mortgagee and/or lessor, and shall be executed by
tenant in each instance within twenty (20) days after written request therefor
by sublandlord. Notwithstanding anything otherwise contained herein, the parties
acknowledge and agree that that certain nondisturbance, attornment and
recognition agreement by and among the city of new york, sublandlord and tenant
of even date herewith sets forth, among other things, the obligations of the
landowner (the city of new york) in the event of a termination of the ground
lease and/or a bankruptcy of landlord, and that this lease will remain in full
force and effect upon termination-of the ground lease and/or bankruptcy of
landlord upon the terms and conditions contained herein (including, without
limitation, tenant's obligations to continue to pay possession rent and/or pond
support payments, as the case may be).
143
<PAGE>
Section 13.2 Attornment.
----------
A. If a Mortgagee or lessor of an Underlying Lease, as the case may
Be, otherwise so elects at its option to accept such attornment, then the lease
shall not terminate as a result of mortgagee's or lessor's actions, tenant shall
attorn to and recognize the mortgagee or lessor as tenant's landlord under the
lease, and the mortgagee shall accept such attornment and recognize tenant as
the mortgagees tenant under the lease. Upon such attornment and recognition the
lease shall continue in full force and effect as or as if it were a direct lease
between mortgagee and tenant upon and subject to all of the then executory
terms, conditions and covenants as are set forth in the lease and which shall be
applicable after such attornment and recognition, or at mortgagee's or lessor's
option, mortgagee and tenant shall enter into a direct lease upon such terms and
conditions, except that the mortgagee, or any person which shall acquire the
interest of landlord under the lease by reason of foreclosure, assignment in
lieu thereof or other enforcement of the mortgage or underlying lease, their
successors and assigns (hereinafter "purchaser"), shall not be:
(i) bound by or liable for any act, omission or default of any prior landlord,
including, without limitation, Sublandlord or Landlord (each a "Prior
Landlord") under the Lease or for the payment of any monies owing by or on
144
<PAGE>
deposit with any Prior Landlord to the credit of Tenant;
(ii) bound by or subject to a claim, counterclaim, defense or
offset, credit or deduction which theretofore shall have accrued to the Tenant
against any Prior Landlord;
(iii) bound by any modification or amendment of the Lease consummated
after the date of the Mortgage or underlying lease or by any previous prepayment
of more than one month's Rent or additional rent unless such amendment,
modification or prepayment shall have been approved in writing by the Mortgagee
or Underlying Lessor, as the case may be;
(iv) obligated to repair, restore, rebuild and replace the Premises or
the building or any part thereof, in the event of total or substantial damage or
destruction beyond such repair, restoration, rebuilding or replacement as can
reasonably be accomplished from the net proceeds of insurance actually received
by, or made available to, the mortgagee or underlying lessor, as the case may
be;
(v) obligated to repair, restore, rebuild and replace the premises
or the building or any part thereof, in the event of partial condemnation,
beyond such
145
<PAGE>
repair, restoration, rebuilding or replacement as can reasonably be accomplished
from the net proceeds of any award actually received by, or made available to,
the Mortgagee, as consequential damages allocable to the part of the Premises or
the Building not taken; or
(vi) obligated with respect to the erection and completion of the
building in which the Premises is located or for completion of the Premises or
any improvements for Tenant's use and occupancy, or to make any contribution or
allowance in respect thereof.
B. Without the prior written consent of the Mortgagee and Underlying
Lessor in each instance, none of Landlord, Sublandlord or Tenant shall, except
as specifically permitted in the Lease, (i) terminate or consent to the
cancellation or surrender of the Lease, except as permitted by the provisions of
the MOrtgage and/or the underlying lease, but in no event shall this lease be
terminated, cancelled or surrendered so long as any of the empire notes shall
remain outstanding, or (ii) modify the lease so as to shorten the unexpired term
thereof, decrease the amount of rent payable thereunder or reduce the premises,
or change or delete any renewal or expansion option herein, or in any other
material respect, unless the parties shall have first obtained both the written
consent of the bond trustee and the written confirmation from
146
<PAGE>
Standard & Poor's that any such proposed modification will not result in a
downgrade, withdrawal or qualification of the current rating assigned to the
Empire Notes, or (iii) make, or accept, prepayments of any installments of Rent
to become due under the Lease, except prepayments which are required to be paid
thereunder or which are in the nature of security for the performance of
Tenant's obligations thereunder, or (iv) in any other manner impair in any
material respect the value of the Premises or the security of the Mortgage or
Underlying Lease.
C. The provisions of this Article 13 shall be selfoperative and no
further instrument shall be necessary to effect the aforementioned attornment,
recognition and subordination. Nevertheless, Tenant agrees that in confirmation
thereof Tenant, within twenty (20) days after demand by Sublandlord from time to
time, shall execute and deliver to a Mortgagee or Underlying Lessor a
subordination and nondisturbance/attornment agreement executed by and among
Tenant, the mortgagee or underlying lessor and/or sublandlord incorporating the
provisions of this article 13 in form reasonably acceptable to sublandlord,
tenant and such mortgagee or underlying lessor. Sublandlord and tenant agree
that such an agreement in substantially the form annexed hereto shall be deemed
reasonably acceptable to tenant.
147
<PAGE>
ARTICLE 14
MISCELLANEOUS PROVISIONS
Section 14.1 Notices.
-------
A. Any notice from Landlord or Sublandlord to Tenant or from Tenant to
Landlord or Sublandlord shall be in writing and shall be deemed duly rerved if
mailed by registered or certified mail, return receipt requested, or by
overnight courier or by hand delivery with receipt acknowledged, or by Fax (with
a copy by mail as specified above), addressed, if to Tenant, at Tenant's address
set forth on page 1 of this Lease, Attention: Mr. Richard Pettit (Fax Number
(212) 387-2689), or to such other address as Tenant shall have last designated
by notice in writing to Landlord and Sublandlord with a copy to Raymond A.
Levites, Esq., Pavelic & Levites P.C., 101 East 52nd Street, New York, New York
10022 (Fax Number (212) 856-0616), and if to Landlord or Sublandlord, at its
address set forth on page 1 of this Lease or such other address as such party
may have last designated by notice in writing to Tenant, with a copy to Muss &
Muss, 118-35 Queens Boulevard, Forest Hills, New York, 11375, Attention: General
Counsel. Notice shall be deemed served when mailed, faxed or when actually
received if hand delivered or delivered by overnight courier. Landlord shall
give Tenant a copy of any notice relating to the construction of the Building
which Landlord must give, and any
148
<PAGE>
communication which Landlord receives from, the New York City Economic
Development Corporation (or its successor) under the Ground Lease.
B. While any Mortgage is outstanding, no notice of default from Tenant
to Landlord or sublandlord shall be effective unless and until a copy of such
notice of default is given to each Mortgagee, provided that Tenant shall have
been furnished with the name and address of such Mortgagee. Such Mortgagee shall
have a reasonable period for curing such default following such notice and
following the time when such Mortgagee shall have been entitled under its
Mortgage to remedy the same (which shall in no event be less than the period, if
any, to which Landlord or Sublandlord as the case may be, would be entitled
under this Lease to cure such default), provided such Mortgagee diligently
commences and continues to remedy such default.
Section 14.2 Brokeraqe. Tenant and Landlord represent and warrant that
---------
they had no dealings with any broker or agent in connection with this lease
(except to the extent provided in that certain memorandum of understanding dated
as of June 1, 1995 by and between leucadia national corporation, muss
development company, mwr associates, and tag realty, l.L.C.) And each covenants
to indemnify, defend and hold harmless the other from and against any and all
cost, expense or liability
149
<PAGE>
(including attorneys' fees and disbursements) for any compensation, commissions
and charges claimed by any broker or agent with respect to this Lease or the
negotiation thereof with whom the indemnifying party had dealings. Tenant shall
not be required to pay any compensation, commissions or charges to Landlord, the
managing agent of the Office Portion, or any broker or agent of Landlord in
respect of any assignments or subleases of the Premises under Article 11 hereof
by or on behalf of Tenant unless Tenant expressly shall have engaged Landlord,
its broker or agent in that respect.
Section 14.3 Estoppe1 Certificates. Tenant agrees from time to time,
----------------------
within thirty (30) days after written request therefor, to furnish to Landlord
and Sublandlord an executed statement, duly acknowledged, setting forth the then
Base Annual Rent payable under this Lease, the date to which Base Annual Rent
and additional rent have been paid, whether any offsets or defenses exist
against payment of Services Rent and, if any are alleged to exist, the nature
thereof, whether the lease is in full force and effect, whether the lease has
been amended, renewed, modified or assigned, whether tenant has accepted
possession of the entire premises or any individual office floors and such other
information as landlord, sublandlord, ground lessor or any mortgagee may
reasonably request. Any outside party may rely on the statements made in such
estoppel certificates.
150
<PAGE>
Section 14.4 Applicable Law and Construction. The laws of the State of
-------------------------------
New York shall govern in all respects the validity, performance and enforcement
of this Lease. The invalidity or unenforceability of any provision of this
Lease shall not affect or impair any other provision. The submission of this
document to Tenant for examination does not constitute an offer to lease, or a
reservation of or option to lease, and becomes effective only upon execution and
delivery thereof by Landlord, Sublandlord and Tenant, subject to all of the
terms hereof. All negotiations, considerations, representations and
understandings between the parties with respect to the subject matter hereof are
incorporated in this Lease and in the Date Certain Agreement. Landlord,
Sublandlord or their agents have made no representations or promises with
respect to the Office Portion, Building or the Premises, except as herein
expressly set forth. Tenant further understands that this Lease and every other
lease or agreement with every other tenant or occupant of the Building is
negotiated on its own merits and neither Landlord nor Sublandlord makes any
representation as to the similarity of the terms of this lease with any other
such lease or agreement. The headings of the several articles and sections
contained herein are for convenience only and do not define, limit or construe
the contents of such articles or sections. Whenever herein the singular number
is used, the same shall include the plural, and the neuter gender shall include
the masculine and feminine genders.
151
<PAGE>
Section 14.5 Relationship of the Parties. Nothing contained herein
shall be deemed or construed by the parties hereto, or by any third party, as
creating the relationship of principal and agent or partnership or joint venture
between the parties hereto, it being understood and agreed that no provision
herein, nor any acts of the parties hereto, shall be deemed to create any
relationship between the parties hereto other than the relationship of landlord
and tenant.
Section 14.6 Construction on Adjacent Premises or Buildings. If any
-----------------------------------------------
excavation or other building operation shall be about to be made on any premises
adjoining or above or below the Premises or on any other portion of the
Building, Tenant shall permit Landlord or the adjoining owner, and their
respective agents, employees, licensees and contractors, to enter the Premises
and to shore the foundations and/or walls thereof, and to erect scaffolding
and/or protective barricades around and about the Premises (but not so as to
preclude complete entry thereto) and to do any act or thing necessary for. the
safety or preservation of the Premises. Tenant's obligations under this Lease
shall not be affected by any such construction or excavation work, shoring-up,
scaffolding or barricading. Neither Landlord nor Sublandlord shall be liable in
any such case for any inconvenience, disturbance, loss of business or any other
annoyance arising from any such construction, excavation, shoring-up,
scaffolding or
152
<PAGE>
barricades, but Landlord shall use its diligent efforts so that such work will
cause as little inconvenience, annoyance and disturbance to Tenant as possible
consistent with accepted construction practice in the vicinity and so that such
work shall be expeditiously completed.
Section 14.7 Short Form Lease. Tenant agrees sot to record this Lease.
----------------
Each party shall, at the request of the other, promptly execute, acknowledge and
deliver for recording, a memorandum of lease prepared by Sublandlord and
mutually satisfactory in form and substance, but the provisions of this Lease
shall control the rights and obligations of the parties.
Section 14.8 Binding Effect of Lease. The covenants, agreements and
-----------------------
obligations herein contained, except as herein otherwise specifically provided,
shall extend to, bind and inure to the benefit of the parties hereto and their
respective personal representatives, heirs, successors and permitted assigns.
Each covenant, agreement, obligation or other provision herein contained shall
be deemed and construed as a separate and independent covenant of the party
bound by, undertaking or making the same, not dependent on any other provision
of this lease unless otherwise expressly provided.
Section 14.9 Effect of Unavoidable Delays. The provisions of this
-----------------------------
Section shall be applicable if there shall
153
<PAGE>
Occur, during the term, or prior to the commencement thereof, any: (i)
strike(s), lockout(s) or labor dispute(s); (ii) inability to obtain labor,
materials, or reasonable substitutes therefor; (iii) disputes between landlord
or sublandlord and tenant with respect to the matters described in article 2 of
this lease in accordance with the terms thereof; or (iv) acts of god,
governmental requirements, governmental restrictions, regulations or controls,
enemy or hostile governmental action, civil commotion, fire or other casualty,
or other conditions similar or discimilar to those enumerated in this item (iv)
beyond the reasonable control of the party obligated to perform (an "unavoidable
delay"). If landlord, sublandlord or tenant shall, as the result of any
unavoidable delay, fail punctually to perform any obligation on its part to be
performed under this lease, then such failure shall be excused and not be a
breach of this lease by the party in question, but only to the extent occasioned
by such event. If any right or option of either party to take any action under
or with respect to this lease is conditioned upon the same being exercised
within any prescribed period of time or at or before a named date, then such
prescribed period and such named date shall be deemed to be extended or delayed,
as the case may be, for a period equal to the period of the delay occasioned by
any above-described event. Notwithstanding anything herein contained, however,
the provisions of this section shall not be applicable to, and shall not affect,
tenant's obligations: to pay rent or its
154
<PAGE>
Obligations to pay any other sums, moneys, costs, additional rent, charges or
expenses required to be paid by tenant hereunder; to deliver notices.
Certificates and documents required to be delivered hereunder; to comply with
any obligation under this lease the failure of which would subject landlord or
sublandlord to any -ivi1 or criminal liability; or to exercise its option to
renew pursuant to section 10.1(A) hereof.
Section 14.10 No Oral chances. Neither this Lease nor any provision
---------------
hereof may be changed, waived, discharged or terminated orally, but only by an
instrument in writing signed by the party against whom enforcement of the
change, waiver, discharge or termination is sought and otherwise subject to the
requirements of Article 12.
Section 14.11 Executed Counterparts of Lease. This Lease may
Be executed in any number of counterparts and each of such counterparts shall
for all purposes be deemed to be an original; and all such counterparts shall
together constitute but one and the same lease.
Section 14.12 Arrangement of Entrances. Etc. Except as otherwise
Provided in this lease, each of landlord and sublandlord has the right at any
time to change the arrangement or location of entrances, passageways, doors,
doorways,
155
<PAGE>
corridors, elevators, stairs, toilets and other public parts of the Building
and/or Common Areas outside the Premises, provided that any such change does not
significantly and adversely alter the general appearance or utility of, or
access to the Premises. Landlord or Sublandlord, as the case may be, agrees to
give Tenant prompt notice of any such change before such change is implemented:
Section 14.13 Condominium. Notwithstanding anything to the contrary
contained herein or otherwise (but subject in all events to the provisions of
Article 13 hereof), Tenant hereby acknowledges and agrees that Landlord,
Sublandlord and/or the Ground Lessor may wish to subject all or any part of the
Building (including, without limitation, the Office Portion) to a condominium
regime. Accordingly, Tenant hereby agrees that this Lease shall be subject and
subordinate to any declaration of condominium (including, without limitation,
the Condominium Documents and except to the extent such subordination is limited
by the provisions of article 37 of the declaration of easements) at any time
affecting all or any part of the building (including, without limitation, the
office portion). Pursuant to such declaration certain rights and obligations
hereunder of landlord hall be assumed by the condominium association formed in
connection with the condominium conversion. In confirmation of the foregoing,
tenant shall, from time to time, execute, acknowledge and deliver to landlord
156
<PAGE>
or Sublandlord within thirty (30) days following such party's request such
instruments of subordination as such party may reasonably require. On notice to
Landlord, Tenant shall have the right in Tenant's discretion and at its sole
cost and expense, subject to the approval of the Institutional Lender(s), to
divide the Premises into two or more condominium units, and Landlord shall
cooperate fully with Tenant to effect such conversion. Nothing in this Lease
shall be deemed to constitute an offering of a condominium unit or units to
Tenant, nor is Landlord obligated to convert the Building to condominium
ownership or to designate the Premises into one or more condominium units.
Section 14.14 Waiver of Subrogation. Whenever (a) any loss, cost,
----------------------
damage or expense resulting from fire, explosion or any other casualty or
occurrence is incurred by either of the parties to this Lease, or anyone
claiming by, through, or under it in connection with the Premises or Office
Portion, as the case may be and (b) such party is then covered in whole or in
part by insurance with respect to such loss, cost, damage or expense or is
required under this lease or the ground lease to be so insured, then the party
so insured (or so required) hereby releases the other party from any liability
said other party may have on account of such loss, cost, damage or expense but
only to the extent of any amount covered by reason of such insurance (or which
could have been recovered had such
157
<PAGE>
insurance been carried as so required) and waives any right of subrogation which
might otherwise exist in or accrue to any person on account thereof.
Section 14.15 Access by Handicapped Persons. Landlord represents that
-----------------------------
the Premises demised herein will be suitable for access by handicapped persons
and will be in full compliance with the Americans with Disabilities Act of 1990,
as amended.
Section 14.16 Diligence. Landlord, Sublandlord and Tenant shall
---------
perform their respective obligations under this Lease with all reasonable
diligence.
Section 14.17 Condominium Documents. Landlord shall not modify, amend
---------------------
or delete Article 37 of the Declaration of Easements or the corresponding
sections of any other Condominium Documents without the prior written consent of
Tenant.
Section 14.18 Interest on Offset Amounts. With respect to tenant's
---------------------------
rights of offset against services rent pursuant to sections 3.3C(i)(c), 5.11B,
6.1B and c, 8.1B and c, 8.2A and article 16 hereof, in the event that any cost
or expense subject to such offset right shall not have been satisfied out of the
services rent after a period of one year after such cost
158
<PAGE>
or expense shall have accrued, then Tenant shall be entitled to interest on any
unsatisfied amounts at the interest rate actually incurred by Tenant in respect
of such cost or expense, not to exceed the Late Rate, accruing from and after
the expiration of such one year period until such cost or expense shall have
been satisfied from Services Rent or otherwise paid by Landlord, which interest
may be offset against future installments of Services Rent, and if not so
offset, shall be paid to Tenant by Landlord. The provisions of this Section
shall survive the expiration or other termination of this Lease.
Section 14.19 No Termination. Notwithstanding anything contained
---------------
herein to the contrary, Tenant agrees that, so long as all or any portion of the
Empire Notes shall remain outstanding, it shall have no right to terminate this
Lease or claim a partial or total eviction by reason of Landlord's or
Sublandlord's acts or omissions or any other reason whatsoever and it shall
continue to pay Possession Rent and/or Bond Support Payments, as the case may
be, under all circumstances. Following repayment in full of all amounts due and
owing under the empire notes, tenant shall not exercise any right it may have at
law or in equity to terminate this lease or claim a partial or total eviction by
reason of landlord's or sublandlord's acts or omissions or any other reason
whatsoever unless it shall have first given notice of such act or omission
159
<PAGE>
to the Mortgagee at the address furnished to Tenant.
Section 14.20 Due Authorization. As an inducement to Landlord and
------------------
Sublandlord to execute this Lease, Tenant represents and warrants to Landlord
and Sublandlord, knowing that Landlord and Sublandlord are relying thereon,
that all applicable and necessary approvals and authorizations have been
obtained by Tenant prior to its execution and delivery of this Lease.
ARTICLE 15
ARBITRATION
Section 15.0 Sublandlord. Landlord and Tenant acknowledge and agree
-----------
that Sublandlord shall have no liability in connection with any arbitration
under this Article and each hereby waives any claim with expect to such
liability.
Section 15.1 Arbitration. Any party may request arbitration on any
-----------
matter in dispute wherein arbitration pursuant to this section 15.1 Is expressly
provided in this lease as the appropriate remedy. All such controversies shall
be settled by the American Arbitration Association in New York City in
accordance with the procedural rules then obtaining of the American Arbitration
Association or any successor thereto. The arbitrator or arbitrators may grant
injunctions or other
160
<PAGE>
relief in such controversies of claims. The decision of the arbitrator or
arbitrators shall be final, conclusive and binding upon the parties, and a
judgment may be obtained thereon in any court having jurisdiction. Pending the
resolution of a dispute by arbitration as herein provided, Tenant shall continue
to make all payments of Rent and additional rent as and hen billed by Landlord
and Sublandlord, whether or not such payments are the subject matter of the
arbitration, and shall otherwise perform its obligations hereunder. The
unsuccessful party in any such arbitration proceeding shall bear the costs and
expenses of the arbitrators and of the successful party (including reasonable
attorney' and other professionals' and experts, fees and disbursements); if a
party is partially successful, such costs and expenses shall be allocated by the
arbitrators.
Section 15.2 Expedited Dispute Resolution. In such cases where this
------------------------------
lease expressly provides for the settlement of a dispute or question arising
under article 2 of this lease or respecting the size of the premises, tenant's
pro rata share and/or the gross leasable area of the office portion, and only in
such cases, such dispute or question shall be determined by an arbitration
conducted in accordance with the terms and provisions of this section 15.2.
161
<PAGE>
A. The party hereto desiring to arbitrate a dispute or question
arising under Article 2 of this Lease or respecting the Size of the Premises,
Tenant's Pro Rata Share, the Gross Leasable Area of the Office Portion or as
otherwise provided therein, shall give notice ("Dispute Notice") to that effect
to the other parties hereto, and the dispute in question shall be presented for
resolution to the first available arbiter set forth on the list below. In the
event the first named arbiter is not available or is unwilling to serve, the
arbiter next set forth on the list shall be engaged, and so on, until arriving
at an available arbiter:
1. Lew Davis, of Davis, Brody and Associates
2. John Belle, of Beyer, Blinder & Belle
3. Robert Fox, of Fox and Fowle Architects, P.C.
During any Lease Year, Tenant, Landlord and Sublandlord may each, by
written notice to the other, disqualify any of the listed arbiters for any
reason whatsoever and propose additional arbiters to be added to the list to be
agreed upon in accordance with section 15.2(B) except no party can disqualify an
arbiter who then has a pending dispute before him for resolution. The remaining
arbiters shall move up on the list to fill in any vacancies so created. The
arbiter serving to resolve any dispute hereunder is hereinafter referred to as
the "arbiter."
162
<PAGE>
Any party may, within five (5) business days of receipt of a
party's Dispute Notice ("Notice Period"), give notice to the other parties and
to the Arbiter ("Dispute Notice") stating that the dispute is not subject to
the dispute resolution mechanism of this Section 15.2 (a "Non-Arbitrable
Dispute"). The validity of a party's Dispute Notice shall also be subject to
arbitration as set forth in this Section 15.2. If the party giving the Dispute
Notice fails to notify the other party within the Notice Period that the dispute
is a Non-Arbitrable Dispute, then such dispute shall be deemed arbitrable and
the parties shall make whatever presentations they wish to the Arbiter within
five (5) business days after the expiration of Notice Period. Within five (5)
business days thereafter, the Arbiter shall attempt to cause Landlord and/or
Sublandlord and Tenant to agree on a resolution of the dispute and, failing
that, shall make his or her decision in writing. Copies of the arbiteris
decision shall be sent to landlord, sublandlord and to tenant and shall be
binding on each. Any costs incurred by or payable to the arbiter in any such
proceeding shall be paid by the party which does not prevail or as shall be
determined by the arbiter. In the event landlord or tenant is the unsuccessful
party in three (3) or more disputes referred to arbitration under section 15.2,
Then such unsuccessful party shall reimburse the successful party for its
reasonable attorneys, fees and expenses for each additional arbitration that it
loses under section 15.2, Regardless of who
163
<PAGE>
succeeds in such additional arbitration. Notwithstanding the foregoing, in the
event that Sublandlord shall be the unsuccessful party in an arbitration under
this Section, Landlord shall pay to Tenant any costs or reasonable attorneys
fees which would otherwise be payable by Sublandlord. Each of the parties hereto
agrees that it will engage the services of legal counsel in connection with an
arbitration under Section 15.2 only to the extent reasonably necessary under the
circumstances to resolved a dispute under this Section. In assessing the costs
to be allocated, the Arbiter shall determine if it was reasonably necessary to
engage legal counsel, but the Arbiter may not deny any party the right to engage
counsel.
B. If any of the named arbiters dies, goes out of business, is
disqualified by landlord, sublandlord or tenant, or elects to withdraw from the
list, then the parties shall agree on a replacement within twenty (20) days
after notice thereof. If the parties fail to so agree, and if more than one
arbiter remains on the list, each party within five (5) days after such twenty
(20) day period, shall designate one of the remaining arbiters and the two
arbiters so chosen shall appoint a replacement within twenty (20) days
thereafter. If only one arbiter remains on the list, that arbiter shall so
appoint a replacement, in his or her sole discretion, from the names proposed by
landlord, sublandlord and tenant. All newly chosen
164
<PAGE>
Arbiters shall be placed at the bottom-most position of the list.
C. This arbitraton procedure shall be the exclusive remedy as to
items described in Section 15.2 and Landlord, Sublandlord or Tenant shall not
have any right to seek any injunctive or other mandatory relief pending
completion of the procedures set forth in this Section 15.2.
D. Landlord and Tenant, jointly and severally, shall hold harmless and
indemnify the Arbiter(s) for any costs and damages resulting from the good faith
arbitration of the dispute.
ARTICLE 16
CERTIFICATE OF OCCUPANCY - COMPLIANCE WITH LAWS
Unless Tenant shall perform Tenants Work Plan pursuant to Section
2.1(I), landlord agrees to deliver to tenant, as soon as same is available to
landlord, a true copy of either a temporary or permanent certificate of
occupancy, or other sufficient indicia of legality for use of the premises, for
the purposes set forth in this lease.
Provided this Lease in in full force and effect and Tenant is not in
default thereunder, Landlord at its own cost
165
<PAGE>
and expense agrees, except as otherwise provided in this lease, to comply with
all governmental requirements (including, without limitation, those relating to
hazardous materials and substances and the environment) and rules and
regulations of any board of fire underwriters having jurisdiction over the
premises or the real property of which they form a part, during the term hereof
or renewal term, if any, and to remove all violations which may be placed
against the premises or the real property of which they form a part, including
but not limited to building code and fire code violations, except those
violations caused by tenant or its agents, employees or guests; provided that
landlord reserves the right to contest and challenge any such violations through
appropriate legal proceedings or otherwise. Subject to the foregoing and to
unavoidable delay, if landlord fails to remove those violations landlord is
obligated to remove pursuant to the provisions of this article, tenant, after
ninety (90) days written notice to landlord, may, as agent of landlord, perform
the same and deduct the reasonable cost thereof from any services rent (or upon
payment in full of the empire notes, any rent) due or that may become due and
payable under this lease, unless landlord has commenced to cure, remove and/or
institute legal proceedings or action to contest such violation and diligently
thereafter continues the prosecution thereof. Tenant hereby agrees that (i) any
remedies available to tenant under this article 16 may be exercised only against
landlord and not
166
<PAGE>
against Sublandlord and (ii) while any of the Empire Notes shall remain
outstanding, Tenant shall have no right to offset any amounts clue to Tenant
under this Article 16 against Possession Rent.
IN WITNESS WHEREOF, Landlord, Sublandlord and Tenant have hereunto Executed
this Lease as of the day and year first above written.
LANDLORD:
BROOKLYN RENAISSANCE PLAZA LLC
BY: ALLIED RENAISSANCE
MANAGERS LLC, Manager
SUBLANDLORD:
BRP II LLC
BY: BRP II Managers LLC,
Managing member
BY: BRP II Corp.,
Managing Member
BY: __________________________
Name: Joshua L. Muss
Title: President
167
<PAGE>
BROOKLYN RENAISSANCE PLAZA LLC
By: Allied Renaissance Managers LLC,
Manager
By: Muss Brooklyn
Development Co. L.P.,
Manager
By: Muss Brooklyn Development
Corp.,
General partner
BY: __________________________
Joshua L. Muss
President
<PAGE>
STATE OF New York )
: ss.:
COUNTY OF New York )
On this 27th day of June 1996, before me personally came Joshua L. Muss, to
me known, who, being by me duly sworn, did depose and say that he resides at 11
Rutherford Lane, Lawrence, New York; that he is the President of Muss Brooklyn
Development Corp., the corporation described in and which executed the
foregoing instrument as the General Partner of Muss Brooklyn Development Co.
L.P., the Manager of Allied Renaissance Managers LLC, the Manager of Brooklyn
Renaissance Plaza LLC, the limited liability company described in and which
executed the foregoing instrument; and that he signed his name thereto by
authority of the board of directors of the Muss Brooklyn Development Corp. as
the act and deed of Brooklyn Renaissance Plaza LLC.
_______________________________
Notary Public
MARY J. FISNAR
Notary Public, State of New York
No. 31-5003018
Qualified in New York County
Commission Expires October 13, 1996
<PAGE>
TENANT:
EMPIRE INSURANCE COMPANY
BY: ________________________
Thomas A. Daffron
Senior vice President
STATE OF New York )
: ss.:
COUNTY OF New York )
On the 10Th day of July, 1996, before me personally came Thomas A.
Daffron, to me known, who being by me duly sworn, did depose and say that he
resides at 38 Lance Road, Lebanon, New Jersey, that he is the Senior Vice
President of Empire Insurance Company, the Corporation described in and which
executed the foregoing instrument as Tenant, that he knows the seal of said
corporation; that the seal affixed to said instrument is such corporate seal;
that it is so affixed by order of the Board of Directors of said corporation;
and that he signed his name thereto by like order.
STATE OF New York )
: ss.:
COUNTY OF New York )
On the day of June, 1996 before me personally came Joshua L. Muss, to
me known, who being by me duly sworn, did depose and say that he resides at 17
Rutherford Lane, Lawrence, New York; that he is the President of Muss Brooklyn
Development corp., The corporation described in and which executed the
foregoing instrument as general partner of MWR associates, the managing member
of Brooklyn Renaissance plaza llc, landlord; that he knows the seal of said
corporation; that the seal affixed to said instrument is such corporate seal;
that it was so affixed by order of the board of directors of said corporation;
and that he signed his name thereto by like order.
168
<PAGE>
STATE OF New York )
: ss.:
COUNTY OF New York )
On this 27 day of June, 1996, before me personally came Joshua
L. Muss, to me known, who, being by me duly sworn, did depose and say that he
resides at I 1 Rutherford Lane, Lawrence, New York; that he is the President of
BRP II Corp., the corporation described in and which executed the foregoing
instrument as the Manager of BRP II Managers LLC, the Manager of BRP II LLC, the
limited liability company described in and which executed the foregoing
instrument; and that he signed his name thereto by authority of the board of
directors of BRP !I Corp. as the act and deed of BRP II LLC.
_______________________________
Notary Public
MICHEL MELENDEZ
Notary Public, State of New York
No. 01ME5052901
Qualified in Queens County
Commission Expires Dec. 4m 1997
<PAGE>
EXHIBIT A
BASE BUILDING/BUILDING SPECIFICATIONS
I. BASE BUILDING
1. FINISHES
A. DRYWALL
-------
Perimeter walls sheetrocked And taped. Interior columns
sheetrocked and taped. Core area, including bathrooms, telephone
closets, electrical closets, mechanical rooms, elevator lobbies
(all as otherwise required herein) sheetrocked and taped.
B. FLOORING
--------
Concrete slabs ready for carpet installation.
C. CEILING
-------
2' 0" x 4' O" lay-in ceiling in bathrooms only.
D. CERAMIC TILE
------------
Flooring and base in men's and women's bathrooms in core only.
Ceramic tile wainscot on fixture walls.
E. DOORS AND BUCKS
---------------
Hollow metal doors and BUCKS ON ALL service area rooms and
closets, bathrooms and stairways.
F. HARDWARE
Building standard.
2. MECHANICAL
A. ELECTRIC
--------
265/460 Service switch on each floor at buss duct. Fire alarm
system is as per code. Lighting in stairways and stairway exit
light only. Sleeves for telephone and computer cable in telephone
closet. Electricity directly metered to tenant.
B. HVAC
----
One air handler unit with associated controls per floor in
mechanical room with conditioned chilled or condenser water
<PAGE>
provided by central building system. Duct work in mechanical room
terminates at penetration of core wall. Exterior walls provided
with perimeter hot water base board heating. Bathrooms ventilated
as per Code.
C. SPRINKLER
---------
O.S. & Y valve provided at sprinkler riser in core.
D. PLUMBING
--------
One men's and one women's bathroom per floor complete in core.
Two wet columns provided at diagonal ends of building. Connection
for two drinking fountains at core.
II. BUILDING SPECIFICATIONS
1. PARTTIIONS:
Tenant's design shall provide that partitions ending at an extenior
wall of the building shall meet a mullion or column without
interfering with access to the peripheral enclosure or bisecting or in
any other way interfering with a vision light.
2. ELECTRICAL CONSTRUCTION:
A. Wiring: Electrical capacity with respect to each floor sufficient
for electric loads not to exceed 2-'h watts per square foot of
area served of 265/460 volt three phase for lighting and 3-
1/2 watts per square foot of 120/208 volt three phase for power.
3. HEATING, VENTILATION AND AIR CONDITIONING SYSTEM
The H.V.A.C. System will meet the following criteria:
Summer: Inside.......................78 D.B..............50% +- R.H.
Outside......................89 D.B..............75 W.B.
Winter: Outside......................72 D.B.
Outside......................15 D.B.
(Note: All temperatures are Degrees F.)
<PAGE>
The H.V.A.C. System is designed to meet the criteria set forth above within
tolerances appropriate for a first-class office building provided that:
(i) In any given room within the Premises, the occupancy does not exceed
one (1) person for each 100 square feet of rentable area served;
(ii) Total electrical load, including lighting and power, does not exceed 6
watts per square foot of area served;
(iii) Venetian blinds shall be installed by Tenant and shall be closed when
any sun load exists (all four seasons). All exterior venetian blinds shall be
subject to Landlord's approval in its sole and absolute discretion. Any
additional decorative window treatment shall allow for the proper circulation of
air in and around the window glass area and shall be subject to the approval of
Landlord which approval shall be made in Landlord's sole and absolute
discretion.
(iv) The maximum ventilation rate shall be as required by Code.
<PAGE>
EXHIBIT B
<PAGE>
Floor Plans for levels 22 through 26
consisting of 27,440 sq. ft. each
including elevator banks.
<PAGE>
Floor Plans for levels 27, 28 & 29
consisting of 27,440 sq. ft. each
including elevator banks.
<PAGE>
Floor Plans for levels 30 & 31
consisting of 27,440 sq. ft. each
including elevator banks.
<PAGE>
EXHIBIT C
LAND
BEGINNING at a point on the westarly side of Jay Street distant 210.51 feet
southerly from the corner formed by the westerly side of Jay Street and the
southerly side of Johnson Street;
RUNNING THENCE southerly along the westerly side of Jay Street 369.02 feet;
THENCE westerly along a line forming an interior angle of 89 degrees 22 minutes
24 seconds with the westerly side of Jay Street, 70 feet;
THENCE southerly and parallel with Jay Street, 6 feet;
THENCE westerly along a line forming an interior angle of 89 degrees 22 minutes
24 seconds with the last mentioned course 271.52 feet to the easterly side of
Adams Street;
THENCE northerly along the easterly side of Adams Street 375,02 feet;
THENCE easterly and parallel with Johnson Street 341.52 feet to the westerly
side of Jay Street the point or place of BEGINNING
<PAGE>
DESCRIPTI0N
(Office Unit 2)
The leasehold is comprised of premises designated and described as the
"Office Unit 2" as depicted on the Lease Diagrams for Brooklyn Renaissance
Plaza (the "Plans") prepared by Montrose Surveying Co., Inc. contained in that
certain Declaration of Easements (the "Declaration") dated as of June 27, 1996
made by MWR Associates, as Declarant, and intended to be recorded in the King's
County Register's Office, in respect of the building (the "Building") to be
constructed on the land (the "Land") more particularly described on Schedule
A-1 annexed hereto and made a part hereof.
TOGETHER WITH a21.843% interest in the "Common Elements" as such term is defined
in the Lease and the Declaration.
ALSO TOGETHER WITH the easements as described in, but subject to the
restrictions, requirements and limitations set forth in, the Declaration,
including, without limitation, the following:
(1) An easement for vertical and lateral support among all adjoining Units (as
such term is defined in the Declaration).
(2) An easement to erect, maintain, alter, repair, replace, substitute, expand,
renew and relocate (collectively, "Construct and Maintain") the Building.
(3) An easement to Construct and Maintain within the Land and Building or any
Unit therein or the subsurface thereof, the columns, footings, bracings,
foundations, slabs, exterior walls and all other structural members
supporting or serving the Building, for so long as they support and serve
the Building, and an easement to Construct and Maintain the support
facilities for the Building, any Unit therein and any replacements thereof
and additions thereto (collectively, the "Support Facilities").
(4) An easement to Construct and Maintain the Utility Facilities (as such term
is defined in the Declaration), together with a nonexclusive easement to
receive service through the Utility Facilities.
(5) An easement up and through the Building to the roof thereof to Construct
and Maintain ventilating shafts or ducts (the "Ventilating Facilities").
(6) An easement to construct and maintain gratings, manholes, sidewalks,
driveways, ramps, stairways, exits, ducts, conduits, overhead contact rails
and their supports and other similar facilities and any replacements
thereof and additions thereto (collectively, the "additional facilities")
together with a nonexclusive easement to use the additional facilities (the
support facilities, the utility fac$1ities, the ventilating facilities and
the additional facilities are collectively referred to as the
"Facilitiest").
(7) An easement of reasonable access on, over, across and through the land and
building and each unit therein (i) to perform any inspections or
obligations that are permitted or required to be performed under the
declaration, (ii) to exercise the rights granted pursuant to the
declaration and (iii) to comply with any applicable governmental
requirements affecting the land, the building and the facilities.
<PAGE>
EXHIBIT D
PRELIMINLARY PLANS and SPECIFICATIONS
Architectural plans for Brooklyn Renaissane Plaza prepared by William
B. Tabler Architects, 333 Seventh Avenue, New York, New York 10001 identified
as follows:
FIRST LAST
PAGE DESCRIPTION ISSUED REVISION
- ---- ----------- ------ --------
A-1 TITLE PAGE 05/01/89 12/29/89
A-2 SITE PLAN 02/13/89 12/29/89
A-3 1/32" SCALE PLANS 05/01/89 12/29/89
A-4 1/32" SCALE PLANS 02/13/89 12/29/89
A-5 1/32" SCALE PLANS 02/02/89 12/29/89
A-6 THIRD SUB-LEVEL PARKING - NORTH 01/05/89 12/29/89
A-7 THIRD SUB-LEVEL PARKING - SOUTH 01/05/89 12/29/89
A-8 SECOND SUB-LEVEL PARKING - NORTH 01/05/89 12/29/89
A-9 SECOND SUB-LEVEL PARKING - SOUTH 01/05/89 12/29/89
A-10 JAY ST. ENTRANCE - FIRST SUB-LEVEL PARKING - N. 01/05/89 12/29/89
A-11 JAY ST. ENTRANCE - FIRST SUB-LEVEL PARKING - S. 01/05/89 12/29/89
A-11C JAY STREET LOBBY ENTRANCE 08/28/97 -
A-12 ADAMS STREET ENTRANCE - NORTH - BUILDING FL. 1 01/05/89 12/29/89
A-13 ADAMS STREET ENTRANCE - SOUTH - BUILDING FL. 1 12/19/89 12/29/89
A-13C ADAMS STREET LOBBY ENTRANCE 08/28/91 -
A-14 HOTEL LOBBY FLOOR PLAN - NORTH - BUILDING FL. 2 02/02/89 12/29/89
A-15 HOTEL LOBBY FLOOR PLAN - SOUTH - BUILDING FL. 2 02/02/89 12/29/89
A-16 FIRST GUESTROOM FLOOR PLAN - N. - BLDG. FLOOR 3 02/02/89 12/29/89
A-17 FIRST GR FL. PLAN HEALTH CLUB - S. BLDG. FLOOR 4 02/02/89 12/29/89
A-18 SECOND GUESTROOM FLOOR PLAN - N. - BLDG. FLOOR 4 02/02/89 12/29/89
A-19 SECOND GR FL. PLAN - SOUTH - BUILDING FLOOR 5 02/13/89 12/29/89
A-20 THIRD GR FL. PLAN - NORTH - BUILDING FLOOR 5 02/13/89 12/29/89
A-21 THIRD GR FL. PLAN/MECH. ROOM - SOUTH-BLDG. FL. 5 01/05/89 12/29/89
A-22 FOURTH GR FL. PLAN - NORTH - BUILDING FLOOR 6 02/13/89 12/29/89
<PAGE>
EXHIBIT D
FIRST LAST
PAGE DESCRIPTION ISSUED REVISION
- ---- ----------- ------ --------
A-23 FOURTH GR FL. PLAN - S. - BUILDING FLOOR 6 02/13/89 12/29/89
A-24 FIFTH GR FL. PLAN - N. - BUILDING FLOOR 7 02/13/89 12/29/89
A-25 FIFTH GR & PART OFFICE FL. PLAN S. - BLDG. FL. 7 12/19/88 12/29/89
A-26 GUESTROOM ROOF PLAN - NORTH - BUILDING FLOOR 8 02/13/89 12/29/89
A-27 FIRST OFFICE FLOOR PLAN - BUILDING FLOOR 8 12/19/89 12/29/89
A-28 SECOND OFFICE FLOOR PLAN - BUILDING FLOOR 9 12/19/88 12/29/89
A-29 TYP. LOW-RISE OFF. FL. PLANS - BLDG. FLS. 10 THRU 17 12/19/88 12/29/89
A-30 OFFICE FLOOR TRANSFER FLOOR - BUILDING FLOOR 18 12/19/88 12/29/89
A-31 OFF. FL. LOW-RISE ELEVATORS OVERRUN-BLDG. FL. 19 12/19/88 12/29/89
A-32 OFF. FL. LOW-RISE ELEV. MACHINE RM.-BLDG. FL. 20 12/19/88 12/29/89
A-33 TYP. HI-RISE OFF. FLS.-BLDG. FLOORS 21 THRU 23 12/19/88 12/29/89
A-34 TYPICAL HI-RISE OFFICE FLOOR-BUILDING FLOOR 24 12/19/88 12/29/89
A-35 TYP. HI-RISE OFF. FLS.-BLDG FLS. 25 AND 26 12/19/88 12/29/89
A-36 TYP. HI-RISE OFF. FL. - BUILDING FLOOR 27 12/19/88 12/29/89
A-37 TYP. HI-RISE OFFICE FLOORS-BLDG. FLS. 28 AND 29 12/19/88 12/29/89
A-38 ROOFTOP LOUNGE AND MECH. RM. - BUILDING FL. 30 01/05/89 12/29/89
A-39 COOLING TOWERS AND ROOF MECH. RM. MEZZ.-BLDG. 31 05/01/89 12/29/89
A-40 ROOF PLAN AND PENTHOUSE PLAN-BLDG. FLOOR 32 02/13/89 12/29/89
A-41 WEST BUILDING ELEVATION - ADAMS STREET FACADE 05/01/89 12/29/89
A-42 SOUTH BUILDING ELEVATION - PEARL STREET FACADE 05/01/89 12/29/89
A-43 EAST BUILDING ELEVATION - JAY STREET FACADE 05/01/89 12/29/89
A-44 NORTH BUILDING ELEVATION 05/01/89 12/29/89
A-45 BUILDING SECTION A-A 05/01/89 12/29/89
A-46 BUILDING SECTION B-B 06/29/89 12/29/89
A-47 BUILDING SECTION C-C 06/29/89 12/29/89
A-48 MUNICIPAL GARAGE DETAILS 08/30/89 12/29/89
A-49 TYPICAL CENTRAL GUESTROOMS 08/30/89 12/29/89
A-50 TYPICAL SOUTHERN GUESTROOMS 08/30/89 12/29/89
A-51 BLDG. FL. 2, SECTOR-1 KITCHEN RESTAURANT 12/29/89 12/29/89
A-52 BLDG. FL. 2, SECTOR-2, BANQUET STORAGE 12/29/89 12/29/89
<PAGE>
EXHIBIT D
FIRST LAST
PAGE DESCRIPTION ISSUED REVISION
- ---- ----------- ------ --------
A-53 BLDG. FL. 2, SECTOR-3, RESTAURANT-SOUTH 12/29/89 12/29/89
A-54 BLDG. FL. 2, SECTOR-4, BALLROOM 12/29/89 12/29/89
A-55 BLDG. FL. 2, SECTOR-5, COCKTAIL LOUNGE 12/29/89 12/29/89
A-56 BLDG. FL. 2, SECTOR-6, PRE-ASSEMBLE 12/29/89 12/29/89
A-57 BLDG. FL. 2, SECTOR-7, FRONT DESK 12/29/89 12/29/89
A-58 BLDG. FL. 2, SECTOR 8, MEETING ROOMS 12/29/89 12/29/89
A-70 STAIR SECTIONS 12/29/89 12/29/89
A-71 STAIR SECTIONS AND DETAILS 12/29/89 12/29/89
<PAGE>
RULES AND REGULATIONS
EXHIBIT E
-----
1. Except as may otherwise be expressly provided in these Rules and
Regulations, the sidewalks, entrances, driveways, passages, courts, elevators,
vestibules, stairways, corridors, halls and/or other Common Areas shall not be
obstructed or encumbered by Tenant or used for any purpose other than for
ingress to and egress from the Premises and/or delivery of merchandise and
equipment in a prompt and efficient manner using elevators and passageways
designated for such delivery by Landlord. There shall not be used in any space
or in any public hall of the building in the delivery or receipt of merchandise,
any hand trucks, except those equipped with rubber tires, side guards and
bumpers.
2. The water and wash closets, plumbing fixtures and mechanical rooms,
if any, within the Premises shall not be used for any purposes other than those
for which they were designed or constructed and no sweepings, rubbish, rags,
acids or other substances shall be deposited therein, and the expense of any
breakage, stoppage, or damage resulting from the violation of this rule shall be
borne by the tenant who, or whose clerks, agents, employees or visitors, shall
have caused it.
3. No carpet, rug or other article shall be hung or shook out of any
window of the building. Tenant shall not sweep or throw, or permit to be swept
or thrown from the Premises any dirt or other substances into any of the
corridors or halls, elevators, or out of the doors or windows or stairways or
other Common Areas of the
<PAGE>
building, and Tenant shall not use, keep or permit to be used or kept any foul
or noxious gas or substance in the Premises, or permit or suffer the Premises to
be occupied or used in a manner offensive or objectionable to Landlord or other
occupants of the building by reason of noise, odors and/or vibrations, or
interfere in any way with other Tenants or those having business therein, nor
shall any animals or birds be kept in or about the building. Smoking or carrying
lighted cigars or cigarettes in the elevators of the building is prohibited.
Tenant shall comply, and cause its employees, guests and/or invitee to comply,
with any and all New York City and New York State smoking laws as same apply to
the Premises and rules and with such non-discriminatory building-wide
regulations promulgated by Landlord pursuant thereto.
4. No awnings or other projections shall be attached to the outside
walls of the building without the prior written consent of Landlord.
5. No sign, advertisement, notice or other lettering shall be
exhibited, inscribed, painted or affixed by Tenant on any part of the outside of
the Premises or the building or on the inside of the premises if the same is
visible from the outside of the Premises without the prior written consent of
Landlord, except that the name of Tenant may appear on the entrance door of the
Premises. In the event of the violation of the foregoing by Tenant, Landlord may
remove same without any liability, and may charge Tenant the expense incurred by
Landlord for such removal (including, but not limited to repair of the surface
area). Interior signs on doors and directory
-2-
<PAGE>
tablet shall be inscribed, painted or affixed for each tenant by Landlord at the
expense of such tenant and shall be of a size, color and style acceptable to
Landlord.
6. Tenant shall not mark, paint, drill into, or in any way deface any
part of the Premises or the building. No boring, cutting or stringing of wires
shall be permitted, except with the prior written consent of Landlord, and as
Landlord may direct. No Tenant shall lay linoleum or other similar floor
covering, so that the same shall come in direct contact with the floor of the
Premises, and no linoleum or other similar floor covering is desired to be used,
an interlining of builder's deadening felt shall be first affixed so that floor
by a paste or other material, soluble in water, the use of cement or other
similar adhesive material being expressly prohibited.
7. No additional locks or bolts of any kind shall be placed upon any of
the doors or windows of the Premises by Tenant, nor shall any changes be made in
existing locks or mechanism thereof. Tenant must, upon the termination of his
tenancy, restore to Landlord all keys of offices and toilet rooms, either
furnished to, or otherwise procured by such Tenant, and in the event of the loss
of any keys so furnished, such Tenant shall pay to Landlord the cost thereof.
8. Freight, furniture, business equipment, merchandise and bulky matter
of any description shall be delivered to and removed from the Premises only on
the freight elevators and through the service entrances and corridors, and only
during hours and in a manner approved by the Landlord. Landlord reserves the
right to inspect
-3-
<PAGE>
all freight to be brought into the building and to exclude from the building all
freight which violates any of these Rules and Regulations or the Lease. Landlord
reserves the right to require Tenant to reimburse Landlord upon demand the
reasonable cost of Landlord's staff supervision should same be required for such
after-hours-delivery and/or freight moving. Nothing herein shall be deemed to
obligate Landlord to provide such staff supervision.
9. Tenant shall not obtain for use upon the Premises ice, drinking
water, towel and other similar services, or accept barbering or bootblacking
services in the Premises, except from persons authorized by Landlord, and at
hours and under regulations fixed by the Landlord. Canvassing, soliciting and
peddling in the building is prohibited and Tenant shall cooperate with Landlord
to prevent the same.
10. Landlord reserves the right to exclude from the building between
the hours of 6 pm and 8 am and at all hours on Saturdays, Sundays, and legal
holidays all persons who do not present a pass (or similar identification
device) to the building issued and assigned by the Landlord or its authorized
representative. Tenant shall be responsible for all persons for whom it requests
such a pass and shall indemnify and hold Landlord harmless from for all acts of
such persons. Landlord reserves the right to recover from Tenant, on demand, the
costs of preparing and issuing said passes.
11. Tenant shall not bring or permit to be brought or kept in or on the
Premises any inflammable, combustible or explosive fluid, material, chemical or
substance, or cause or permit any odors
-4-
<PAGE>
of cooking or other processes or any unusual or other objectionable odors to
permeate in or emance from the Premises.
12. If the building includes a central HVAC system, Tenant agrees to
keep all windows and shades closed at all times and to abide by all rules and
regulations issued by the Landlord, from time to time, with respect to such
services. If Tenant requires HVAC services after the Standard Building hours and
days, Tenant shall give notice in writing to the building superintendent prior
to 2:00 p.m. in the case of services required on week days, and prior to 3:00
p.m. on the day prior in the case of after-hours service required on weekends or
on holidays. Tenant shall reimburse Landlord for such after-hour use in
accordance with the provisions of the Lease.
13. Landlord reserves the right for itself, its agents, contractors and
designees to unlimited access to all Common Areas, mechanical and service areas
within the Premises for purposes of inspection and/or service to equipment which
affects any portion of the remainder of the building. Nothing herein obligates
the Landlord to perform maintenance or repair service on the equipment except as
otherwise expressly provided in this Lease. Landlord reserves the right to
perform Tenant's obligations for the maintenance, service, and/or repair of the
Premises or of any mechanical systems situated therein if Tenant fails to do
same in accordance with the terms of the Lease, and to bill Tenant, as
additional rent, for the Landlord's reasonable cost therefor.
14. Tenant agrees that mechanical, service and Common Areas within the
Premises are to be kept clean and free of debris and are
-5-
<PAGE>
not to be used for any storage whatsoever.
15. Tenant agrees to abide by any non-discriminatory rules and
regulations promulgated by Landlord, from time to time, with respect to
after-hours access, including, but not limited to, paying Tenant's proportionate
share of the reasonable cost of purchasing, installing and maintaining any
building security system during such hours. Nothing herein shall be deemed to
obligate Landlord to supply or install any such security system.
-6-
<PAGE>
EXHIBIT F
Standard Building Hours & Days
------------------------------
Monday to Friday 8:00 a.m. - 7:00 p.m.
Saturday 9:00 a.m. - 4:00 p.m.
Building closed for all Holidays set forth in 32 B-JRAB Union Contract,
as may be amended from time to time.
New Years Day
Washington's Birthday
Good Friday
Memorial Day
Independence Day
Labor Day
Columbus Day
Thanksgiving Day
Day after Thanksgiving
Christmas Day
<PAGE>
EXHIBIT G
TITLE MATTERS
<PAGE>
OFFICE 2 LEASE
1. Survey made by Montrose Surveying Co., Inc., dated March 15, 1995 and last
revised May 17, 1996, shows the following:
(a) 6-inch concrete curbs encroach up to 1-3.4 inches onto Jay street;
(b) Outside limits of subway are approximately located on the easterly
portion of described premises. 1-story entrance, 6-inch concrete
curbs, iron fence, tress, concrete pavement, 12-inch granite wall and
utilities are located above said outside limits;
(C) Com Edison electric conduits are located on the easterly,
southeasterly and southwesterly portions of described premises and
continue onto Jay Street, Pearl Street and Adams Street. Electric
manholes are located on the southeasterly and southwesterly portions
of described premises;
(d) Column of 13-story stone building on premises adjacent on the
southeast encroaches up to 1 inch onto the southeasterly portion of
described premises;
(e) Brooklyn Union Gas 12-inch gas main is located on the northerly
portion of described premises and continues onto Adams Street and Jay
Street;
(f) 18-inch stone wall on premises adjacent on the north encroaches up to
8 inches onto the northerly portion of described premises;
(g) 12-inch stone and concrete wall and 12-inch granite wall on the
northeasterly portion of described premises encroach up to 21/2 inches
onto premises adjacent on the northeast;
(h) Curb on premises adjacent on the northeast encroaches onto the
northeasterly portion of described premises; and
(i) Light poles, manholes, drains, catch basins, gratings, water valves,
gas pipes, pipes and other utilities are located within record lines.
2. Water and sewer meter charges from date of last actual reading and entries
for meter readings not shown in the New York City Collector's records at or
prior to closing and entered and billed subsequent to closing for periods
prior to closing.
3. Merger of Zoning Lots and Declaration of Restrictions dated February 19,
1002, recorded September 1, 1992 in Real 2905 page 284 made by The City of
New York, as Declarant.
4. Zoning Lot Development Agreement dated February 19, 1992, recorded
September 1, 1992 in Real 2905 page 297 made by and among The City of New
York, New York City Economic Development Corporation, MME Associates and
Forest City Ratner Companies.
5. Declaration of Easements made by MMR Associates, as Declarant, dated as of
June 27, 1996 and intended to be recorded in the King's County Register's
Office.
6. Terms, covenants and conditions of Severed, Amended and Restated Agreement
of Lease (Office Unit 2 Severance Lease) between The City of New York
(Landlord) and Brooklyn Renaissance Plaza LLC (Tenant), dated as of June
27, 1996, a memorandum of which is intended to be recorded in the King's
County Register's Office.
<PAGE>
OFFICE 2 LEASE
7. Lease between Brooklyn Renaissance Plaza LLC (Landlord) and MRP II LLC
(Tenant), dated as of June 27, 1996, a memorandum of which is intended to
be recorded in the Kings County Register's Office. With respect thereto:
(a) Leasehold Mortgage, Assignment of Lease and Rents and Security
Agreement made by New York City Industrial Development Agency and MRP
II LLC to United States Trust Company of New York (as Indenture
Trustee), dated as of June 27, 1996 in the principal amount of
$53,433.00 and intended to be recorded in the King's County Register's
Office. (Also encumbers Agreement of Lease {Exception 8})
8. Agreement of Lease (Empire LLC-IDA) between BRP II LLC (Lessor) and New
York City Industrial Development Agency (Lessee), dated as of June 27,
1996, a memorandum of which is intended to be recorded in the King's
Country Register's Office. With respect thereto:
(a) Leasehold Mortgage, Assignment of lease and Rents and Security
Agreement made by New York City Industrial Development Agency and
Brooklyn Renaissance Funding Company LLC to United States Trust
Company of new York (as Indenture Trustee) dated as of June 27, 1996
in the principal amount of $80,766,000 and intended to be recorded in
the King's County Register's Office.
(b) Intercreditor Agreement dated as of June 27, 1996 among BRP II LlC,
New York City Industrial Development Agency, Brooklyn Renaissance
Funding Company LLC, United States Trust Company of New York and Paine
Webber Incorporated intended to be recorded in the King's County
Register's Office.
9. Lease Agreement (IDA-Empire LLC) between New York City Industrial
Development Agency (Lessor) and BRP II LLC (Lessee), dated as of June 27,
1996, a memorandum of which is intended to be recorded in the King's County
Register's Office.
10. Agreement of Lease by and between Brooklyn Renaissance Plaza LLC
(Landlord), BRP II LLC (Sublandlord) and Empire Insurance Company (Tenant),
dated as of June 27, 1996, a memorandum of which is intended to be recorded
in the King's County Register's Office. With respect thereto:
(a) Lease Assignment and Agreement made by BRP II LLC to United
States Trust Company of New York (as Indenture Trustee) dated
as of June 27, 1996 and intended to be recorded in the King's
County Register's Office.
<PAGE>
EXHIBIT H
---------
CLEANING SPECIFICATIONS
-----------------------
GENERAL Except as specifically provided herein, Landlord
-------
shall furnish all labor, supplies, materials,
equipment, supervision, and perform satisfactorily
the services at the frequencies and during the times
as specified herein. The services shall include all
functions normally considered a part of workmanlike,
satisfactory janitorial work.
1. TOILET ROOMS - (INCLUDES PRIVATE TOILET ROOMS):
-----------------------------------------------
A. Daily:
-----
(1) Floors shall be swept and wet mopped or scrubbed with
disinfectant detergent.
(2) Water closets, seats and urinals shall be washed
inside and out with a disinfectant detergent. Seas
shall be left in a raised position. No rust,
encrustation or water rinse shall exist.
(3) Traps shall be maintained free from odor at all
times.
(4) All washbasins shall be thoroughly cleaned.
(5) All mirrors, shelving, dispensers, chromium fixtures
and piping shall be damp wiped and polished dry.
(6) Radiators, window sills, ledges, grilles and stall
partitions shall be dusted monthly.
(7) Wall surfaces, partitions, doors, window frames,
sills and waste receptacles shall be spot cleaned.
(8) Paper towel waste receptacles shall be emptied prior
to the building occupants' official starting time.
In addition, during the contractor's day shift, the
paper towel waste receptacles shall be again
emptied, toilet roomsshall be policed and
washbasins shall be clean.
(9) Paper towels, hand soap, toilet paper, seat cover
dispensers (where provided) shall be serviced prior
to building occupants' official starting time. These
dispensers shall also be serviced daily
-1-
<PAGE>
during the building occupants' working hours on a
schedule approved by the Building Manager based
on the traffic demands. Soap dispensers will be
maintained in a clean condition, free of excess
soap, gum, etc. Malfunctions of any type shall be
reported to the Building Manager.
B. Monthly:
-------
Wall surfaces, toilet partitions, etc. shall be washed.
C. Semi-Annually:
-------------
Entire restroom areas are to be thoroughly cleaned, including
washing of toilet stalls, walls, etc. The floors shall be
thoroughly cleaned and appropriate sealing, stripping, waxing,
etc., shall be performed based on floor type.
2. Office, Room Space Cleaning:
---------------------------
A. Daily:
-----
Office areas, file rooms, libraries, conference rooms, etc.
and the corridor space adjacent to these areas shall receive
the following daily cleaning:
(1) Ashtrays:
--------
The contents of ashtrays and smoking stands shall be
emptied into metal containers and the ashtrays wiped
clean with a damp cloth.
(2) Wastebaskets:
------------
Wastebaskets shall be emptied. Trash shall be removed
to main disposal area.
(3) Floor Sweeping:
--------------
The full floor area is to be cleaned to remove all
dirt, dust and litter. Exposed floor areas in
partially carpeted office are to be swept in
accordance with the above requirements. Spot mop as
required.
Note: The work requirements for floor sweeping and rug
-----
vacuuming are to be performed on a schedule basis
approved by the Tenant's representative. Obvious
surface dirt referred to is any visible foreign
matter found on the floor, rug or carpet surface and
includes but is not limited to paper clips, staples,
metal fasteners, pencil sharpenings, erasers, paper
pieces, fragments, clippings and ashes, mud, sand,
rubber bands, cigarette butts and so on.
-2-
<PAGE>
(4) Washbasins and mirrors:
----------------------
Washbasins shall be cleaned and mirrors damp wiped
and dried, as necessary, to keep them in a clean and
acceptable condition. Landlord shall service towel
dispensers where provided.
(5) Drinking Fountains:
------------------
Clean extraneous material and damp wipe clean.
Adjacent floors and walls are to be wiped clean at
this time.
(6) Executive Space:
---------------
In executive office space, as identified by the
Tenant's representative, the full rug area shall be
vacuumed.
(7) Dusting:
-------
All top surfaces of furniture, window sills, tops of
cabinets, etc., up to shoulder height shall be dusted
in an approved manner.
B. Weekly:
------
(1) Full rug or carpeted area is to be vacuumed weekly to
remove all dirt, dust and litter. On four remaining
days of each week, rugs and carpets are to be spot
vacuumed to remove obvious surface dirt from traffic
areas and from under furniture.
(2) All resilient flooring shall be mopped when
necessary.
C. Quarterly:
---------
(1) Spot clean all wall surfaces up to approximately 70
inches high.
(2) Dust top of partitions, hand dust all office
furniture, etc.
(3) Damp wipe all waste receptacles and waste baskets.
(4) Dust all baseboards, moldings, ledges and trim.
(5) Strip, scrub wash and apply floor finish to all
resilient flooring.
D. Semi-Annually:
-------------
(1) Dust pictures, frames, charts and other wall
hangings.
-3-
<PAGE>
E. As Necessary:
------------
(1) Relamp. Tenant will supply all bulbs and fluorescent
tubes and Landlord will install the same at Tenant's
cost.
3. ENTRANCES, LOBBIES, CORRIDORS, ELEVATORS, STAIRCASE:
---------------------------------------------------
A. Daily:
-----
(1) All floors shall be swept or, if carpeted, vacuumed.
(2) All surfaces within approximately 70 inches from the
floor shall be dusted, metal and wood surfaces
dusted, damp wiped metal surfaces, wall spot cleaned.
(3) Damp wipe all waste receptacles and waste baskets.
Empty, clean and damp wipe all ashtrays, cigarette
burns, etc.
(4) All glass surfaces shall be cleaned.
(5) All hard floors shall be swept, wet-mopped and/or
scrubbed.
(6) All resilient floors shall be swept with treated
sweep mop.
Note: Where thee are carpeting runners, vinyl runners etc.,
----
they shall be picked up and areas underneath cleaned.
Rugs, runners shall be properly cleaned and replaced
daily.
B. Quarterly:
---------
(1) Strip, scrub, wash and apply floor finish to
resilient flooring.
(2) Dust all vertical surfaces, walls, etc., not reached
in daily cleaning.
C. Elevators:
---------
(1) All surfaces in interior of car shall be cleaned
daily including hoistway doors and crevices. All
bright metal surfaces shall be properly cared for
daily.
(2) Resilient floors shall be cleaned, damp mopped daily
and spray buffed, if applicable.
-4-
<PAGE>
D. Stairways:
---------
(1) Weekly, stairways shall be swept or vacuumed. Hand
railings, doors, radiators, grilles and fire
operators shall be dusted.
(2) Weekly, all landings, steps and risers shall be
mopped. Glass surfaces cleaned and bright metal.
cleaned. Walls shall be spot cleaned and dusted
(low).
(3) Semi-annually, all landings, steps and risers shall
be scrubbed. Walls shall be spot cleaned and dusted
(high).
4. MISCELLANEOUS CLEANING: OUTSIDE ENTRANCE, SIDEWALKS, GROUND:
------------------------------------------------------------
A. Daily:
-----
Sweep all landings, steps, sidewalks, entrances, loading
platforms, delivery areas etc. Maintain clean refuse area.
B. Weekly:
------
Clean entrance door metal work, kick plates, push plates and
bars, etc. Remove all foreign matter, (grease, oil, mold),
etc.
C. Monthly:
-------
Hose down exterior areas, sidewalks, etc.
Note: Weather and water use restrictions shall be observed.
----
5. DAYTIME SERVICES:
----------------
Daily:
-----
(1) Bathrooms stocked daily (minimum).
(2) Lobby to be policed three (3) times daily.
(3) Exterior to be swept once daily.
(4) Graffiti to be removed (when required).
(5) Snow removal (when required).
(6) Servicing complaints, (when required).
(7) Clean up work due to floor spills, etc., and similar
occurrences (when required).
-5-
<PAGE>
6. MISCELLANEOUS DUTIES: In addition to the work specified above, the
following additional duties shall be
performed by the Landlord or Landlord's
contractor in conjunction with the cleaning
operation.
(1) Reporting fires, hazardous conditions and items in need of
repair, leaking faucets, toilet stoppages, etc.
(2) Closing windows and turning off switchable lights when not in
use.
(3) Seeing that rooms in Security Areas are locked after cleaning and
the keys are returned to the designated office, or otherwise
follow security requirements.
(4) Turning in at the designated office all lost and found articles.
(5) Landlord shall be responsible for removal, but not separation, of
all normal rubbish of Tenant. All rubbish removal of major items
and other than normal rubbish shall be the responsibility of
Tenant.
(6) With respect to public spaces, i.e. lobby, elevators, service
areas only, extermination of vermin/insects as required.
(7) Wash all windows, both inside and out, a minimum of three times a
year. Window washer must inform City Employees (custodians or
program director) of his/her presence before starting to work.
-6-
<PAGE>
Exhibit I
Benefits Provided to Tenant
for Deposit in the Tenant Improvement Fund
(i) Mortgage Recording Tax Benefits. By recording the mortgages described
below, the New York City Industrial Development Agency (the "Agency") has saved
the Landlord mortgage recording tax in the amount of 2.75% of the original
principal amount of each of the mortgages:
(A) $54,433,000 Leasehold Mortgage, Security Agreement, Agreement of
Leases and Rents and Financing Statement dated as of June 27, 1996, (the "Agency
Mortgage (Empire Unit)") from the Agency, as mortgagor and the Sublandlord, as
mortgagor and debtor, to United States Trust Company of New york, as Trustee
(the "Trustee");
(B) $80,766,000 Leasehold Mortgage, Security Agreement, Agreement of
Leases and Rents and Financing Statement dated as of June 27, 1996 (the "Agency
Mortgage (DA Unit) ") from the Agency, as mortgagor and BRP I, LLC, as mortgagor
and debtor, to the Trustee, as Trustee; and
(C) 19,750,000 Mortgage and Security Agreement dated as of June 27,
1996 (the "Agency Mortgage (Hotel Unit)") from the Agency, as mortgagor and
Brooklyn Renaissance Hotel, LLC, as mortgagor and debtor, to The Union Labor
Life Insurance Company, as Mortgage.
(ii) The monies identified as the "Empire Funds" pursuant to the Sales Tax
Agreement, consisting of up to $2,000,000 distributed by NYCEDC on behalf of
Tenant pursuant to Section 2.03 of the Sales Tax Agreement.
A/1944-01
<TABLE> <S> <C>
<ARTICLE> 7
<S> <C>
<PERIOD-TYPE> 3-MOS
<FISCAL-YEAR-END> DEC-31-1997
<PERIOD-END> MAR-31-1997
<DEBT-HELD-FOR-SALE> 246,618
<DEBT-CARRYING-VALUE> 254,672
<DEBT-MARKET-VALUE> 254,678
<EQUITIES> 0
<MORTGAGE> 0
<REAL-ESTATE> 0
<TOTAL-INVEST> 254,672
<CASH> 3,264
<RECOVER-REINSURE> 334,669
<DEFERRED-ACQUISITION> 8,083
<TOTAL-ASSETS> 641,993
<POLICY-LOSSES> 406,369
<UNEARNED-PREMIUMS> 113,290
<POLICY-OTHER> 0
<POLICY-HOLDER-FUNDS> 0
<NOTES-PAYABLE> 0
0
0
<COMMON> 7,079
<OTHER-SE> 68,082
<TOTAL-LIABILITY-AND-EQUITY> 641,993
22,222
<INVESTMENT-INCOME> 3,863
<INVESTMENT-GAINS> 17
<OTHER-INCOME> 2,006
<BENEFITS> 19,949
<UNDERWRITING-AMORTIZATION> 3,936
<UNDERWRITING-OTHER> 2,757
<INCOME-PRETAX> 1,317
<INCOME-TAX> 461
<INCOME-CONTINUING> 856
<DISCONTINUED> 0
<EXTRAORDINARY> 0
<CHANGES> 0
<NET-INCOME> 856
<EPS-PRIMARY> .12
<EPS-DILUTED> .12
<RESERVE-OPEN> 0
<PROVISION-CURRENT> 0
<PROVISION-PRIOR> 0
<PAYMENTS-CURRENT> 0
<PAYMENTS-PRIOR> 0
<RESERVE-CLOSE> 0
<CUMULATIVE-DEFICIENCY> 0
</TABLE>